Force Majeure means an event beyond the control of the supplier and not involving the supplier’s fault or negligence and not foreseeable. Such events may include, but is not restricted to, acts of the purchaser in its sovereign capacity, wars or revolutions, fires, floods, epidemics, quarantine restrictions and freight embargoes.
Force Majeure Event means an event, or a series of related events, that is outside the reasonable control of the party affected (including failures of the internet or any public telecommunications network, hacker attacks, denial of service attacks, virus or other malicious software attacks or infections, power failures, industrial disputes affecting any third party, changes to the law, disasters, explosions, fires, floods, riots, terrorist attacks and wars);
Force Majeure Period has the meaning specified in Section 13.1.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Force Majeure Events means acts of war, domestic and/or international terrorism, civil riots or rebellions, quarantines, embargoes and other similar unusual governmental actions, extraordinary elements of nature or acts of God.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Force Majeure Notice means a notice to be given by the Affected Party to the other party stating that a Force Majeure Event has occurred;
Force Majeure Failure has the meaning set forth in Section 8.1(d).
Relevant Force Majeure Event means a Force Majeure Event in relation to which an Affected Party is claiming relief under this Clause 17; and
Force Majeure Report means a report to be given by the Affected Party to the other party following the giving of a Force Majeure Notice;
Force Majeure Exception means any failure or delay in the performance of the Fund’s reporting obligation pursuant to Section 2.3 arising out of or caused, directly or indirectly, by circumstances beyond its reasonable control, including, without limitation, acts of God; earthquakes; flood; terrorism; wars and other military disturbances; sabotage; epidemics; riots; loss or malfunctions of utilities, computer (hardware or software) or communication services; accidents; acts of civil or military authority and governmental action. The Fund shall use commercially reasonable efforts to commence performance of its obligations during any of the foregoing circumstances.
Event of Force Majeure means one of the following events:
Unavoidable Delay means an event which delays Closing which is a strike, fire, explosion, flood, act of God, civil insurrection, act of war, act of terrorism or pandemic, plus any period of delay directly caused by the event, which are beyond the reasonable control of the Vendor and are not caused or contributed to by the fault of the Vendor. “Unavoidable Delay Period” means the number of days between the Purchaser’s receipt of written notice of the commencement of the Unavoidable Delay, as required by paragraph 5(b), and the date on which the Unavoidable Delay concludes.
Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,
Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.
Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:
Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.
Service Interruption means the cessation of electricity supply to an ICP for a period of 1 minute or longer, other than by reason of De-energisation of that ICP:
Unplanned Service Interruption means any Service Interruption where events or circumstances prevent the timely communication of prior warning or notice to the Trader or any affected Customer;
Outage has the meaning set forth in the CAISO Tariff.
Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:
Unavoidable means adverse impacts that remain after all appropriate and practicable avoidance and minimization have been achieved.
Planned Service Interruption means a Service Interruption that has been scheduled to occur in accordance with schedule 5;