Phase Completion Date definition

Phase Completion Date. [means, as the context may require, the Phase 1 Completion Date and/or the Phase 2 Completion Date;]
Sample 1Sample 2
Phase Completion Date with respect to each Phase, the earlier to occur of (i) Completion of such Phase, (ii) (x) as to the Initial Phases for the Applicable Sites located in Miami, Florida and San Antonio, Texas, October 21, 1997, (y) as to all other Initial Phases, the date which is six months after the Phase Commencement Date for such Phase, and (z) as to all Subsequent Phases, January 21, 2000, and (iii) the last day of the Acquisition Period.
Sample 1
Phase Completion Date means for each relevant Phase the date falling 10 Working Days after the later of the following:- (a) the Pre Emption Satisfaction Date (b) the date of receipt by the Agency of a Developer's Drawdown Request for the relevant Phase
Sample 1

Examples of Phase Completion Date in a sentence

  • Without prejudice to Clauses 40 (DBFM Co Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • If Vendor fails to meet any Targeted Phase Completion Date by more than ten (10) weeks, or fails to achieve completion of the System by more than ten (10) weeks after the Targeted System Completion Date, SIA shall be entitled without prejudice to any other rights or remedies it may have hereunder or at law to terminate forthwith this Agreement immediately by giving written notice to Vendor.

  • Without prejudice to Clauses 40 (Sub-hubco Event of Default), 42 (Authority Voluntary Termination), 46 (Compensation on Termination) and 47 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the Completion Date [Phase Completion Date] and the Actual Completion Date [relevant Phase Actual Completion Date].

  • Notwithstanding that the Works [relating to a Phase] may have been completed in accordance with this Agreement, the Actual Completion Date [Phase Actual Completion Date] may only occur on a date on or after the Completion Date [Phase Completion Date] unless the Authority, in its absolute discretion, agrees otherwise in writing.

  • The following chart presents the projected data for each phase of the Project: Phase # of Homes Effective Date Phase Completion Date Minimum Phase Valuation Phase Approx.

  • LARA Program Review Process Flowchart with Phase Completion Date vFigure 1.

  • Multi-year project?: Yes ☐ No ☐ Phase Completion Date (10/1/16-9/30/18): Enter text.

  • Provided that performance of this Agreement has not been suspended or terminated by the City under Article VII hereof, the City shall pay any Loan Advances attributable to each phase of the Project which is approved by any one or more Requisitions under this Article to the Developer within twenty-one (21) calendar days after (i) each Phase Completion Date, and (ii) the approval of any such Requisition(s) applicable thereto, whichever in (i) and (ii) occurs last.

  • Without prejudice to Clause 44 (Project Co Event of Default), 46 (Authority Voluntary Termination), 50 (Compensation on Termination) and 51 (Consequences of Termination) the Authority shall not be entitled to claim liquidated or general damages in respect of any delay which elapses between the [Completion Date] [Phase Completion Date] and the [Actual Completion Date] [relevant Phase Actual Completion Date].

  • If and to the extent that a delay pertaining to one or more of the Phases of the Renovation Work delays the commencement or completion of another Phase of the Renovation Work, then the Required Phase Commencement Date and/or Required Phase Completion Date, as applicable, for the later Phase shall be extended by the actual delay caused by such Force Majeure event pertaining to the preceding Phase or Phases, it being understood that the Phases are intended to be completed sequentially.


More Definitions of Phase Completion Date

Phase Completion Date with respect to each Phase, the earlier to occur of (i) Completion of such Phase, (ii) the date which is six months after the Phase Commencement Date for such Phase, and (iii) the last day of the Acquisition Period.
Sample 1
Phase Completion Date means the date that XXX.XXXXXX notifies CUSTOMER that the Products for a given phase are installed and available for customer use (including for the purpose of configuration and beta testing by CUSTOMER) The provisions of this Agreement shall be deemed included in accompanying Addendums or Attachments to this Agreement, except if there is a conflict with a provision in any such separate Agreement, in which event, the separate Agreement shall control.
Sample 1
Phase Completion Date means the date on which the Completion Certificate is issued under the provisions of Article 13;
Sample 1

Related to Phase Completion Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Final Completion Date means the date on which Final Completion occurs.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Phase 2 means the second implementation phase of this section, beginning June 1, 2022 and continuing thereafter.

  • COMPLETION TIME means the period by date specified in the acceptance of tender for handing over the erected equipment/plant which are found acceptable by the Engineer being of required standard and conforming to the specifications of the contract.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Completion Deadline means August 15, 2018, or such later date as may be agreed to in writing by the Parties;

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Commercial Operation Date means the date on which a Material Project is substantially complete and commercially operable.

  • Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.