Escalation Procedure definition

Escalation Procedure means the procedure set out in Section 14;

Escalation Procedure means the procedure for the escalation of disputes set out in Schedule 4;

Escalation Procedure means the procedure for the escalation of disputes set out in Schedule 4; Estimated Project Cost means the estimated costs of the Works as set out in paragraph 3 of Schedule 3 as updated from time to time in accordance with this Agreement;

Examples of Escalation Procedure in a sentence

• Accordingly, the parties agree, in relation to any matter of dispute between the parties in connection with this Agreement, that the parties will try to resolve the dispute through the Escalation Procedure.

• The Contractor shall provide a draft Problem Escalation Procedure (PEP) that includes, at a minimum, titles of individuals to be contacted by the Contract Monitor should problems arise under the Contract and explains how problems with work under the Contract will be escalated to resolve any issues promptly.

• If the Escalation Procedure fails, any dispute arising out of this Agreement, shall be referred to and finally resolved by arbitration under the Rules of the London Court of International Arbitration, which Rules are deemed to be incorporated by reference into this Clause.

• The Access Seeker may refer a Billing Dispute to the Billing Dispute Escalation Procedure under this Clause 12(e)(viii) by notifying the Access Provider’s Billing Representative.

• If the Operators are unable to resolve any Billing Dispute after exhausting the Billing Dispute Escalation Procedure, either Operator may refer the Billing Dispute to the Commission for resolution under Chapter 7 of Part V of the Act.

More Definitions of Escalation Procedure

Escalation Procedure has the meaning given to it in Clause 33.2;

Escalation Procedure means the steps taken by the parties in accordance with clause 10 and Appendix 3 should a complaint and/or dispute arise;

Escalation Procedure means the decision-making procedure described in Section 12 hereof, whereby the parties intend to avoid deadlocks between them and undue delays in reaching mutually acceptable Committee Action(s).

Escalation Procedure has the meaning ascribed thereto in Section 36.

Escalation Procedure means the procedure referred to in article 11.

Escalation Procedure means the decision making procedure described in Section 12, whereby the parties intend to avoid deadlocks between them and undue delays reaching mutually-acceptable Committee Action(s).

Escalation Procedure means the escalation process notifying the relevant CONTRACTOR and AUTHORITY representatives as set out in paragraph 4 of Schedule 2 (Services);