DUCATI definition

DUCATI or “Client”: Ducati Motor Holding S.p.A. - Sole Shareholder Company, subject to the direction and coordination of AUDI AG - with registered office in Bologna, ▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ 3, VAT and Tax no. 05113870967; "Documentation": any and all technical and information documents and/or any other document necessary for the proper use of the Works and the Services as provided by the Contractor therewith (such as technical manuals); “Intellectual Property Rights”: any rights related to laboratory work and/or notes, patentable and non-patentable inventions, patents, database rights, computer programmes, project rights, rights on drawings and models, logos, domain names, copyrights, know¬how and information associated therewith, confidential information, and any other rights related to any industrial or intellectual property, whether registered or not, including all rights to claim such rights.
View Source
DUCATI means Ducati Motor Holding SpA - Sole Shareholder Company, subject to the direction and coordination of Audi AG - with registered office at via Cavalieri Ducati no. 3, 40132 - Bologna, Italy.
View Source

Examples of DUCATI in a sentence

  • These requirements define the expectations of DUCATI as to the approach and behaviour within business activities and many of them are contained in the Organisational and Management Model pursuant to Italian Legislative Decree no.

  • After the expiration of such term with no remedies adopted, the Contract shall be deemed as terminated and DUCATI shall be entitled to compensation for damages, which the Contractor shall pay within 60 (sixty) days of the receipt of the relevant debit note.

  • DUCATI complies and requires its trading partners, the Contractor included, to comply with some sustainability requirements.

  • The Contractor shall indemnify and hold DUCATI harmless against any such damages and claims.

  • The Contractor may also make use of temporary employees, in compliance with the provisions of the applicable law and subject to the prior written authorization of DUCATI.

  • However, DUCATI reserves the right to submit, at its discretion, the dispute to a competent court of the place where the Contractor has its domicile.

  • Should the subcontracting authorization be revoked for any reason whatsoever, DUCATI shall, in any case, be entitled to compensation for any damage against the Contractor and, if the case, to termination of the Contract.

  • The right of DUCATI to opt for one of two aforementioned remedies also applies in case of delays that are subject to no penalties under the Contract.

  • In the event of lexical ambiguities and/or gabs and/or contrasting terms, the document concerned shall be clarified and supplemented by taking the other texts into consideration according to the following order of prevalence: 1 Proposal; 2 Annexes; 3 General Terms and Conditions; 4 Contractor's technical documents as approved by DUCATI (if appropriate).

  • DUCATI reserves the right to verify the compliance with sustainability requirements by the Contractor, including through access at the production or commercial premises of the latter.

Related to DUCATI

  • Education means planned and organized activity by a consultant to impart information to employers and employees to enable them to establish and maintain employment and a place of employment that are safe and healthful.

  • Seaplane means a fixed wing aircraft which is designed for taking off and landing on water and includes amphibians operated as seaplanes;

  • Qard means a contract of lending money whereby the borrower is obliged to repay the equivalent amount to lender.

  • Dementia means an illness characterized by multiple cognitive deficits which represent a decline from previous levels of functioning and include memory impairment and one or more of the following cognitive disturbances: aphasia, apraxia, agnosia, and disturbance in executive functioning.

  • aeroplane means a power-driven heavier-than-air aircraft, deriving its lift in flight chiefly from aerodynamic reactions on surfaces which remain fixed under given conditions of flight;