Construction Milestone Schedule definition

Construction Milestone Schedule means the schedule of significant development and construction milestones Made Available by the Project Company to each Investor, as amended from time to time by Approved Construction Changes, for the design, development, construction, and start up of the Project through “Final Construction Completion” under the Construction Documents and in accordance with the Construction Plans.
Construction Milestone Schedule means the schedule of Milestones and Milestone Dates by which such Milestones are to be achieved as set forth in Schedule 3.2(a) to the Facility Lease.
Construction Milestone Schedule means the milestone schedule, in a form reasonably acceptable to the Administrative Agent, attached as an exhibit to the Steex Xxxstruction Contract.

Examples of Construction Milestone Schedule in a sentence

  • This Trade Contractor agrees to estimate and perform the contract work necessary to achieve the completion dates as outlined in the Construction Milestone Schedule and Milestone Schedule Dates (as outlined in this proposal form):, including multiple mobilizations, overtime, multiple crews, supervision and multiple shifts.

  • CM/GC shall identify in the Construction Milestone Schedule when such licenses, permits, fees and inspections shall be necessary.

  • The Sponsor estimates in good faith that the Total Funding Available to the Project Company (i) will be sufficient to carry out the Project in accordance with the Construction Milestone Schedule, including adequate contingency funds for identified Cost Overruns and (ii) equals or exceeds Total Project Costs.

  • Borrower estimates in good faith that the Total Funding Available to each Project Company (i) will be sufficient to carry out each Project in accordance with the Construction Milestone Schedule, including adequate contingency funds for identified Cost Overruns and (ii) equals or exceeds Total Project Costs.

  • This Trade Contractor agrees to estimate and perform the contract work necessary to achieve the completion dates as outlined in the Construction Milestone Schedule Milestone Schedule Dates (as outlined in this proposal form):, including multiple mobilizations, overtime, multiple crews, supervision and multiple shifts..In general, the following clarifies the scope of work to be included.

  • The Construction Milestone Schedule is as follows: Exterior Enclosures & Waterproofing December: 2015 – 2Q2019 Mechanical, Electrical Plumbing: 2015 – 2Q2019 Interiors/Finishes: 2016 – 2Q2019Metal Panels & Ceilings: 2016 – 2Q2019 Systems & Commissioning: 2016 – 2Q2019 The CM/GC’s schedule shows remaining construction activities extending into the third quarter of 2019.

  • Construction Milestone Schedule is as follows as well as located in section 00230 of the Project Manual.

  • The parent’s selection of a provider and entering into care or continued attendance at a previously selected provider constitute acknowledgment of the notification of eligibility.

  • This Trade Contractor agrees to estimate and perform the contract work necessary to achieve the completion dates as outlined in the Construction Milestone Schedule Milestone Schedule Dates (as outlined in this proposal form):, including multiple mobilizations, overtime, multiple crews, supervision and multiple shifts.

  • This plan shall address procedures and programs to be carried out during ALL phases of construction beginning on day one and continued through the punch list and final completion phases of Work including initial occupancy as required and anticipated in the Construction Milestone Schedule.

Related to Construction Milestone Schedule

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Work Schedule means the approved order and timeline for how the requirements of this contract, including Work on individual Units or groups of Units, will be fulfilled by the Contractor.

  • Baseline Schedule means the initial time schedule prepared by Contractor for Owner’s information and acceptance that conveys Contractor’s and Subcontractors’ activities (including coordination and review activities required in the Contract Documents to be performed by A/E and ODR), durations, and sequence of work related to the entire Project to the extent required by the Contract Documents. The schedule clearly demonstrates the critical path of activities, durations and necessary predecessor conditions that drive the end date of the schedule. The Baseline Schedule shall not exceed the time limit current under the Contract Documents.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • The Project Plan means the document to be developed by the Supplier and approved by the Purchaser, pursuant to GCC Clause 19, based on the requirements of the Contract and the Preliminary Project Plan included in the Supplier’s bid. The “Agreed and Finalized Project Plan” is the version of the Project Plan approved by the Purchaser, in accordance with GCC Clause 19.2. Should the Project Plan conflict with the Contract in any way, the relevant provisions of the Contract, including any amendments, shall prevail.

  • Project Scope means the description or activity of work to be accomplished on the project.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.

  • Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Implementation Unit or “PIU” means the unit referred to in Section I.A.1(b) of Schedule 2 to this Agreement.

  • Subproject Agreement means any of the agreements referred to in Section 3.07 of this Agreement; and

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Project Implementation Manual or “PIM” means the manual setting out the measures required for the implementation of the Project, as the same may be amended from time to time, subject to prior approval of the Association;

  • Project Deliverables means the Project deliverables set out in Schedule 2. Project Material means all the material including but not limited to documents, computer software, and data stored by any means which is created by the Fellow in the course of undertaking the Project.

  • Subprojects means more than one such Subproject.