Delay Events definition

Delay Events has the meaning given to it in Clause 12.2 (Time for Completion);
Sample 1Sample 2
Delay Events has the meaning given in Section 39.1(a) of the Project Agreement.
Sample 1
Delay Events has the meaning given in Section 25.1 (Delay Events);
Sample 1

Examples of Delay Events in a sentence

  • Furthermore, extension of time applications was made by EPB, notifying AZSB of the Delay Events.

  • Documents relating to events of Force Majeure, Delay Events and Relief Events and the consequences of the same.

  • The PSFA Amendment provides that if certain agreed milestones are not met in a timely manner (subject to extension for Delay Events as defined) then Oyu Tolgoi will be entitled to select from, and implement, the alternative power solutions specified in the PSFA (as amended), including an Oyu Tolgoi-led coal fired power plant and a primary renewables solution, and the Government of Mongolia would be obliged to support such decision.

  • In addition, prior to Project Completion, extensions of milestones and/or activities identified on the Baseline Schedule for Delay Events affecting the Work will be made based on Schedule Impact Analysis, using the then current Baseline Schedule and taking into account impacts of the Delay Events on Critical Path items, in accordance with the Technical Requirements, and will extend, as applicable, the Intermediate Milestone completion dates, the Project Completion Date and the Long Stop Date.

  • Representative shall, after receipt of written details under Clause 24.4 (Delay Events and Compensation Events), or of further particulars under Clause 24.5 (Delay Events and Compensation Events), be entitled by notice in writing to require D&B Co to provide such further supporting particulars as he may reasonably consider necessary.

  • For this reason, early-career women need to maintain some intellectual autonomy from their partners to be seen as independent scholars (Creamer, 2006; Wolf-Wendel et al., 2003).Fourthly, more women than men are primary caregivers of young children and researchers conclude that ‘babies matter’ to academic women’s promotion (Grummell et al., 2009).

  • Delay Events shall only apply to the particular element of the Work with respect to which it has occurred and shall not apply to any other aspect of the Work.

  • Representative shall, after receipt of written details under Clause 30.4 (Delay Events and Compensation Events ), or of further particulars under Clause 30.5 (Delay Events and Compensation Events ), be entitled by notice in writing to require Project Co to provide such further supporting particulars as he may reasonably consider necessary.

  • Delay Events are events typically outside of the Developer's control, the risk of which the Developer is (relative to the Department) best placed to manage.

  • It is extremely difficult to generalize about the extent to which unforeseen geotechnical risk, hazardous substance risk, utility risk and/or unanticipated discovery of endangered species should be treated as Compensation Events or Delay Events in Concession Agreements.


More Definitions of Delay Events

Delay Events means: (a) loss or damage by fire, explosion, earthquake, lightning, xxxxx, xxxxxxx, civil commotion of any kind and not caused by the Developer or the Developer's employees, servants, contractors or subcontractors; (b) industrial disputes, strikes or lockouts resulting from industry-wide third party disputes and not caused directly by the Developer; (c) unusual delays in obtaining approvals by any relevant Authority including any delay occasioned by any demanded resubmission of requests where consent has been refused ; (d) inclement weather; (e) any matter beyond the reasonable control of the Developer which results in a delay of the Works; (f) any prohibition or embargo imposed under or by virtue of any Law; (g) any delay in PTC giving its consent approval to or authorisation of any matter thing or action under this Agreement including any delay occasioned by demanded resubmission; (h) any interruption of access to the Site under CLAUSE 7.3; and (i) dispute resolution proceedings instigated by either party under CLAUSE 20
Sample 1
Delay Events means a delay caused by any of the matters referred to and as set out in Clause 18.1 (Delay Events);
Sample 1
Delay Events has the meaning given to it in Schedule 4;
Sample 1
Delay Events has the meaning given to it in Clause 12.2 (Time for Completion); "Design and Construction Specification" means the technical standards and design and construction specifications for the Toll Road as set out in Part 1 of Schedule 3, {that the Parties Comment [ID2]: This appears to conflict with the intent of the wording commented on at ID1-in one case the Core Requirements over-rule the Design and Construction Specification in the case of conflict and now the parties are agreeing that the Specification is in compliance with the Core Requirements. agree, as at the date hereof, satisfy the Core Requirements};
Sample 1

Related to Delay Events

  • Delay Event means any event set out at Clause 5.19.4 [Delay Events].

  • Termination Events means each of the events specified in Clause 10.3 of this Contract.

  • Company Event of Default bears the meaning ascribed thereto in Section 13.1; “Company Notice of Default” bears the meaning ascribed thereto in Section 13.2;

  • Triggering Events means Triggering Event I, Triggering Event II and Triggering Event III, collectively.

  • Extraordinary Events Any of the following conditions with respect to a Mortgaged Property (or, with respect to a Cooperative Loan, the Cooperative Apartment) or Mortgage Loan causing or resulting in a loss which causes the liquidation of such Mortgage Loan:

  • Liquidity Event of Default with respect to any Liquidity Facility, has the meaning assigned to such term in such Liquidity Facility.

  • Fall Away Event means such time as the Notes shall have an Investment Grade Rating and the Company shall have delivered to the Trustee an Officers’ Certificate certifying that the foregoing condition has been satisfied.

  • Events Each of the following events or conditions will constitute an Event of Default and a repudiation of this Agreement by Lessee (whether any such event or condition is voluntary or involuntary or occurs by operation of law or pursuant to or in compliance with any judgment, decree or order of any court or any order, rule or regulation of any Government Entity):-

  • Sequential Pay Event means any Event of Default with respect to an obligation to pay money due under the Mortgage Loan, any other Event of Default for which the Mortgage Loan is actually accelerated or any other Event of Default which causes the Mortgage Loan to become a Specially Serviced Mortgage Loan, or any bankruptcy or insolvency event that constitutes an Event of Default; provided, however, that unless the Servicer under the Servicing Agreement has notice or knowledge of such event at least ten (10) Business Days prior to the applicable distribution date, distributions will be made sequentially beginning on the subsequent distribution date; provided, further, that the aforementioned requirement of notice or knowledge will not apply in the case of distribution of the final proceeds of a liquidation or final disposition of the Mortgage Loan. A Sequential Pay Event shall no longer exist to the extent it has been cured (including any cure payment made by the Note B Holder (unless a Control Appraisal Period has occurred and is continuing) in accordance with Section 11) and shall not be deemed to exist to the extent the Note B Holder is exercising its cure rights under Section 11.

  • Occurrence means an accident, including continuous or repeated exposure to substantially the same general harmful conditions.

  • Financial Covenant Event of Default has the meaning specified in Section 8.01(b).

  • Warranty Event As to any Asset, the discovery that as of the related Cut-Off Date or Funding Date there had existed a breach of any representation or warranty relating to such Asset and the continuance of such breach through any applicable determination date or beyond any applicable cure period.

  • Severe Disruption Event means any event specified as such in the Final Terms.

  • PTC Event of Default means, with respect to each Trust Agreement, the failure to pay within 10 Business Days after the due date thereof: (i) the outstanding Pool Balance of the applicable Class of Certificates on the Final Legal Distribution Date for such Class or (ii) interest due on such Certificates on any Distribution Date (unless the Subordination Agent shall have made an Interest Drawing or a withdrawal from the Cash Collateral Account relating to a Liquidity Facility for such Class, with respect thereto in an aggregate amount sufficient to pay such interest and shall have distributed such amount to the Trustee entitled thereto).

  • Default Event means an event or circumstance which leads Operator to determine that a Venue User is or appears to be unable or likely to become unable to meet its obligations in respect of an Order or Transaction or to comply with any other obligation under an Agreement or Applicable Law.

  • Additional Disruption Event means any of Change in Law, Hedging Disruption and/or Increased Cost of Hedging.

  • Triggering Event of Default means (i) any Event of Default with respect to an obligation of the Mortgage Loan Borrower to pay money due under the Mortgage Loan or (ii) any non-monetary Event of Default as a result of which the Mortgage Loan becomes a Specially Serviced Mortgage Loan (which, for clarification, shall not include any imminent Event of Default (i.e., subclause (vii) of the definition of Special Servicing Loan Event)).

  • Non-Viability Event means the earlier of:

  • Material Events means any of the events listed in Section 3 of this Continuing Disclosure Undertaking.

  • Note Event of Default means any “Event of Default” specified in Section 5.1 of the Indenture.

  • Exclusion Event means an event or related events resulting in the exclusion of the Borrower or any Subsidiary from participation in any Medical Reimbursement Programs.

  • Specified Event of Default means any Event of Default pursuant to Section 9.01(a), Section 9.01(f) or Section 9.01(g).

  • Acceleration Event of Default means an Event of Default under Section 5.1(a), (d), (e) or (f), whatever the reason for such Acceleration Event of Default and whether it shall be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body.

  • Potential Event of Default means any event which, with the giving of notice or the lapse of time or both, would constitute an Event of Default.

  • Default under Specified Transaction provisions of Section 5(a)(v) will not apply to Party A and will not apply to Party B.

  • Regulatory Event means, following the occurrence of a Change in Law (as defined below) with respect to the Issuer and/or Société Générale as Guarantor or in any other capacity (including without limitation as hedging counterparty of the Issuer, market maker of the Certificates or direct or indirect shareholder or sponsor of the Issuer) or any of its affiliates involved in the issuer of the Certificates (hereafter the “Relevant Affiliates” and each of the Issuer, Société Générale and the Relevant Affiliates, a “Relevant Entity”) that, after the Certificates have been issued, (i) any Relevant Entity would incur a materially increased (as compared with circumstances existing prior to such event) amount of tax, duty, liability, penalty, expense, fee, cost or regulatory capital charge however defined or collateral requirements for performing its obligations under the Certificates or hedging the Issuer’s obligations under the Certificates, including, without limitation, due to clearing requirements of, or the absence of, clearing of the transactions entered into in connection with the issue of, or hedging the Issuer’sobligation under, the Certificates, (ii) it is or will become for any Relevant Entity impracticable, impossible (in each case, after using commercially reasonable efforts), unlawful, illegal or otherwise prohibited or contrary, in whole or in part, under any law, regulation, rule, judgement, order or directive of any governmental, administrative or judicial authority, or power, applicable to such Relevant Entity (a) to hold, acquire, issue, reissue, substitute, maintain, settle, or as the case may be, guarantee, the Certificates, (b) to acquire, hold, sponsor or dispose of any asset(s) (or any interest thereof) of any other transaction(s) such Relevant Entity may use in connection with the issue of the Certificates or to hedge the Issuer’s obligations under the Certificates, (c) to perform obligations in connection with, the Certificates or any contractual arrangement entered into between the Issuer and Société Générale or any Relevant Affiliate (including without limitation to hedge the Issuer’s obligations under the Certificates) or(d) to hold, acquire, maintain, increase, substitute or redeem all or a substantial part of its direct or indirect shareholding in the Issuer’s capital or the capital of any Relevant Affiliate or to directly or indirectly sponsor the Issuer or any Relevant Affiliate, or (iii) there is or may be a material adverse effect on a Relevant Entity in connection with the issue of the Certificates.