{"component": "definition", "props": {"groups": [{"size": 456, "snippet": "means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms \u201carchitect\u201d and \u201cengineer\u201d shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect\u2019s authority is as set forth elsewhere in this contract.", "snippet_links": [{"key": "other-entity", "type": "definition", "offset": [20, 32]}, {"key": "and-other-services", "type": "clause", "offset": [99, 117]}, {"key": "related-to", "type": "definition", "offset": [118, 128]}, {"key": "the-work", "type": "definition", "offset": [129, 137]}, {"key": "in-the-contract", "type": "clause", "offset": [154, 169]}, {"key": "to-act", "type": "definition", "offset": [199, 205]}, {"key": "the-terms", "type": "definition", "offset": [224, 233]}, {"key": "the-architect-shall", "type": "clause", "offset": [282, 301]}, {"key": "technical-representative", "type": "definition", "offset": [313, 337]}, {"key": "contracting-officer", "type": "definition", "offset": [345, 364]}, {"key": "in-this-contract", "type": "clause", "offset": [418, 434]}], "samples": [{"hash": "1vtI5sjZfXo", "uri": "/contracts/1vtI5sjZfXo#architect", "label": "Contract", "score": 35.0591201782, "published": true}, {"hash": "8ZLPULNhdks", "uri": "/contracts/8ZLPULNhdks#architect", "label": "Contract for Services", "score": 34.1836891174, "published": true}, {"hash": "4mqeaXhk4wE", "uri": "/contracts/4mqeaXhk4wE#architect", "label": "Contract for Services", "score": 33.3975372314, "published": true}], "hash": "03cb8368c553f4395cb2422f18d849a1", "id": 1}, {"size": 142, "snippet": "\u201cEngineer,\u201d or \u201cA/E\u201d means a person or entity lawfully entitled to practice architecture or engineering, representing Owner within the limits of its delegated authority.", "snippet_links": [{"key": "person-or-entity", "type": "definition", "offset": [29, 45]}, {"key": "to-practice", "type": "clause", "offset": [64, 75]}, {"key": "delegated-authority", "type": "clause", "offset": [149, 168]}], "samples": [{"hash": "kZikAKgyIJy", "uri": "https://www.des.wa.gov/sites/default/files/2024-07/swr-direct-negotiate-contract-instructions.pdf", "label": "Contract", "score": 21.2014465332, "published": false}, {"hash": "c4ki5KBNVXK", "uri": "https://www.co.cowlitz.wa.us/DocumentCenter/View/34863/2025-0028-01-Admin-Roof-Replacement---ITB?bidId=", "label": "www.co.cowlitz.wa.us", "score": 20.252620697, "published": false}, {"hash": "gZ4PDLEXfGo", "uri": "https://www.islandcountywa.gov/DocumentCenter/View/9840/Island-County-Bayshore-Project---Bid-Specs-PDF?bidId=", "label": "www.islandcountywa.gov", "score": 20.2100048065, "published": false}], "hash": "87d91a7d70cfce28e5b5c91cc073e87d", "id": 2}, {"size": 77, "snippet": "means the Architect appointed or to be appointed from time to time by Promoter for the purpose of planning, designing and supervision of the construction of the Building(s).", "snippet_links": [{"key": "the-architect", "type": "definition", "offset": [6, 19]}, {"key": "from-time-to-time", "type": "clause", "offset": [49, 66]}, {"key": "for-the-purpose-of", "type": "definition", "offset": [79, 97]}, {"key": "construction-of-the", "type": "clause", "offset": [141, 160]}], "samples": [{"hash": "k7qZdtaCL67", "uri": "/contracts/k7qZdtaCL67#architect", "label": "Agreement for Sale", "score": 34.1974868774, "published": true}, {"hash": "lpaH5zBJ53x", "uri": "/contracts/lpaH5zBJ53x#architect", "label": "Agreement for Sale", "score": 34.051651001, "published": true}, {"hash": "9BVVEGnYMcY", "uri": "/contracts/9BVVEGnYMcY#architect", "label": "Agreement for Sale", "score": 34.051651001, "published": true}], "hash": "c9e3a4d38e6233befab02d021d39b524", "id": 3}, {"size": 68, "snippet": "means a holder of a license, a certificate of practice, or a temporary license under the Architect\u2019s Act as defined in the Building Code.", "snippet_links": [{"key": "a-holder-of-a", "type": "clause", "offset": [6, 19]}, {"key": "certificate-of-practice", "type": "definition", "offset": [31, 54]}, {"key": "temporary-license", "type": "definition", "offset": [61, 78]}, {"key": "the-architect", "type": "definition", "offset": [85, 98]}, {"key": "building-code", "type": "definition", "offset": [123, 136]}], "samples": [{"hash": "kc7PN0umAgA", "uri": "https://www.snnf.ca/api/media/file/BUILDINGBYLAW.pdf", "label": "www.snnf.ca", "score": 20.4224300385, "published": false}, {"hash": "gYsjjpacst5", "uri": "https://www.stratford.ca/en/inside-city-hall/resources/BUILDING-PLANNING-SERVICES/BUILDING/Building-By-law---112-2005_aoda.pdf", "label": "www.stratford.ca", "score": 19.8711147308, "published": false}, {"hash": "6xuZIH0W7a4", "uri": "https://listview.kenora.ca/Files/ByLaws/2024/168-2024%20Construction,%20Demolition%20and%20Change%20of%20Use%20Permits%20and%20Inspections.pdf", "label": "listview.kenora.ca", "score": 19.798204422, "published": false}], "hash": "acf89c968b688cf5e6f5f4362e5fcc6b", "id": 4}, {"size": 68, "snippet": "means the architect/s appointed by the Seller from time to time for the purposes of the Development;", "snippet_links": [{"key": "the-architect", "type": "definition", "offset": [6, 19]}, {"key": "by-the-seller", "type": "clause", "offset": [32, 45]}, {"key": "from-time-to-time", "type": "clause", "offset": [46, 63]}, {"key": "the-development", "type": "clause", "offset": [84, 99]}], "samples": [{"hash": "iFwlAda5K6p", "uri": "/contracts/iFwlAda5K6p#architect", "label": "Agreement of Sale", "score": 31.7660675049, "published": true}, {"hash": "ho0mki91EZ3", "uri": "/contracts/ho0mki91EZ3#architect", "label": "Agreement of Sale", "score": 31.1884822845, "published": true}, {"hash": "3pEmb0msvLv", "uri": "/contracts/3pEmb0msvLv#architect", "label": "Sale Agreement", "score": 30.7049846649, "published": true}], "hash": "be2630fdf38d32a657a7f00bd6835656", "id": 5}, {"size": 67, "snippet": "or \u201cArchitect/Engineer\u201d means any person or firm employed by the Commission for the purpose of designing the project.", "snippet_links": [{"key": "any-person", "type": "clause", "offset": [30, 40]}, {"key": "by-the-commission", "type": "clause", "offset": [58, 75]}, {"key": "for-the-purpose-of", "type": "definition", "offset": [76, 94]}, {"key": "the-project", "type": "clause", "offset": [105, 116]}], "samples": [{"hash": "gLbjVy4xo4u", "uri": "/contracts/gLbjVy4xo4u#architect", "label": "Design Build Agreement", "score": 26.4894371033, "published": true}, {"hash": "6i2RzQDA73m", "uri": "/contracts/6i2RzQDA73m#architect", "label": "Design Build Agreement", "score": 25.1218338013, "published": true}, {"hash": "3y1Wr6NdJVW", "uri": "/contracts/3y1Wr6NdJVW#architect", "label": "Design Build Agreement", "score": 25.1218338013, "published": true}], "hash": "2ccda9288248d466aee2f52896619d72", "id": 6}, {"size": 64, "snippet": "means a member of the project team who is a New Mexico licensed architect and is responsible for the architectural services.", "snippet_links": [{"key": "the-project-team", "type": "clause", "offset": [18, 34]}, {"key": "new-mexico", "type": "definition", "offset": [44, 54]}, {"key": "licensed-architect", "type": "definition", "offset": [55, 73]}, {"key": "responsible-for", "type": "clause", "offset": [81, 96]}, {"key": "the-architectural-services", "type": "clause", "offset": [97, 123]}], "samples": [{"hash": "kdCQlOqpcm7", "uri": "https://core-docs.s3.us-east-1.amazonaws.com/documents/asset/uploaded_file/1176/BCS/4692266/DBB_RFP_for_Construction_review_final__002_.pdf", "label": "core-docs.s3.us-east-1.amazonaws.com", "score": 19.2974147797, "published": false}, {"hash": "2Zffd7N4U4P", "uri": "https://core-docs.s3.us-east-1.amazonaws.com/documents/asset/uploaded_file/3198/NMSD/4511851/NMSD_RFP_for_JAL_Rennovation___Central_Plant_Upgrades.pdf", "label": "core-docs.s3.us-east-1.amazonaws.com", "score": 19.2102012634, "published": false}, {"hash": "cOUpiHl4hMT", "uri": "https://core-docs.s3.us-east-1.amazonaws.com/documents/asset/uploaded_file/3492/CMSD/3739784/P20-010_Clovis_Barry_ES_DBB_RFP_for_Construction-1.pdf", "label": "core-docs.s3.us-east-1.amazonaws.com", "score": 18.5820865631, "published": false}], "hash": "e26f8a0080b341d6d0034ea94f87557b", "id": 7}, {"size": 63, "snippet": "means the person or other entity engaged by for performance of the work. The Contractor shall also the PHA to perform architectural, engineering, design, furnish all necessary water, heat, light, and power not", "snippet_links": [{"key": "other-entity", "type": "definition", "offset": [20, 32]}, {"key": "performance-of-the-work", "type": "clause", "offset": [48, 71]}, {"key": "the-contractor-shall", "type": "clause", "offset": [73, 93]}, {"key": "necessary-water", "type": "definition", "offset": [166, 181]}], "samples": [{"hash": "eWVF4dNSTlL", "uri": "https://homesforgood.org/documents/files/bids/116/25-C-0019-HC-HVAC-System-Upgrade-Manual.pdf?cb=252014032046", "label": "Contract", "score": 24.0717086792, "published": false}, {"hash": "444nOQaGaHy", "uri": "https://housinguc.org/pdf/RFP-HAUC2024-06-General%20Contractor.pdf", "label": "General Contract", "score": 23.3115692139, "published": false}, {"hash": "1OAvRWWub8R", "uri": "https://trumbulltmha.org/wp-content/uploads/2022/08/4E-HUD-5370.pdf", "label": "Construction Contract", "score": 21.2886962891, "published": false}], "hash": "319e8a4a1e436794680aab53c3b6531d", "id": 8}, {"size": 62, "snippet": "means Architect/ Architectural Consultant appointed by the Bank for the Project.", "snippet_links": [{"key": "architectural-consultant", "type": "definition", "offset": [17, 41]}, {"key": "by-the-bank", "type": "clause", "offset": [52, 63]}, {"key": "the-project", "type": "clause", "offset": [68, 79]}], "samples": [{"hash": "kTxLWXvhWbp", "uri": "https://canarabank.com/img/UploadedFiles/Tenders/English/a1e31d7fc58849d882fd4c030c03975f.pdf", "label": "canarabank.com", "score": 19.9870471954, "published": false}, {"hash": "3ieReHFU7he", "uri": "https://canarabank.com/img/UploadedFiles/Tenders/English/bd5cc9e63b4f4071923cde573b5562bd.pdf", "label": "canarabank.com", "score": 19.9734077454, "published": false}, {"hash": "hEvK7NHJ3RQ", "uri": "https://canarabank.com/img/UploadedFiles/Tenders/English/3a9499461d614f5099f60578b9a798bb.pdf", "label": "canarabank.com", "score": 19.9734077454, "published": false}], "hash": "91a79ea7c20e0cae400c990ffbf60ee8", "id": 9}, {"size": 59, "snippet": "means the person so designated in writing by the Commissioner in the Notice to Proceed or the Order to Work to act as such in relation to this Contract, including a private Architect or Engineer or Project Manager, as the case may be. Subject to written approval by the Commissioner, the Engineer, Architect or Project Manager may designate an authorized representative.", "snippet_links": [{"key": "in-writing", "type": "clause", "offset": [31, 41]}, {"key": "the-commissioner", "type": "clause", "offset": [45, 61]}, {"key": "the-notice-to-proceed", "type": "clause", "offset": [65, 86]}, {"key": "order-to-work", "type": "definition", "offset": [94, 107]}, {"key": "to-act", "type": "definition", "offset": [108, 114]}, {"key": "in-relation-to", "type": "clause", "offset": [123, 137]}, {"key": "this-contract", "type": "definition", "offset": [138, 151]}, {"key": "architect-or-engineer", "type": "clause", "offset": [173, 194]}, {"key": "project-manager", "type": "clause", "offset": [198, 213]}, {"key": "the-case", "type": "definition", "offset": [218, 226]}, {"key": "subject-to", "type": "clause", "offset": [235, 245]}, {"key": "approval-by", "type": "clause", "offset": [254, 265]}, {"key": "the-engineer", "type": "definition", "offset": [284, 296]}, {"key": "manager-may", "type": "definition", "offset": [319, 330]}, {"key": "authorized-representative", "type": "definition", "offset": [344, 369]}], "samples": [{"hash": "fZ3qShTqWQG", "uri": "/contracts/fZ3qShTqWQG#architect", "label": "Service Agreement", "score": 26.2416152954, "published": true}, {"hash": "lWiZMpZUHAa", "uri": "/contracts/lWiZMpZUHAa#architect", "label": "Supply and Service Agreement", "score": 26.1704311371, "published": true}, {"hash": "kX9lqro0NmN", "uri": "/contracts/kX9lqro0NmN#architect", "label": "Furnish and Install Agreement", "score": 26.1704311371, "published": true}], "hash": "6247df2082a68f2c830092244aabe4ca", "id": 10}], "next_curs": "ClYSUGoVc35sYXdpbnNpZGVyY29udHJhY3RzcjILEhpEZWZpbml0aW9uU25pcHBldEdyb3VwX3Y1NiISYXJjaGl0ZWN0IzAwMDAwMDBhDKIBAmVuGAAgAA==", "definition": {"size": 5855, "snippet": "means the person or other entity engaged by the PHA to perform architectural, engineering, design, and other services related to the work as provided for in the contract. When a PHA uses an engineer to act in this capacity, the terms \u201carchitect\u201d and \u201cengineer\u201d shall be synonymous. The Architect shall serve as a technical representative of the Contracting Officer. The Architect\u2019s authority is as set forth elsewhere in this contract.", "title": "Architect", "id": "architect", "examples": ["Contractor shall furnish to Owner (and, if directed by the Owner, Contractor shall furnish a copy to the <strong>Architect</strong>) monthly applications for payment in such form as may be approved by the Owner not later than the 30th day of the month (\u201cApplication for Payment\u201d).", "The Owner may delegate to the <strong>Architect</strong> some of its rights or responsibilities in this Agreement.", "The <strong>Architect</strong> has no authority, over its individual signature, to authorize any additional or changed Work that would require an increase in the Contract Sum or an extension of the Completion Dates.", "All Drawings, Specifications and copies thereof furnished by the <strong>Architect</strong> are and shall remain the property of the Owner.", "The Contractor, Subcontractors, Sub-subcontractors and material or equipment suppliers are granted a limited license to use and reproduce applicable portions of the Drawings, Specifications and other documents prepared by the <strong>Architect</strong> appropriate to and for use in the execution of their Work under the Contract Documents.", "Within thirty-five (35) days after the Contractor has furnished the Owner (and <strong>Architect</strong>, if required) with a complete and accurate Application for Payment as provided by this Agreement, the Owner shall make payment to the Contractor.", "In the event of delay to the critical path activities of the Work caused by the Owner, the <strong>Architect</strong>, or the employees or agents of either, the Contractor shall also be entitled to an equitable adjustment in the Contract Sum only for those additional field overhead costs actually incurred as a result of delay to the critical path activities of the Work, and no other damages or costs of any kind, including indirect (e.g., home office overhead costs), incidental, or consequential damages.", "Neither the Owner nor the Project Manager or <strong>Architect</strong> shall be responsible for the supervision, coordination or inspection of the Contractor\u2019s Work.", "The Owner may designate the Project <strong>Architect</strong>, if any, to fulfill some or all of its responsibilities in connection with shop drawings, samples and product data.", "The Contractor shall promptly correct Work rejected by the Owner, the <strong>Architect</strong>, or any governmental authority, or that does not conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed."], "related": [["project-architect", "Project Architect", "Project <strong>Architect</strong>"], ["architect-engineer", "Architect/Engineer", "<strong>Architect</strong>/Engineer"], ["architects", "Architects", "<strong>Architects</strong>"], ["landscape-architect", "Landscape architect", "Landscape <strong>architect</strong>"], ["engineer", "Engineer", "Engineer"]], "related_snippets": [], "updated": "2026-04-10T04:42:41+00:00"}, "json": true, "cursor": ""}}