Certification of Contract Completion definition

Certification of Contract Completion means a form used to document that a Contractor’s Work is complete, and the Contractor has complied with all conditions precedent to final payment and release of retainage. This form may also be used to document partial completion.
Sample 1Sample 2Sample 3

Examples of Certification of Contract Completion in a sentence

  • The policy shall specifically permit and allow for partial occupancy by the owner prior to execution of the final Certification of Contract Completion, and coverage shall remain in effect until all punch list items are completed.

  • Before the City commences Partial Occupancy, the A/E shall process a Certification of Contract Completion for the designated area listing incomplete or Defective Work under the Contract for approval of the City.

  • The policy shall specifically permit and allow for partial occupancy by the owner prior To execution of the final Certification of Contract Completion, and coverage shall remain in effect until all punch list items are completed.

  • The policy shall specifically permit and allow for partial occupancy by the owner prior to the execution of the final Certification of Contract Completion, and coverage shall remain in effect until all punch list items are completed.

  • The Vendor shall submit a Certification of Contract Completion with the final invoice (see Attachment “G”).

  • Prepare the final Project Completion Report (PCR), including Historically Underutilized Business (HUB) Report and Certification of Contract Completion.

  • The Vendor shall submit a Certification of Contract Completion (Attachment “C”) with the final invoice.

  • According to Fred Rogers of OHGR, the Certification of Contract Completion indicates that all contract work, change order work, training, and all outstanding cost issues have been reconciled with the prime contractor for the particular project.

  • Vote: Unanimous01-1153A resolution was adopted to approve Certification of Contract Completion for the General Trades of the Prime Contractors of the New Administration Building Project and Authorize the President of Board to sign same.

  • The aim will be to have a well defined and distinctive place that respects the values of the community and a place where people will want to work, live and play and a place where people can meet.

Related to Certification of Contract Completion

  • Certification period means the period for which an individual is certified eligible for a program.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Delay Delivery Certification As defined in Section 2.02(a) hereof.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • CEC Certification and Verification means that the CEC has certified (or, with respect to periods before the Project has commenced commercial operation (as such term is defined by and according to the CEC), that the CEC has pre-certified) that the Project is an ERR for purposes of the California Renewables Portfolio Standard and that all Energy produced by the Project qualifies as generation from an ERR for purposes of the Project.

  • Certification Date means with respect to Securities of any series (i), if Bearer Securities of such series are not to be initially represented by a temporary global Security, the date of delivery of the definitive Bearer Security and (ii), if Bearer Securities of such series are initially represented by a temporary global Security, the earlier of (A) the Exchange Date with respect to Securities of such series and (B), if the first Interest Payment Date with respect to Securities of such series is prior to such Exchange Date, such Interest Payment Date.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Back-Up Certification As defined in Section 3.18(k).

  • Certification Regarding Venue" Terms with TIPS Members Vendor agrees that if any "Venue" provision is included in any sales agreement/contract between Vendor and a TIPS Member, that clause must provide that the "Venue" for any litigation or alternative dispute resolution is shall be in the state and county where the TIPS Member operates unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a "Venue" clause that conflicts with these terms is rendered void and unenforceable. If Vendor disagrees, after this solicitation legally closes and TIPS begins evaluating Vendor's file, TIPS will provide Vendor with a draft Word Document version of the Vendor Agreement and will be instructed to include all requested negotiations as redline edits for TIPS consideration. Does Vendor agree? Yes Certification Regarding "Automatic Renewal" Terms with TIPS Members Vendor agrees that no TIPS Sale may incorporate an "Automatic Renewal" clause that exceeds month to month terms with which the TIPS Member must comply. All renewal terms incorporated into a TIPS Sale Supplemental Agreement shall only be valid and enforceable when Vendor received written confirmation of acceptance of the renewal term from the TIPS Member for the specific renewal term. The purpose of this clause is to avoid a TIPS Member inadvertently renewing a Supplemental Agreement during a period in which the governing body of the TIPS Member has not properly appropriated and budgeted the funds to satisfy the Agreement renewal. Any TIPS Sale Supplemental Agreement containing an "Automatic Renewal" clause that conflicts with these terms is rendered void and unenforceable. If Vendor disagrees, after this solicitation legally closes and TIPS begins evaluating Vendor's file, TIPS will provide Vendor with a draft Word Document version of the Vendor Agreement and will be instructed to include all requested negotiations as redline edits for TIPS consideration. Does Vendor agree? Yes Certification Regarding "Indemnity" Terms with TIPS Members Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]" unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable. If Vendor disagrees, after this solicitation legally closes and TIPS begins evaluating Vendor's file, TIPS will provide Vendor with a draft Word Document version of the Vendor Agreement and will be instructed to include all requested negotiations as redline edits for TIPS consideration. Does Vendor agree? Yes Certification Regarding "Arbitration" Terms with TIPS Members Vendor agrees that if any "Arbitration" provision is included in any TIPS Sale agreement/contract between Vendor and a TIPS Member, that clause may not require that the arbitration is mandatory or binding. Vendor agrees that if any "Arbitration" provision is included in any TIPS Sale agreement/contract between Vendor and a TIPS Member, that clause provides for only voluntary and non-binding arbitration unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing a “Arbitration” clause that conflicts with these terms is rendered void and unenforceable. If Vendor disagrees, after this solicitation legally closes and TIPS begins evaluating Vendor's file, TIPS will provide Vendor with a draft Word Document version of the Vendor Agreement and will be instructed to include all requested negotiations as redline edits for TIPS consideration. Does Vendor agree? Yes

  • Affidavit of Small Business Enterprise Certification means the fully completed, signed, and notarized affidavit that must be submitted with an application for SBE certification. Representations and certifications made by the applicant in this Affidavit are made under penalty of perjury and will be used and relied upon by City to verify SBE eligibility and compliance with SBE certification and documentation requirements.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Improvement completion assurance means a surety bond, letter of credit,

  • Certification Requirements means those requirements specified or referenced in this Agreement that you must meet in order to use and maintain the Certification Designation and use the Logo in accordance with the terms of this Agreement.

  • certification body means a body, including product or quality systems certification bodies, that may be designated by one Party in accordance with this Part to conduct certification on compliance with the other Party's standards and/or specifications to meet relevant mandatory requirements;

  • Certificate of Completion means the certificate of completion given by the Engineer-in-charge pursuant to clause 40 of these conditions;

  • Construction Completion Certificate means a document:

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Tax Certification Forms means any forms or other documentation as may be issued or required by a Tax Authority or by us from time to time to confirm your tax status [or the tax status of a Connected Person].

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Interim Certification As defined in Section 2.02.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:

  • Special Contract Attachments means any attachment to this Contract.

  • Recertification means the process by which a client’s eligibility to continue to receive child care assistance benefits are determined.

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.