Minor Items definition

Minor Items means items that do not affect the commercial utility or safe operation of the Vessel or prevent or otherwise limit the ability of the Vessel to trade.
Sample 1Sample 2
Minor Items means any uncompleted construction or improvements which do not materially interfere with Tenant's use and occupancy of the Demised Premises. Tenant shall promptly submit to Landlord a "punch-list" of such "minor items," which punch-list items, after approval by Landlord, shall be diligently completed. Tenant shall periodically inspect Landlord's Work and make any objections thereto, if called for, without delay, so as to mitigate changes, delays and costs.
Sample 1

Examples of Minor Items in a sentence

  • The Design Professional will assign a value for each the Minor Items and Permitted Incomplete Work.

  • The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2).

  • The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited by the Owner or incurred as liquidated damages, and less amounts withheld for the punchlist by reason of Minor Items or Permitted Incomplete Work.

  • Minor Items shall be completed as expeditiously as possible, but not later than thirty days after Material Completion of the Work.

  • The Design Professional shall confirm that the Final Punch List and all Minor Items and Permitted Incomplete Work are successfully accomplished.

  • The Design Professional’s Certificate of Final Completion shall not be issued until all Minor Items and Permitted Incomplete Work are completed.

  • The Contractor may request payment of the remaining contract balance, including retainage, less the amounts credited the Owner or incurred as Liquidated Damages, and less the amounts withheld for the punchlist by reason of Minor Items or Permitted Incomplete Work.

  • The Contractor shall complete construction, except for Minor Items and Permitted Incomplete Work (see Article 6.1.1), not later than the Material Completion and Occupancy Date, as adjusted by Change Order.

  • The Design Professional shall confirm the Final Punch List has been completed including all Minor Items.

  • The Design Professional shall confirm the Initial Punch List and shall add or delete such Minor Items or Permitted Incomplete Work as shall be appropriate.

Related to Minor Items

  • Punch List Items means such items (i) as are reasonably necessary or appropriate to fully complete the construction, equipping and furnishing of the Hotel in accordance with this Contract and (ii) that, unless otherwise agreed by Buyer in its sole discretion, (a) individually and in the aggregate do not and will not prohibit, cause a delay in or otherwise adversely affect, under applicable Legal Requirements, the Franchise Agreement or otherwise, the opening of the Hotel for business to the public or the continued occupancy and operation of the Hotel as contemplated under the Brand and (b) may be corrected or completed, subject to delays caused by Force Majeure, within not more than sixty (60) days.

  • Source-image receptor distance means the distance from the source to the center of the input surface of the image receptor.

  • Collective Work means a work, such as a periodical issue, anthology or encyclopedia, in which the Work in its entirety in unmodified form, along with a number of other contributions, constituting separate and independent works in themselves, are assembled into a collective whole. A work that constitutes a Collective Work will not be considered a Derivative Work (as defined below) for the purposes of this License.

  • Items means the finished goods or services which are intended for export from the United States, either directly or as an Indirect Export, meet the U.S. Content requirements in accordance with Section 2.01(b)(ii) of this Agreement and are specified in Section 4.A. of the Loan Authorization Agreement.

  • Unique item identifier type means a designator to indicate which method of uniquely identifying a part has been used. The current list of accepted unique item identifier types is maintained at http://www.acq.osd.mil/dpap/pdi/uid/uii_types.html.

  • Respiratory protective equipment means an apparatus, such as a respirator, used to reduce an individual's intake of airborne radioactive materials.

  • Contractor’s Equipment means all apparatus, machinery, vehicles and other things required for the execution and completion of the Works and the remedying of any defects. However, Contractor’s Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the Equipment.

  • Unique item identifier means a set of data elements marked on items that is globally unique and unambiguous. The term includes a concatenated unique item identifier or a DoD recognized unique identification equivalent.

  • Nonconforming structure means a structure the size, dimension or location of which was lawful prior to the adoption, revision or amendment of a zoning ordinance, but which fails to conform to the requirements of the zoning district in which it is located by reasons of such adoption, revision or amendment.

  • Excluded Items means any items which the Committee determines shall be excluded in fixing Performance Goals, including, without limitation, any gains or losses from discontinued operations, any extraordinary gains or losses and the effects of accounting changes.

  • Nominal tomographic section thickness means the full width at half-maximum of the sensitivity profile taken at the center of the cross-sectional volume over which x-ray transmission data are collected.

  • Minor defect means a defect which is not a Major Defect.

  • Image receptor means any device, such as a fluorescent screen or radiographic film, which transforms incident X-ray photons either into a visible image or into another form which can be made into a visible image by further transformations.

  • Contractor Materials means Materials owned or developed prior to the provision of the Work, or developed by Contractor independently from the provision of the Work and without use of the Court Materials or Confidential Information.

  • Tooling means tools funded or provided by the Buyer.

  • Explosives or munitions emergency response specialist means an individual trained in chemical or conventional munitions or explosives handling, transportation, render-safe procedures, or destruction techniques. Explosives or munitions emergency response specialists include Department of Defense (DOD) emergency explosive ordnance disposal (EOD), technical escort unit (TEU), and DOD-certified civilian or contractor personnel; and other Federal, State, or local government, or civilian personnel similarly trained in explosives or munitions emergency responses.

  • Standard equipment means the basic configuration of a vehicle which is equipped with all the features that are required under the regulatory acts of the Contracting Party including all features that are fitted without giving rise to any further specifications on configuration or equipment level.

  • Third Party Items means Third Party Content and Third Party Products.

  • Color additive means a material that either:

  • HIV/AIDS means human immunodeficiency virus/acquired immune deficiency syndrome;

  • DoD item unique identification means a system of marking items delivered to DoD with unique item identifiers that have machine- readable data elements to distinguish an item from all other like and unlike items. For items that are serialized within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier and a unique serial number. For items that are serialized within the part, lot, or batch number within the enterprise identifier, the unique item identifier shall include the data elements of the enterprise identifier; the original part, lot, or batch number; and the serial number.

  • Electrical equipment means underground equipment that contains dielectric fluid that is necessary for the operation of equipment such as transformers and buried electrical cable.

  • Supplier Materials has the meaning set out in clause 8.1(g);

  • Predictive emissions monitoring system or "PEMS" means all of the equipment necessary to monitor process and control device operational parameters (for example, control device secondary voltages and electric currents) and other information (for example, gas flow rate, O2 or CO2 concentrations), and calculate and record the mass emissions rate (for example, pounds per hour) on a continuous basis.

  • Check Meter means the Buyer revenue-quality meter section(s) or meter(s), which Buyer may require at its discretion, and which will include those devices normally supplied by Buyer or Seller under the applicable utility electric service requirements.

  • Defective Work means (a) Work that is unsatisfactory, deficient or damaged, does not conform to the Contract Documents, or does not meet the requirements of any inspection, test or approval, or (b) Work associated with punch list items that the Contractor fails to complete within a reasonable time after issuance of the punch list by the Project Manager.