Landlord's Damages definition

Landlord's Damages means the sum of (i) the present value of the Base Rent and additional rent specified in this lease for the residue of the stated term following termination of the lease or of Tenant's rights to possession less the present value of fair market rental value of the demised premises for such residue and (ii) any other sums then due to Landlord hereunder. In calculating the amount of Landlord's damages (x) present value shall be computed on the basis of a discount of ten percent (10%) per year and (y) the additional rent due Landlord for the rest of the lease term shall be deemed to equal the additional rent payable for the last calendar year of the lease term prior to termination of this lease or of Tenant's right to possession (or the additional rent which would have been paid for the calendar year in which such termination occurred, if no additional rent had previously been paid).
Sample 1
Landlord's Damages means an amount equal to the present value of the amount by which the Remainder Rent exceeds the Fair Market Rent for the remainder of the stated Term of this Lease. The present value shall be computed on the basis of a discount rate equal to the then-current yield on United States Treasury obligations having a maturity approximately equal to the residue of the stated Term of the Lease (had there been no Default), as determined by Landlord.
Sample 1
Landlord's Damages means the sum of (i) the Rent specified in this Lease for the remainder of the stated Term following termination of this Lease or of Tenant's right to possession, (ii) any other sums or damages then due to Landlord hereunder, and (iii) any other expenses, costs or damages (including, without limitation, reasonable attorneys' fees and court costs and any damages or deficiency in the reletting of the Premises) incurred by Landlord in connection with any default hereunder or any corresponding default under the Master Lease.
Sample 1

More Definitions of Landlord's Damages

Landlord's Damages means the sum of (i) the present value of the Base Rent and additional rent specified in this lease for' the residue of the stated term following termination of the lease or of Tenant's rights to possession less the present value of fair market rental value of the demised premises for such residue and (ii) any other sums then due to Landlord hereunder. In calculating the amount of Landlord's damages (x) present value shall be computed on the basis of a discount of ten percent (l0~) per year and (y) the additional rent due Landlord for the rest of the lease term shall be deemed to equal the additional rent payable for the last calendar year of the lease term prior to termination of this lease or of Tenant's right to possession (or the additional rent which would have been paid for the calendar year in which such termination occurred, if no additional rent had previously been paid).
Sample 1

Related to Landlord's Damages

  • Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent of the then replacement cost of the Building.

  • Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition, Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 12 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.

  • Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.

  • Major Damage means damage that in the estimation of the surveyor exceeds USD

  • Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Environmental Damages means all claims, judgments, damages, losses, penalties, fines, liabilities, encumbrances, liens, costs and expenses of investigation and defense of any claim, including, without limitation, attorney’s fees, that are incurred at any time as a result of the existence of Environmental Conditions upon, about or beneath the Project Site or migrating or threatening to migrate to or from the Site, and including, without limitation:

  • Subleased Premises means approximately -18;961 rentable square feet on the 141h floor of the Building, as more specifically depicted on Exhibit A attached hereto and made a part hereof. The Subleased Premises include all of the Leased Premises identified in the Prime Lease.

  • Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.

  • Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord means the owner, lessor or sublessor of the dwelling unit or the building of which such

  • Sublessor means one who conveys real property by sublease."

  • Structural damage means a covered building, regardless of the date of its construction, has experienced the following.

  • Environmental Damage means any injury or damage to persons, living organisms or property (including offence to man’s senses) or any pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;

  • Subtenant means any Person entitled to occupy, use, or possess any Premises under a Sublease.

  • Tenant means any Person leasing, subleasing or otherwise occupying any portion of the Property under a Lease or other occupancy agreement.

  • Additional Rent means all amounts, other than Basic Rent and any Security Deposit, required to be paid by the Tenant to the Landlord in accordance with this Agreement.

  • Leased Premises means the Leased Premises as defined in Paragraph 1.

  • Direct Damage has the meaning given to it in clause 26.2;

  • the Building means any building of which the Property forms part.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Tenants means the tenants under the Leases.

  • Sublessee means any Person for so long, but only so long, as such Person is in possession of the Airframe and/or any Engine pursuant to the terms of a Sublease which is then in effect pursuant to Section 7(b)(x) of the Lease.

  • Rent as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the “worth at the time of award” shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.