Building Completion Date definition

Building Completion Date means the Phase 1 Building Completion Date, either BOA Building Completion Date or the Phase 2 Building Completion Date, as the case may be.
View Source

Examples of Building Completion Date in a sentence

  • If construction of the Unit and the building in which the Unit is to be located is not completed by the Building Completion Date, such failure to so complete shall be a default by Seller under this Agreement, in which case Buyer shall be entitled to the applicable remedies set forth in Article V, Section G.2 of this Agreement, including the cancellation of this Agreement at any time after the Building Completion Date, as the same may have been extended.

  • Accordingly, notwithstanding any other provision in this Agreement to the contrary, Seller shall complete construction of the Unit and the building in which the Unit is to be located so as to permit normal occupancy within two (2) years from the date this Agreement is signed by Buyer (the "Building Completion Date"); provided, however, that the Building Completion Date will be extended for any period of time during which construction is actually delayed by Force Majeure Events.

  • Landlord hereby agrees to make available to Tenant from and after the Base Building Completion Date, and thereafter through the Term, five thousand (5,000) square feet of Usable Area of storage space in a location within the Building reasonably acceptable to Tenant upon the terms and conditions provided in this Article 12.

  • Substantial Completion of the Base Building Improvements by the Base Building Completion Date may provide Tenant the opportunity to commence its installation of furniture, fixtures and equipment in the Leased Premises in May 2007.

  • Landlord will commence mobilization and pre-construction work for construction of the Building and Base Building Improvements (as defined in Schedule D-1 )no later than January 31, 2006, with the pouring of concrete for the core of the Building to have begun during the month of March 2006, so that the Building ,Base Building Improvements and any Upgrades shall be substantially completed by May 1, 2007 ("Base Building Completion Date").

  • Align acknowledges and accepts that if the inspections materially interfere or disrupt the construction process and causes a delay, BBC shall be released from any responsibility in connection to such interference or disruption and the Building Completion Date and/or Closing could be delayed but not more than the equivalent to the delay caused by such interference or disruption.

  • Landlord shall cause Landlord's Work to be constructed in a good and workmanlike manner in accordance with the Building Plans and Specifications on or before January 1, 1998 (the "Scheduled Building Completion Date").

  • Even if not so requested or expressed, Tenant may request prior to the Base Building Completion Date to see such Base Building Work and it shall be uncovered by Landlord.

  • If the conditions to the New Building Completion Date are met with respect to a portion of the Premises, Landlord shall notify Tenant of the same, and in the event that Tenant determines that partial occupancy is commercially reasonable for its business, then Tenant shall take early occupancy of such portion of the Premises and the earliest such date shall constitute the “New Building Partial Completion Date,” but in no event shall there be more than one New Building Partial Completion Date.

  • Notwithstanding anything contained in this section to the contrary, if Lessor is delayed in the completion of the Base Building Improvements by, or as a result of the work of Lessee’s GC and/or the completion of Lessee’s Work, then Lessor shall be entitled to extend the Base Building Completion Date by one (1) day for each day of such delay.

Related to Building Completion Date

  • Construction Completion Date or “Completion Date” means the date by which the overall Development of the Project is completed in accordance with the provisions of this Agreement and when the Completion Certificate is issued by the Authority as per Article 14.1.

  • Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which: