Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Allowed Delay has the meaning set forth in Section 2(c)(ii).
Constructive Termination means:
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.
Effective Termination Date has the meaning set forth in Section 10(b) hereof.
Disability Date means the date on which a Participant is deemed disabled under the employee benefit plans of the Corporation applicable to the Participant.
Constructive Termination Without Cause means the termination of the Executive’s employment at his initiative after, without the Executive’s prior written consent, one or more of the following events:
Stated Termination Date means December 31, 2000.
Due Cause means any of the following events:
Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,
Delivery Period Termination Date Has the meaning specified in the Related Pass Through Trust Supplement.
Delay Period shall have the meaning set forth in Section 5 hereof.
Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.
Delay Event means any event set out at Clause 5.19.4 [Delay Events].
Terminating Event means any of the following events:
Extended Termination Date has the meaning specified in Section 2.16(c).
Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.
Termination for Good Reason means a Termination of Employment by Executive for a Good Reason.
Supply Failure shall have the meaning ascribed to it in Section 2.8.
SOFR Index Cessation Effective Date means, in relation to a SOFR Index Cessation Event, the date on which the Federal Reserve Bank of New York (or any successor administrator of the daily Secured Overnight Financing Rate) ceases to publish the daily Secured Overnight Financing Rate, or the date as of which the daily Secured Overnight Financing Rate may no longer be used;
€STR Index Cessation Effective Date means, in respect of an €STR Index Cessation Event, the first date on which €STR is no longer provided by the European Central Bank (or any successor administrator of €STR), as determined by the Issuer and notified by the Issuer to the Calculation Agent;
Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:
Voluntary Termination for Good Reason means that the Executive voluntarily terminates his employment after any of the following are undertaken without Executive’s express written consent:
OBFR Index Cessation Effective Date means, in relation to an OBFR Index Cessation Event, the date on which the Federal Reserve Bank of New York (or any successor administrator of the daily Overnight Bank Funding Rate) ceases to publish the daily Overnight Bank Funding Rate or the date as of which the daily Overnight Bank Funding Rate may no longer be used;