BSA Completion Date means the date on which the BSA Examination has been completed and any fines or penalties imposed by the Internal Revenue Service in connection with the BSA Examination have been paid.
Project Completion Date means the date on which the Completion Certificate is issued;
Final Completion Date means the date on which Final Completion occurs.
Target Completion Date has the meaning given such term in Section 3.3(b).
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Substantial Completion Date means the date on which Substantial Completion occurs.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Scheduled Project Completion Date shall have the meaning specified in Section 6.3 (c);
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
COMPLETION TIME means the period by date specified in the acceptance of tender for handing over the erected equipment/plant which are found acceptable by the Engineer being of required standard and conforming to the specifications of the contract.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;
Start-up Period means up to 7 Academy Financial Years and covers the period up to and including the first Academy Financial Year in which all age groups are present at the Academy (that is, all the pupil cohorts relevant to the age range of the Academy will have some pupils present).
Construction Completion means physical construction of a cleanup action component is complete.
Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.
Project Commencement Date means the commencement date notified to the Minister pursuant to clause 4(1);
Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.
Commercial Operation Date (COD) means the date certified by the DISCOM’s committee upon successful commissioning (as per provisions of the PPA) of the project when all equipments as per rated capacity have been installed and energy has flown into the grid.
Project Start Date means the first Milestone Start Date specified in Schedule B;
Completion Rate means the percentage of an apprenticeship cohort who receives a certificate of apprenticeship completion within 1 year of the projected completion date. An apprenticeship cohort is the group of individual apprentices registered to a specific program during a 1 year time frame, except that a cohort does not include the apprentices whose apprenticeship agreement has been cancelled during the probationary period or who have transferred.