Landlord Related Party definition

Landlord Related Party means any officer, director, partner, employee, member, agent or contractor of Landlord.
Sample 1Sample 2Sample 3
Landlord Related Party means an employee, agent, contractor, licensee, customer, invitee or affiliate of Landlord, but specifically excludes Tenant and any other lessee or tenant of the Project. “Tenant-Related Party” means an employee, agent, contractor, licensee, customer, invitee or affiliate of Tenant but specifically excludes Landlord.
Sample 1Sample 2Sample 3
Landlord Related Party means any officer, director, owner, partner, employee, agent, contractor, vendor, or property manager of Landlord or any affiliate of Landlord.
Sample 1Sample 2

Examples of Landlord Related Party in a sentence

  • Neither Landlord nor any Landlord Related Party shall have any personal liability with respect to any of the provisions of the Lease, or the Premises.

  • In no event shall Landlord or any Landlord Related Party ever be liable to Tenant for loss of profits, loss of business, or indirect or consequential damages suffered by Tenant from whatever cause.

  • This indemnity extends to the costs incurred by any Landlord Related Party to investigate, remediate, monitor, treat, repair, clean-up, dispose of, or remove such Hazardous Materials in order to comply with the Environmental Laws; provided that if Tenant is not otherwise in Default, Landlord shall give Tenant not less than thirty (30) days’ advance notice of Landlord’s intention to incur such costs.

  • Tenant agrees that in no case shall Landlord or any Landlord Related Party be responsible or liable on any theory for any injury to Tenant’s business, loss of profits, loss of income or any other form of consequential damage.

  • Pixels with the significant CORemission (T ∗> 0.21 K) are shown in red.

  • Notwithstanding anything to the contrary contained in this Lease, except for any liability of Tenant expressly permitted under Article 18 of this Lease, Tenant shall not be liable to Landlord or any Landlord Related Party for any loss of rent, loss of business, indirect or consequential damages incurred by Landlord from any cause whatsoever, including the negligence or fault of any of Tenant or the Tenant Related Parties.

  • Neither Landlord nor any Landlord Related Party shall be personally liable for any judgment or deficiency, and in no event shall Landlord or any Landlord Related Party be liable to Tenant for any lost profit, damage to or loss of business or a form of special, indirect or consequential damage.

  • No act of Landlord or of any Landlord Related Party, including Landlord’s acceptance of the keys to the Premises, shall constitute Landlord’s acceptance of a surrender or abandonment of the Premises by Tenant prior to the expiration of the Term unless such acceptance is expressly acknowledged by Landlord in a written agreement executed by both parties.

  • Neither Landlord nor any Landlord Related Party shall be personally liable for any judgment or deficiency.

  • Xxxxxx agrees that in no case shall Landlord or any Landlord Related Party be responsible or liable on any theory for any injury to Xxxxxx’s business, loss of profits, loss of income or any other form of consequential damage.


More Definitions of Landlord Related Party

Landlord Related Party means an employee, agent, contractor, licensee, customer, invitee or affiliate of Landlord, but specifically excludes Tenant and any other lessee or tenant of tie Project. "Tenant-Related Party" means an employee, agent, contractor, licensee, customer, invitee or affiliate of Tenant but specifically excludes Landlord. (b) Landlord shall defend, indemnify, protect and hold Tenant harmless against Damages resulting from or arising out of the following Hazardous Materials Contamination or Environmental Conditions: (i) existing or occurring within the Premises on or before Tenant takes occupancy of the Premises or after the expiration or early termination of the Lease Term but only to the extent not caused by Tenant or a Tenant-Related Party; or (ii) existing or occurring within the Premises or any other portion of the Project and caused by Landlord or a Landlord-Related Party. (c) Tenant shall defend, indemnify, protect and hold Landlord harmless against all Damages resulting from or arising out of Hazardous Materials Contamination or Environmental Conditions existing or occurring within the Premises or any other portion of the Project and caused by Tenant or a Tenant-Related Party, but only to the extent not caused by Landlord or a Landlord-Related Party. (d) The Tenant shall store and handle Hazardous Materials at the Premises or at the Project in strict compliance with applicable laws, rules and regulations, and shall indemnify, defend and save harmless the Landlord from all Damages arising out of or in any way connected with Tenant or Tenant-Related Party's storage or handling of Hazardous Materials. In no event shall Tenant's handling or storage of Hazardous Materials in compliance with applicable laws make Tenant liable for Hazardous Materials Contamination or Environmental Conditions in existence or occurring on or before Tenant takes occupancy of the Premises. (e) The obligations and liabilities of both parties under this Section 21 ---------- shall survive the Term of this Lease. (f) The failure by either party to abide by the terms of this Section 21 ---------- shall be restrainable by injunction. 22.
Sample 1
Landlord Related Party means a person or entity (a) in which Landlord directly or indirectly owns a material interest, (b) which directly or indirectly owns a material interest in Landlord, (c) in which a material interest is directly or indirectly owned by another person or entity which also directly or indirectly owns a material interest in Landlord, (d) which directly or indirectly owns a material interest in another entity which also directly or indirectly owns a material interest in Landlord, (e) who is related to any person which directly or indirectly owns a material interest in Landlord as such person's parent, guardian, grandparent, father-in-law, mother-in-law, spouse, fiance, child, xxxx, grandchild, sibling, brother-in-law, sister-in-law, uncle, aunt, great uncle, great aunt, niece, nephew, grandnephew, grandniece, cousin or similar family or legal relation or (f) in which any such relation directly or indirectly owns a material interest. Without limiting the foregoing, the Parties acknowledge that Waterford Development Corp., a Massachusetts corporation, is a Landlord Related Party with respect to the Landlord named in the preamble of this Lease.
Sample 1

Related to Landlord Related Party

  • Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Seller Related Party means the Company and each of its Affiliates and its and their respective stockholders, partners, members, officers, directors, employees, controlling persons, agents and representatives.

  • Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.

  • Tenant Party means any of the following persons: Tenant; any assignees claiming by, through, or under Tenant; any subtenants claiming by, through, or under Tenant; and any of their respective agents, contractors, employees, licensees, guests and invitees.

  • Company Related Party means the Company, its Subsidiaries and its affiliates and its and their respective affiliates’ stockholders, partners, members, officers, directors, employees, controlling persons, agents and representatives.

  • Contractor Related Parties means any affliates of the Contractor and the Contractor's executive officers, Pennsylvania officers and directors, or owners of 5 percent or more interest in the Contractor.

  • Seller Related Parties means Seller, RAR, ROP, the Applicable Parties, any Affiliate of Seller and their respective direct or indirect members, partners, stockholders, officers, directors, employees and agents.

  • Landlord Lien State means such state(s) in which a landlord’s claim for rent may have priority over the Lien of the Agent in any of the Collateral.

  • Rule 506(d) Related Party means, with respect to any Person, any other Person that is a beneficial owner of such first Person’s securities for purposes of Rule 506(d) under the Securities Act.

  • Tenant Parties means Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Anchor Tenant means the primary customer occupying a site.

  • Regulated party means a person who, pursuant to section 95484(a), must meet the average carbon intensity requirements in section 95482 or 95483.

  • Landlord Reserve means, as to each location at which a Borrower has Inventory or books and records located and as to which a Collateral Access Agreement has not been received by Agent, a reserve in an amount equal to the greater of (a) the number of months' rent for which the landlord will have, under applicable law, a Lien in the Inventory of such Borrower to secure the payment of rent or other amounts under the lease relative to such location, or (b) 3 months' rent under the lease relative to such location.

  • Lender-Related Person means, with respect to any Lender, such Lender, together with such Lender’s Affiliates, officers, directors, employees, attorneys, and agents.

  • Flood-related erosion area management means the operation of an overall program of corrective and preventive measures for reducing flood-related erosion damage, including but not limited to emergency preparedness plans, flood-related erosion control works and floodplain management regulations.

  • Exculpated Party means the Debtors, the Reorganized Debtors, each of the Debtors’ and the Reorganized Debtors’ current and former Affiliates, and each of the Debtors’ and the Reorganized Debtors’ and their current and former Affiliates’ current and former directors, managers, officers, managed accounts and funds, predecessors, successors, and assigns, subsidiaries, and each of their respective current and former officers, directors, managers, principals, members, employees, subcontractors, agents, advisory board members, financial advisors, partners, attorneys, accountants, investment bankers, consultants, representatives, management companies, fund advisors, and other professionals, each solely in their capacity as such.

  • Landlord means the owner, lessor or sublessor of the dwelling unit or the building of which such

  • Company Related Parties means, collectively, (i) the Company and its Subsidiaries; and (ii) the former, current and future holders of any equity, controlling persons, Representatives, Affiliates, members, managers, general or limited partners, stockholders and assignees of each of the Company, its Subsidiaries and each of their respective Affiliates.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Major Tenant means a tenant of a Loan Party under a lease of Property which entitles it to occupy 15,000 square feet or more of the net rentable area of such Property.

  • Landlord Liens means liens on or against the Leased Property or any payment of Rent (a) which result from any act of, or any claim against, Landlord or any owner (other than Tenant) of a direct or indirect interest in the Leased Property, or which result from any violation by Landlord of any terms of this Agreement or the Purchase Agreement, or (b) which result from liens in favor of any taxing authority by reason of any tax owed by Landlord or any fee owner of a direct or indirect interest in the Leased Property; provided, however, that "Landlord Lien" shall not include any lien resulting from any tax for which Tenant is obligated to pay or indemnify Landlord against until such time as Tenant shall have already paid to or on behalf of Landlord the tax or the required indemnity with respect to the same.

  • Major Tenants has the meaning ascribed to such term in Section 7.2.

  • Tenant means any Person leasing, subleasing or otherwise occupying any portion of the Property under a Lease or other occupancy agreement.

  • Landlord Default shall have the meaning given such term in Article 14.

  • Designated Party means any person listed:

  • Purchaser Related Parties has the meaning specified in Section 6.1.