HINDRANCE definition

HINDRANCE means an event resulting in stoppage or delay of work because of the purchaser as recorded by the contractor and authenticated by the purchaser.
Sample 1Sample 2Sample 3
HINDRANCE means any real or apprehended hindrance, risk, delay, difficulty, or disadvantage of whatsoever kind to the Carriage, the Carrier, Sub-Contractor(s), the Vessel, or the Goods or any property including without limitation the existence or apprehension of (i) act of God; (ii) war, hostilities, civil commotions, acts of public enemies, or terrorism; (iii) governmental restraints on commerce, shipping, or trading (including voluntary import or export quotas arising from the threat of governmental restraints); (iv) quarantine, sanitary or other similar regulations or restrictions; (v) epidemics or diseases; (vi) work stoppages, strikes, or lockouts, whether or not conducted by employees of the Carrier or Sub-Contractor(s); (vii) accidents, casualties, fire, or transportation disasters; (viii) congestion of, closure of, obstacle in or danger to any canal, strait, waterway, port, wharf, sea terminal, or any other place; (ix) bad weather, shallow water, ice, earthquake, landslip or other obstacles in the Carriage; (x) suspension or denial of the Container or the Goods to load onto the Vessel by the master of the Vessel or his representative and the terminal representative arising out of failure of the Merchant to comply with all laws, statutes, or regulations applicable to this Bill, such as the Shipper's inaccurate verification of gross weight of the packed Container under the International Convention for the Safety of Life at Sea; (xi) any obstacle in the Carriage arising out of abandonment of the Carriage or withdrawal of Vessel by the Sub-Contractor(s), or arrest of, distress of, or seizure of the Vessel, or detention of or seizure of the Container; (xii) server outage, network breakdown, or software system down or destruction at the Carrier or Sub-Contractor resulting from cyberattack, cyberterrorism or any other unlawful offensive maneuver by a third party;
Sample 1Sample 2Sample 3
HINDRANCE means any real or apprehended hindrance, risk, delay, difficulty or disadvantage of whatsoever kind to the Carriage, the Carrier, Sub- Contractor(s), the Vessel, or the Goods or any property including without limitation the existence or apprehension of (i) acts of God; (ii) war, hostilities, civil commotions, acts of public enemies, or terrorism; (iii) governmental restraints on commerce, shipping or trading (including voluntary import or export quotas arising from the threat of governmental restraints); (iv) quarantine, sanitary or other similar regulations or restrictions; (v) epidemics or diseases; (vi) work stoppages, strikes, or lockouts, whether or not conducted by employees of the Carrier or Sub-Contractor(s); (vii) accidents, casualties, fire, or transportation disasters; (viii) congestion of, closure of, obstacle in or danger to any canal, strait, waterway, port, wharf, sea terminal, or any other place; or (ix) bad weather, shallow water, ice, earthquake, landslip or other obstacles in the Carriage;
Sample 1Sample 2

Examples of HINDRANCE in a sentence

  • Any other causes which, at the sole discretion of the company, is beyond the control of the contractor.6.4.1 A HINDRANCE REGISTER shall be maintained by both department and the contractor at site to record the various hindrances, as stated above, encountered during the course of execution.

  • Any other causes which, at the sole discretion of the company, is beyond the control of the contractor.6.4.1 A HINDRANCE REGISTER shall be maintained by both department and the contractor at site to record the various hindrances, as stated above, encountered during the course of execution.Hindrance register will be signed by both the parties.

  • Sl.No.ANNEXURE-IVPROFORMA FOR HINDRANCE REGISTERReference Clause No. 18.5 Sl.No.Nature of hindrance To, The Chairman, IWAI……………………..……………………..

  • Sl.No. Annexure-5 PROFORMA FOR HINDRANCE REGISTER(Reference Clause No. 18.5) Sl. NoAnnexure-6 To, The Chairman, IWAI……………………..……………………..Notice for appointment of Arbitrator (Refer Clause 47)Dear Sir,In terms of Clause 47 of the Agreement, particulars of which are given below, I/we hereby give notice to you to appoint an arbitrator for settlement of disputed mentioned below: 1.

  • PROFORMA OF HINDRANCE REGISTER Name of Work : Date of state of work: Name of Contractor : Period of completion: Agreement No. : Date of completion: Sr. no.Nature of hindranceDate ofoccurrence of hindranceDate of which hindrance was removedperiod of hindranceSignature SE/PERemarks1 2 3 4 5 6 7 SE = Site Engineer PE = Project Engineer38.

  • Any other causes which, at the sole discretion of the company, is beyond the control of the contractor.-19- 6.4.1 A HINDRANCE REGISTER shall be maintained by both department and the contractor at site to record the various hindrances, as stated above, encountered during the course of execution.Hindrance register will be signed by both the parties.

  • NOTWITHSTANDING THE EXISTENCE OR ANY DISPUTE OR DIFFERENCES AND/OR REFERENCE FOR THE ARBITRATION, THE PARTIES SHALL PROCEED WITH AND CONTINUE WITHOUT HINDRANCE THE PERFORMANCE OF ITS OBLIGATIONS UNDER THIS CONTRACT WITH DUE DILIGENCE AND EFFICIENCY IN A PROFESSIONAL MANNER EXCEPT WHERE THE CONTRACT HAS BEEN TERMINATED BY EITHER PARTY IN TERMS OF THIS CONTRACT.

  • A HINDRANCE REGISTER shall be maintained by both department and the contractor at site to record the various hindrances, as stated above, encountered during the course of execution.

  • Remarks of inspecting Officer/Site Engineer(Bank):Site Engineer (Architect) Site Engineer (Contractor)TABLE-I PROFORMA FOR HINDRANCE TO WORK Name of Work : Date of Start of work : Name of Contractor: Period of Completion : Agreement No. :Dt. of Completion of work: TABLE-II PROFORMA FOR RUNNING A/C BILL i.

  • NEITHER PARTY SHALL BE LIABLE TO THE OTHER FOR FAILURE TO PERFORM ANY OF ITS OBLIGATIONS UNDER THIS CONTRACT (EXCEPT IN RELATION TO OBLIGATIONS TO MAKE PAYMENTS DUE UNDER THIS CONTRACT) TO THE EXTENT THAT PERFORMANCE OF ANY OF ITS OBLIGATIONS IS HINDERED, DELAYED OR PREVENTED DUE TO ANY FORCE MAJEURE EVENT (AS DEFINED BELOW).THE TIME FOR PERFORMANCE OF THE AFFECTED OBLIGATION SHALL BE EXTENDED IN ACCORDANCE WITH THE PERIOD OF HINDRANCE, DELAY OR PREVENTION SO CAUSED.


More Definitions of HINDRANCE

HINDRANCE. “impairment” and “reduction”. Are all those words absolute so that even de minimis 15 xxxxx, hindrances, etc are caught or is there not a, so to speak, qualitative element in those terms as
Sample 1

Related to HINDRANCE

  • Undue influence means exploiting a position of power in relation to the consumer so as to apply pressure, even without using or threatening to use physical force, in a way which significantly limits the consumer's ability to make an informed decision;

  • Interference means a discharge which, alone or in conjunction with a discharge or discharges from other sources, both: 1) inhibits or disrupts the POTW, its treatment processes or operations, or its sludge processes, use or disposal; and (2) therefore, is a cause of a violation of any requirement of the POTW's NPDES permit (including an increase in the magnitude or duration of a violation) or of the prevention of sewage sludge use or disposal in compliance with the following statutory provisions and regulations or permits issued thereunder (or more stringent local regulations): Section 405 of the Clean Water Act, the Solid Waste Disposal Act (SWDA) (including Title II, more commonly referred to as the Resource Conservation and Recovery Act (RCRA), and including state regulations contained in any state sludge management plan prepared pursuant to Subtitle D of SWDA), the Clean Air Act, and the Toxic Substances Control Act.

  • Disturbed area means an area where the ground cover is destroyed or removed leaving the land subject to accelerated erosion.

  • Prevention means measures taken before a substance, material or product has become waste, that reduce:

  • Smoke means the gases, particles, or vapors released into the air as a result of combustion, electrical ignition or vaporization, when the apparent or usual purpose of the combustion, electrical ignition or vaporization is human inhalation of the byproducts, except when the combusting or vaporizing of materials contains no tobacco or nicotine and the purpose of the inhalation is solely olfactory, such as, for example, smoke from incense. The term "smoke" includes, but is not limited to, tobacco smoke, electronic cigarette vapors, and cannabis smoke.

  • harmful interference means interference which endangers the functioning of a radio navigation service or of other safety services or which otherwise seriously degrades, obstructs or repeatedly interrupts a radio communications service operating in accordance with the applicable international, Union or national regulations;

  • Appropriation means an authorization granted by a legislative body to incur obligations and to expend public funds for a stated purpose.

  • Disturbance means the placement or reconstruction of impervious surface or motor vehicle surface, or exposure and/or movement of soil or bedrock or clearing, cutting, or removing of vegetation. Milling and repaving is not considered disturbance for the purposes of this definition.