Key Individuals definition

Key Individuals means the Service Provider Representatives identified as being key individuals for the provision of the Services as set out in Schedule 5.5.

Split View

AI-Powered Contracts

Draft, Review & Redline at the Speed of AI

Get StartedSchedule a Demo

Key Individuals means (i) an individual or entity owning 10% or more equity stake in the organization, whether publically- or privately-held: (ii) principal officers of the organization's governing body (e.g., chairman, vice chairman, treasurer or secretary of the board of directors or board of trustees): (iii) the principal officer and deputy principal officer of the organization (e.g., executive director, deputy director; president, vice president); (iv) the program manager or chief of party for the USAID-financed program: and (v) any other person with significant responsibilities for administration of USAID financed activities or resources.

Key Individuals of a Respondent Team means the specific individuals, exclusive to the Respondent, filling the following roles (or equivalent), as described in the Respondent’s Response and as may be changed pursuant to this RFQ:

Examples of Key Individuals in a sentence

• Project Co shall not replace any of the individuals identified in Schedule 9 – Key Individuals without the prior written consent of Contracting Authority, which consent shall not be withheld or delayed where the proposed replacement is suitably qualified and experienced and of equal or better quality and experience than the individual being replaced.

• Project Co shall use commercially reasonable efforts to ensure that such persons remain involved in the Works in the capacity set out in Schedule 9 – Key Individuals and, in particular, will not, for the duration of the Works, require or request any such person to be involved in any other project on behalf of Project Co or any Project Co Party if, in the opinion of Contracting Authority, acting reasonably, such involvement would have a material adverse effect on the Works.

• The Key Individuals must not be released from providing the Services without the approval of the Purchaser (including when carrying out the Exit Management Services), except by reason of long-term sickness, maternity, paternity, adoption or parental leave, termination of employment or equivalent extenuating circumstances.

• Key Individuals The Service Provider acknowledges that the Key Individuals are essential to the proper provision of the Services to the Purchaser.

• A change in the ownership of Manager shall not constitute an assignment, provided that the Key Individuals (as defined in the Operating Agreement), or any of them, remain in control of the day to day operations of Manager with respect to the Project.

More Definitions of Key Individuals

Key Individuals means an individual who will play an important role in the engagement or contract on behalf of a Team Member resulting from this RFP.

Key Individuals of a Proponent means the specific individuals, exclusive to the Proponent, filling the following roles (or equivalent), as identified in the Proponent’s RFQ Response and as may have been changed pursuant to the RFQ or as may be changed pursuant to this RFP.

Key Individuals means ▇▇▇▇ ▇▇▇▇▇▇▇▇, ▇▇▇▇ ▇▇▇▇▇▇▇▇▇▇ and ▇▇▇▇▇▇▇ ▇▇▇▇.

Key Individuals of a Proponent means the specific individuals, exclusive to the Proponent, filling the following roles (or equivalent), as identified in:

Key Individuals of a Proponent means the specific individuals, exclusive to the Proponent, filling the following roles (or equivalent) in the Proponent’s Proposal. Key Individuals may fill multiple roles provided they have the qualifications and experience for all the roles. A Key Individual role may only be filled by one individual:

Key Individuals means the Service Provider Representatives identified as being key individuals for the provision of the Services as set out in Schedule 5.

Key Individuals means the persons identified in Schedule 5 – Key Individuals;