Interim Claim definition

Interim Claim has the meaning set forth in Section 4.2.( c).
View Source

Examples of Interim Claim in a sentence

  • Interim Waiver and Release of Liens and Interim Claim Waivers, however, shall not be required from Major Subcontractors or Major Sub-subcontractors until they have performed Work, and Major Subcontractors and Major Sub-subcontractors shall be required to submit additional Interim Waiver and Release of Liens and Interim Claim Waivers only if they have performed Work not covered by a previous Interim Waiver and Release of Liens and Interim Claim Waiver.

  • Submission of all Interim Waiver and Release of Liens and Interim Claim Waivers in accordance with this Section 7.2C is a condition precedent to payment of any Invoice.

  • The Claimant will fill out a Claim Form for an Interim Claim or a Final Claim.

  • An Interim Claim for the third quarterly period may be submitted up to and including June 30.

  • After an Interim Claim or a Final Claim is presented, the GCCF shall determine within 90 days whether to make a payment to the Claimant and if so the amount of such payment.

  • An Interim Claim for the first quarterly period may be submitted up to and including December 31.

  • An Interim Claim for the second quarterly period may be submitted up to and including March 31.

  • No later than fourteen (14) Days after Owner’s acceptance of the Substantial Completion Certificate, and if Contractor has (1) paid all Substantial Completion Delay Liquidated Damages due and owing under the Agreement (2) provided the Interim Waivers and Release of Liens and Interim Claim Waivers as set forth in the foregoing sentence, Owner shall provide the commercial bank that issued the Contractor Letter of Credit with written notice of such acceptance.

  • Payment application and issuance of Architect’s certificate 30.1 The Contractor shall submit a payment application at the Interim Claim Interval stated in the Appendix with complete details and particulars as required by the Architect and Quantity Surveyor, to enable them to consider and ascertain the amount to be included in an Interim Certificate.

  • Interim Claim Interval [if none stated is one (1) Month] 30.1 and 30.13 …………………………………………....