Default Management Process Completion Date means the date when the Default Management Process in relation to a Default has been completed as determined by the Clearing House in consultation with the DMG and notified to all Clearing Members.
Final Completion Date means the date on which Final Completion occurs.
Project Completion Date means the date on which the Completion Certificate is issued;
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Notice to Proceed (NTP) means the authorization issued by the CO to start performance on this Contract.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Completion Deadline means January 31, 2019, or such later date as may be agreed to in writing by the Parties;
Project Milestone means the project milestone set forth in Schedule-J;