Interim Completion definition

Interim Completion means the achievement of the requirements for Substantial Completion for a particular Conservation Measure prior to the Substantial Completion Date.
Interim Completion means, in relation to any Interim Completion Element, the satisfaction of all the Interim Completion Conditions for such Interim Completion Element.
Interim Completion means the achievement of the requirements for Substantial Completion for a particular ECM prior to the Substantial Completion Date.

Examples of Interim Completion in a sentence

  • Complete all work required for Interim Completion for ____________ in _______ days.

  • Complete all work required for Interim Completion for ____________ on or before __________.

  • Complete all work required for Interim Completion for ____________ in _______ working days.

  • For each day that the Contractor fails to complete the work as specified in Subsection 108.10 of these Special Provisions, for Interim Completion, the Department will assess liquidated damages in the amount of $______.

  • All time limits for Interim Completion, Milestones, Substantial Completion, and Final Completion as stated in the Contract Documents are of the essence of the Contract.

  • Once work begins, status the schedule with the actual date recorded in SiteManager.• Interim Completion Dates or Interim Milestones: When interim completion dates or interim milestones (associated with project stages) are included in the contract specifications.• Mobilization: Preparations for and moving of equipment, etc., to the project site.• Start of Paving: Date paving production and placement is to start.

  • Complete all work required for Interim Completion for ____________on or before __________.

  • The Interim Completion Milestone Date may not be changed without written approval by the Department’s Project Manager.

  • The Interim Completion Milestone Date will be the date determined by adding the number of calendar days proposed by the Design-Builder on Form SCD (the Duration), to the date of the Notice to Proceed as issued by the Department.

  • Key milestone dates specified in the Contract including but not limited to; Notice to Proceed, Interim Completion, Permit Restriction Dates, and Contract Completion Date.


More Definitions of Interim Completion

Interim Completion means that (i) Mechanical Completion of the Facility has occurred; (ii) the Facility is Ready for Start-Up; (iii) the Facility has achieved, during a minimum continuous production period of 72 hours, on average, not less than 75 percent of the Ethanol Production Rate Guarantee, as set forth in Section 11.04, 11.09 and in the Scope of Work and (iv) the Facility is capable to operate continuously, normally and safely, in accordance with the requirements hereunder.
Interim Completion means that (i) Mechanical Completion of the Ethanol Plant has occurred; (ii) the Ethanol Plant is Ready for Start-Up; (iii) the Ethanol Plant has achieved, during a minimum continuous production period of 72 hours, on average, not less than 75 percent of the Ethanol Production Rate Guarantee, as set forth in Section 11.04, 11.09 and in the Scope of Work and (iv) the Ethanol Plant is capable to operate continuously, normally and safely, in accordance with the requirements hereunder.

Related to Interim Completion

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Practical Completion means that stage in the execution of a Named Project when the Works have been completed in accordance with the terms of the relevant Building Contract and/or the terms of this Agreement such that the AHP Dwellings comprised within the Named Project are fit for beneficial occupation as a residential development in accordance with applicable NHBC or equivalent requirements current at the date of inspection subject only to the existence of minor defects and/or minor omissions at the time of inspection which are capable of being made good or carried out without materially interfering with the beneficial use and enjoyment of the Named Project and which would be reasonable to include in a snagging list, and Practically Complete shall be construed accordingly; Process has the meaning ascribed to it in the DPA; Procurement Law means (as the case may be):

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Contract Start Date means the date specified in your Contract for Signature asthe date this Contract starts;

  • Test on Completion means such tests as prescribed in the Contract to be performed by the Contractor before the work is Taken Over by TSECL.