Date of Acceptance of Tender definition

Date of Acceptance of Tender means the date which appears upon the notice in writing of acceptance of the Contractor's tender issued by the Principal or upon the acceptance in writing by either party of an offer (including a counter-offer) for the execution of the work under the Contract and the performance of the obligations of the Contractor under the Contract;
Sample 1Sample 2Sample 3
Date of Acceptance of Tender means the date of the signed Formal Instrument of Agreement.
Sample 1Sample 2Sample 3
Date of Acceptance of Tender means the date which appears on the notice in writing of acceptance of the tender;
Sample 1Sample 2

Examples of Date of Acceptance of Tender in a sentence

  • The Work is to be completed within the Period as indicated in aforesaid APPENDIX 'A' in accordance with the Phasing, if any, indicated in the Tender from the Date of Handing Over Site, which will be on or about TWO WEEKS after the Date of Acceptance of Tender.

  • Performance Bank GuaranteeThe Successful tenderer shall furnish valid Bank Guarantee Bond @ 5% of value of the Contract as Performance Security in favour of Deputy Director General, Unique Identification Authority of India, Mumbai within 7 days of the Date of Acceptance of Tender.

  • As at December 31, 2021, the following working capital balances denominated in US dollars were included in the accounts of GABY Inc.: Receivable (Payable) USDCAD equivalentOther current asset487,593617,098Accounts payable and accrued liabilities(317,225)(401,479)Short‐term notes payable(15,000)(18,984)Net exposure155,368196,635 In addition to the balances above, the Corporation has foreign exchange exposure with regards to long‐term debt totaling USD 26,201,900 (CAD 33,161,125).

  • If the Contract contains Separable Portions insert: Refer to Item 37 of this Annexure A.] Type here Where a period of time is provided, the commencement date shall be deemed to be the Date of Acceptance of Tender.

  • Practical Completion 2A The Date for Practical Completion Clauses 2.1, 35.2 [If there are no Separable Portions, insert a fixed date or a period of time from the Date of Acceptance of Tender.

  • Chair, Board of Environmental Protection c/o Board Clerk17 State House Station Augusta, ME 04333-0017 ruth.a.burke@maine.gov OCF/90-1/r95/r98/r99/r00/r04/r12/r18/r21 The DEP may also request the submittal of the original signed paper appeal documents when the appeal is filed electronically.

  • Performance Bank GuaranteeThe Successful tenderer shall furnish valid Bank Guarantee Bond @ 5% of value of the Contract as Performance Security in favour of Deputy Director General, Unique Identification Authority of India, Bangalore within 7 days of the Date of Acceptance of Tender.

  • Within fourteen (14) days of the Date of Acceptance of Tender, the Contractor shall submit one copy of the Contractor’s proposed indigenous development plan to the Superintendent for approval.

  • Site delay 42A The delay in giving possession of the Site which shall be a substantial breach Clause 44.7(b)(iv) 10% of the duration of the period from the Date of Acceptance of Tender to the Date for Practical Completion, following satisfactory provision of all requirements in Item 24B of this Annexure A.

  • Description of Separable Portion: Date for Practical Completion* (Clause 2.1): Liquidated Damages per Day (Clause 35.6): Defects Liability Period (Clause 37): *Where a period of time is provided in respect of the Date for Practical Completion, the commencement date shall be deemed to be the Date of Acceptance of Tender.


More Definitions of Date of Acceptance of Tender

Date of Acceptance of Tender means the date on which “Acceptance of Tender” is communicated to Bank of India either through fax / e-mail/ letter.
Sample 1Sample 2
Date of Acceptance of Tender means the date of acceptance in writing by one party of an offer by the other (including a counter-offer) for the execution of the Works and the performance of the Contract.
Sample 1
Date of Acceptance of Tender means the date, which appears upon the notice in writing of acceptance of the Contractor’s Tender, issued by LGL.
Sample 1
Date of Acceptance of Tender means the date which appears on the Principal’s written notice of acceptance of the Managing Contractor's Tender.
Sample 1
Date of Acceptance of Tender means the date which appears on any notice in writing of acceptance of the tender or relevant letter of acceptance.’
Sample 1
Date of Acceptance of Tender means the date which appears on the notice in writing of acceptance of the Contractor’s tender; ‘Day’ means calendar day;
Sample 1

Related to Date of Acceptance of Tender

  • Letter of Acceptance of Tender means letter giving intimation to the tenderer that his tender has been accepted in accordance with the provisions contained in that letter.

  • Acceptance of Tender means the letter or memorandum communicating to the supplier the acceptance of his offer (Tender) and shall include advance acceptance of his offer i.e. Letter of Intent or Rate Contract.

  • Date of Acceptance means the date, which appears on the Notice of Acceptance and if no date appears is the date on which the Principal sent the Notice of Acceptance accepting the Contractor’s Tender.

  • Notice of Tender means, in connection with an Optional Tender, a notice, substantially in the form attached to the Tender and Paying Agent Agreement, delivered by a Beneficial Owner or its Agent Member to the Tender and Paying Agent, indicating an intention to tender VRDP Shares for sale on a Purchase Date pursuant to Section 1 of Part II of this Statement.

  • Acceptance Date has the meaning set forth in Section 2.05(a)(v)(D)(2).

  • Notice of Acceptance means the written notification and any accompanying documentation sent to the Consultant by the Principal advising acceptance of its Tender to provide the Services under the Contract.

  • Acceptance Day shall have the meaning specified in paragraph 2B(5).

  • Certificate of Acceptance means written certification, delivered to Contractor and signed by an authorized representative of the State, stating that any Defects in a particular Phase or the Solution discovered after implementation and testing have been corrected as required under this Contract, and that the Phase complies in all material respects with all of the applicable Requirements.

  • Acceptance Condition means, with respect to an Offer, the condition set forth in the Offer Documents with respect to the number of acceptances to an Offer which must be secured to declare such Offer unconditional as to acceptances which shall be more than 50% of the Target shares carrying voting rights.

  • Letter of Acceptance (LOA means the written notice issued by JMRC to the selected bidder(s) intimating the acceptance of selected bidder's Proposal for the award of Lease;

  • Acceptance Letter means the letter from Adviser to BD pursuant to which the Adviser appoints BD as a Broker Dealer for each series of MuniPreferred issued by any Fund that has executed a Request Letter.

  • Acceptance of Bid means the letter/fax or any memorandum communicating to the Bidder the acceptance of its Bid and includes an advance acceptance of his Bid.

  • Confirmation of Acceptance shall have the meaning specified in paragraph 2B(5).

  • Final completion and acceptance means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

  • XXXX Acceptance Form means the “Acceptance Form for End User License Agreement (for SAP On Premise indirect sales)” which will be provided by SAP on a deal by deal basis.

  • Non-Extension Notice Date has the meaning specified in Section 2.03(b)(iii).

  • Final Acceptance Date means the date on which Final Acceptance occurs.

  • Form of Acceptance means the Form of formal acceptance, signed by the Procuring Entity, of the Form of Tender, including any annexed memoranda comprising agreements between and signed by both Parties. If there is no such Form of acceptance, the expression “Form of Acceptance” means the Contract Agreement and the date of issuing or receiving the Form of Acceptance means the date of signing the Contract Agreement.

  • Acceptance period, as used in this provision, means the number of calendar days available to the PHA/IHA for awarding a contract from the date specified in this solicitation for receipt of bids.

  • Non-Extension Notice has the meaning specified in Section 2.10.

  • Acceptance and Prepayment Notice means a notice of the Borrower’s acceptance of the Acceptable Discount in substantially the form of Exhibit M.

  • Acceptance Notice has the meaning set forth in Section 9.2(d)(iii).

  • Non-Acceptance of Proposal means another proposal was deemed more advantageous to the University or that all proposals were rejected.

  • Acceptance of offer means issue of letter of intent/award or memorandum or detailed Order/Contract communicating the acceptance of offer, to the successful Tenderer.

  • Acceptance Window shall have the meaning specified in paragraph 2B(5).

  • Letter of Acceptance means the letter of formal acceptance, signed by the contractor. Procuring Entity, including any annexed memoranda comprising agreements between and signed by both Parties.