Contractor Critical Path Items definition

Contractor Critical Path Items means those items that are designated as “Contractor Critical Path Items” in the Construction Schedule.
Sample 1Sample 2Sample 3

Examples of Contractor Critical Path Items in a sentence

  • The Contractor Critical Path Items set forth in the Construction Schedule shall be subject to Owner's approval, such approval not to be unreasonably withheld or delayed; provided, that Owner's comments on the Contractor Critical Path Items must be provided to Contractor within ten (10) Business Days of Owner's receipt of the Construction Schedule; provided, further, milestones consistent with Exhibit 4A and Exhibit 4B shall be deemed to be approved.

  • Within thirty (30) Days after the Effective Date, Contractor shall deliver to Owner the Construction Schedule, which shall (i) be a Xxxxx chart developed using Primavera, (ii) designate appropriate Contractor Critical Path Items utilizing the critical path method and (iii) be consistent with Exhibit 4 and inclusive of all Milestones set forth therein and shall provide necessary data about the timing for Owner decisions and all Owner milestones.

  • The Contractor Critical Path Items set forth *** CONFIDENTIAL MATERIAL REDACTED AND SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION.

Related to Contractor Critical Path Items

  • Contractor Project Manager means the employee identified in a Statement of Work as the Contractor project manager.

  • Contractor System means the information and communications technology system used by the Contractor in performing the Services including the Software, the Contractor Equipment and related cabling (but excluding the Authority System).

  • Contractor Software means software which is proprietary to the Contractor, including software which is or will be used by the Contractor for the purposes of providing the Services.

  • MSAA Indicator Technical Specifications document means, as the context requires, either or both of the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Indicator Technical Specifications November 5, 2018 Version 1.3” and the document entitled “Multi-Sector Service Accountability Agreement (MSAA) 2019-20 Target and Corridor-Setting Guidelines” as they may be amended or replaced from time to time;

  • Contractor/Supplier means the person or company whose tender is accepted by the Purchaser and shall be deemed to include the Contractor’s successors, heirs, executors, administrators, representatives and assigns approved by the Purchaser.

  • Contractor Personnel means Contractor’s employees and subcontractors (as well as any employees or subcontractors of those subcontractors) performing the Services.

  • Mobile crisis outreach team means a crisis intervention service for minors or families of minors experiencing behavioral health or psychiatric emergencies.

  • Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

  • Contractor information system means an information system belonging to, or operated by or for, the Contractor.

  • Clinical nurse specialist means a registered nurse with relevant post-basic qualifications and 12 months’ experience working in the clinical area of his/her specified post-basic qualification, or a minimum of four years’ post-basic registration experience, including three years’ experience in the relevant specialist field and who satisfies the local criteria.

  • Supplier’s Team means the Supplier and, where applicable, any Relevant Person, and all other employees, consultants, agents and sub-contractors which the Supplier engages in any way in relation to the supply of the Services or the Goods; and

  • Contractor Materials means Materials owned or developed prior to the provision of the Work, or developed by Contractor independently from the provision of the Work and without use of the Court Materials or Confidential Information.

  • Source-image receptor distance means the distance from the source to the center of the input surface of the image receptor.

  • The Works/Project means the works to be executed or done under this contract.

  • Project Implementation Manual or “PIM” means the manual setting out the measures required for the implementation of the Project, as the same may be amended from time to time, subject to prior approval of the Association;

  • Contractor Sensitive Information means any information provided by the Contractor to the Authority (disregarding any protective marking or assertion of confidentiality) which: is specified as Contractor Sensitive Information in Schedule 7 and has not lost its sensitivity according to the justifications and durations set out in that Schedule; and is exempt information pursuant to sections 33(1) or 36, 38 or 39 of FOISA (having regard for that purpose to the public interest there might be in disclosing such information as referred to in section 2(1)(b) of FOISA).

  • First-tier Subcontractor means any Subcontractor that has a contract with the General Contractor.

  • Category 4 Data is data that is confidential and requires special handling due to statutes or regulations that require especially strict protection of the data and from which especially serious consequences may arise in the event of any compromise of such data. Data classified as Category 4 includes but is not limited to data protected by: the Health Insurance Portability and Accountability Act (HIPAA), Pub. L. 104-191 as amended by the Health Information Technology for Economic and Clinical Health Act of 2009 (HITECH), 45 CFR Parts 160 and 164; the Family Educational Rights and Privacy Act (FERPA), 20 U.S.C. §1232g; 34 CFR Part 99; Internal Revenue Service Publication 1075 (xxxxx://xxx.xxx.xxx/pub/irs-pdf/p1075.pdf); Substance Abuse and Mental Health Services Administration regulations on Confidentiality of Alcohol and Drug Abuse Patient Records, 42 CFR Part 2; and/or Criminal Justice Information Services, 28 CFR Part 20.

  • Drug use test means a scientifically substantiated method to test for the presence of illegal or performance-enhancing drugs or the metabolites thereof in a person’s urine.

  • Clean coal technology demonstration project means a project using funds appropriated under the heading “Department of Energy—Clean Coal Technology,” up to a total amount of $2,500,000,000 for commercial demonstration of clean coal technology, or similar projects funded through appropriations for the Environmental Protection Agency. The federal contribution for a qualifying project shall be at least 20 percent of the total cost of the demonstration project.

  • Nuclear fuel cycle-related research and development activities means those activities which are specifically related to any process or system development aspect of any of the following: - conversion of nuclear material, - enrichment of nuclear material, - nuclear fuel fabrication, - reactors, - critical facilities, - reprocessing of nuclear fuel, - processing (not including repackaging or conditioning not involving the separation of elements, for storage or disposal) of intermediate or high-level waste containing plutonium, high enriched uranium or uranium-233, but do not include activities related to theoretical or basic scientific research or to research and development on industrial radioisotope applications, medical, hydrological and agricultural applications, health and environmental effects and improved maintenance.

  • Technical Specifications means the detailed requirements for the Work furnished by the Architect and set forth in Book 3 of the Contract Documents.

  • TDP means “TDP” as that term is defined in the Second Amended Joint Plan or as that term is defined in any Plan confirmed by the Bankruptcy Court.

  • Electronic Subcontracting Reporting System (eSRS) means the Governmentwide, electronic, web-based system for small business subcontracting program reporting. The eSRS is located at http://www.esrs.gov.

  • Contractor Group means Contractor, its parent and subsidiary companies as defined by the term “Affiliate,” and its and their respective Subcontractors and contractors of whatever tier and the officers, directors, employees, agents and representatives of all of the foregoing.

  • Contractor attributional/proprietary information means information that identifies the contractor(s), whether directly or indirectly, by the grouping of information that can be traced back to the contractor(s) (e.g., program description, facility locations), personally identifiable information, as well as trade secrets, commercial or financial information, or other commercially sensitive information that is not customarily shared outside of the company.