Energy Improvement Works definition

Energy Improvement Works means the energy improvement works relating to the (i) installation of Approved Equipment, and (ii) redesigning and conversion of air-conditioned spaces to naturally ventilated or mixed mode ventilated spaces at the Development, for the purpose of improving the energy performance of the Development;
Sample 1
Energy Improvement Works in relation to a Building shall mean energy improvement works involving the installation of Approved Equipment and aimed at improving the energy efficiency of the Building.
Sample 1
Energy Improvement Works in relation to the Premise shall mean energy improvement works involving the installation of Approved Equipment aimed at improving the energy efficiency of the said Premise.
Sample 1

Examples of Energy Improvement Works in a sentence

  • If the Applicant is unable to complete the Energy Improvement Works by the Expected Completion Date, the Applicant may send a written request at least 14 days prior to the Expected Completion Date setting out the reasons for his inability to complete the said works by the Expected Completion Date for BCA’s consideration.

  • Schedule or timelines including the dates for the start and completion for the whole Energy Improvement Works.

  • Id. generic company to challenge an overbroad patent description.115 Finally, Justice Kagan and the Court rejected the argument that Congress enacted the counterclaim only to solve problems similar to those in Mylan.116 Justice Kagan and the Court ultimately decided that Caraco was allowed to bring a counterclaim, which requested Novo to correct its use code on the ground that the patent did not claim an approved method of use for the drug.117 1.

  • Contract documents and such other documents including Letter of Award to the contractors and Purchase Orders showing the details and costs of each of the Energy Improvement Works, which shall inter alia, act to provide evidentiary proof and/or basis of the Estimated Qualifying Costs.

  • A table showing the detailed breakdown of each Energy Improvement Works and Approved Equipment, actual contract cost, consultancy services and fees.

  • Under the Climate Change (Scotland) Act 2009 and most recently The Assessment of Energy Performance of Non Domestic Buildings (Scotland) Regulations 2016, the Government intends to enforce Energy Improvement Works on occupiers as detailed within the Energy Performance Certificate and within a predetermined Compliance Period.

  • The Scheme is not applicable in relation to any Energy Improvement Works or any equipment which had already commenced or already been installed before the time of application for participation in this Scheme.

  • Where in the opinion of BCA any of the Energy Improvement Works have been removed, altered or obstructed, BCA shall be entitled to recover from the Applicant part or all the monies disbursed.

  • The license holders therefore, should check these details in their licenses and ensure that the same are corrected before presenting the license for registration.

  • In sum, a total of 826 applications were received including 44 energy conservation education projects, 50 Energy-cum-carbon Audits (ECA) and 732 Energy Improvement Works (EIW) projects.

Related to Energy Improvement Works

  • Needs Improvement the Educator’s performance on a standard or overall is below the requirements of a standard or overall, but is not considered to be unsatisfactory at this time. Improvement is necessary and expected.  Unsatisfactory: the Educator’s performance on a standard or overall has not significantly improved following a rating of needs improvement, or the Educator’s performance is consistently below the requirements of a standard or overall and is considered inadequate, or both.

  • Home improvement means the remodeling, altering,

  • Infrastructure improvement means permanent infrastructure that is essential for the public health and safety or that:

  • The Works/Project means the works to be executed or done under this contract.

  • Quality Improvement means a focus on activities to improve performance above minimum standards and reasonably expected levels of performance, quality and practice.

  • Licensee Improvements means any improvement, enhancement, modification, derivative work or upgrade to any of Licensor Patent Rights made, conceived, reduced to practice, affixed or otherwise developed by or on behalf of Licensee during the term of this Agreement and solely as exercised under the License.

  • Infrastructure Improvements means a street, road, sidewalk, parking facility, pedestrian mall, alley, bridge, sewer, sewage treatment plant, property designed to reduce, eliminate, or prevent the spread of identified soil or groundwater contamination, drainage system, waterway, waterline, water storage facility, rail line, utility line or pipeline, transit-oriented development, transit-oriented property, or other similar or related structure or improvement, together with necessary easements for the structure or improvement, owned or used by a public agency or functionally connected to similar or supporting property owned or used by a public agency, or designed and dedicated to use by, for the benefit of, or for the protection of the health, welfare, or safety of the public generally, whether or not used by a single business entity, provided that any road, street, or bridge shall be continuously open to public access and that other property shall be located in public easements or rights-of-way and sized to accommodate reasonably foreseeable development of eligible property in adjoining areas. Infrastructure improvements also include 1 or more of the following whether publicly or privately owned or operated or located on public or private property:

  • Energy efficiency improvement means equipment, devices, or materials intended to decrease energy consumption, including, but not limited to, all of the following:

  • Home improvement contractor or "contractor" means a person who sells goods and services, or agrees to furnish or render services, to a retail buyer pursuant to a home improvement installment contract, or sells goods and services to a retail buyer pursuant to a home improvement charge agreement, but not in connection with construction of new homes.

  • Improvement Plan means the plan required by the Authority from the Supplier which shall detail how the Supplier will improve the provision of the Goods and/or Services pursuant to Clause 29.1.1 (Authority Remedies);

  • Substantial improvement means any combination of repairs, reconstruction, rehabilitation, addition, or other improvement of a structure, taking place during any one-year period for which the cost equals or exceeds 50 percent of the market value of the structure before the “start of construction” of the improvement. This term includes structures which have incurred “substantial damage”, regardless of the actual repair work performed. The term does not, however, include either:

  • Project Improvements means site improvements and facilities that are:

  • Site Improvements means any construction work on, or improvement to, streets, roads, parking facilities, sidewalks, drainage structures and utilities.

  • The Works/ Project means the works to be executed or done under this contract.

  • Home improvement contract means an oral or written

  • Improvements means the buildings, structures, improvements, and alterations now constructed or at any time in the future constructed or placed upon the Land, including any future replacements and additions.

  • Installation Works means, as the context so requires,

  • Private Improvements means the improvements to be constructed on the Property that are not Public Improvements.

  • Maximum medical improvement means that no further material improvement would reasonably be expected from medical treatment or the passage of time;

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Sewage works means all facilities for collecting, pumping, treating, and disposing of sewage.

  • Work/ works means work / works to be executed in accordance with the contract.

  • Quality improvement organization or “QIO” shall mean the organization that performs medical peer review of Medicaid claims, including review of validity of hospital diagnosis and procedure coding information; completeness, adequacy and quality of care; appropriateness of admission, discharge and transfer; and appropriateness of prospective payment outlier cases. These activities undertaken by the QIO may be included in a contractual relationship with the Iowa Medicaid enterprise.

  • Minimum Improvements means the acquisition of land and construction of a 152-unit market rate residential apartment building, construction of a stormwater pond and related improvements. The Minimum Improvements are more fully depicted in Exhibit B, which is attached hereto and incorporated herein.

  • Joint Improvements has the meaning set forth in Section 7.1(d).

  • Construction Works means all works and things necessary to complete the Project Facilities in accordance with this Agreement;