EXHIBIT 10.3
AGREEMENT BETWEEN THE AGRICULTURAL FOUNDATION OF CALIFORNIA STATE UNIVERSITY,
FRESNO AND BION ENVIRONMENTAL TECHNOLOGIES, INC.
(Regarding the contribution, installation, use and removal of environmental
testing equipment/structures)
This Agreement (hereinafter referred to as the "Agreement") is entered into
this 19th day of November, 2002, by Bion Environmental Technologies, Inc.
(hereinafter referred to as "BION"), and the Agricultural Foundation of
California State University, Fresno, a California nonprofit public benefit
corporation serving as a California State University sponsored projects
auxiliary organization (hereinafter referred to as the "Agricultural
Foundation").
WHEREAS, the Agricultural Foundation is not a public agency, but rather an
Internal Revenue Code Section 170 (c) qualified charitable organization exempt
from taxation under Internal Revenue Code Section 501 (c) (3) and California
Revenue and Taxation Code Section 23701d; and
WHEREAS, the Agricultural Foundation, by virtue of an Operating Agreement and
Lease Agreement with the Trustees of the California State University, has the
right to possess and operate certain farming and dairy properties/facilities
on the campus of California State University, Fresno (hereinafter the
"Premises") for research, educational, and related purposes and uses in
conformity with Title V of the California Code of Regulations Section 42500,
in the furtherance of California State University, Fresno's (hereinafter the
"University") educational mission; and
WHEREAS, BION is involved in the business of developing innovative livestock
nutrient management systems; and
WHEREAS, BION wishes to contribute certain equipment/structures to the
Agricultural Foundation for mutually-beneficial research purposes (as such
purposes are described in Exhibit C hereto), and install the same on the
Premises, subject to the terms and conditions contained herein; and
WHEREAS, from time to time, the California Agricultural Technology Institute
(hereinafter "CATI") may serve as the designee of the Agricultural Foundation
for the purposes of conducting agriculturally related research projects
utilizing the property/facilities leased by the Agricultural Foundation; and
WHEREAS, it is the desire of the Agricultural Foundation, through its
designee, CATI, to engage in such agriculturally related research and
educational activities on the terms and conditions contained herein.
NOW THEREFORE, in consideration of the mutual recitals and promises herein
contained and for such other and further consideration as is hereby
acknowledged, and upon consultation with their respective counsel/advisors
and/or opportunity therefor, the parties agree as follows:
1. Term and Termination. (a) This Agreement shall be effective upon the
due execution of the Construction Agreement (as defined below). Once
effective, this Agreement shall continue in full force and effect for a period
of thirty (30) days following the Completion Date (as defined in section 6(a)
below) (hereinafter the "Term"), subject to earlier termination in accordance
with the provisions hereof.
(b) BION shall have the right to terminate this Agreement, effective
immediately upon written notice, if (i) the University Parties (as defined
below) fail to substantially perform their duties pursuant hereto or (ii) the
University Parties breach the provisions hereof.
(c) The Agricultural Foundation shall have the right to terminate this
Agreement effective immediately upon written notice if BION fails to
substantially perform its duties pursuant hereto or it breaches the provisions
hereof.
2. Equipment. BION agrees that it will provide to the Agricultural
Foundation, at no cost to the Agricultural Foundation, the University, the
Trustees of the California State University, CATI, or the State of California,
such equipment and the related structure as specified in Exhibit A attached
hereto and incorporated herein by this reference (collectively, the
"Equipment"). The Agricultural Foundation shall allow the Equipment to be
installed on the Premises by May 1, 2003 or as soon thereafter as reasonably
possible. Notwithstanding the foregoing, the parties understand and agree
that the Agricultural Foundation shall be responsible for (i) its portion of
the taxes set forth in Section 4(a), with BION being responsible for its own
portion of said taxes pursuant thereto, (ii) the laboratory research and other
costs set forth in Section 6(a), and (iii) all ongoing operational and
maintenance costs related to the Transferred Equipment (as defined below)
incurred following the Term.
3. Installation of Equipment. BION will cause the Equipment to be
installed on that portion of the Premises identified to and approved by the
Executive Director of the Agricultural Foundation, by retaining a California
general contractor experienced and qualified to perform the installation of
the Equipment (hereinafter the "Contractor"). The Contractor will be selected
by BION, but will be subject to the reasonable approval of the Agricultural
Foundation. BION will be solely responsible for all installation,
installation materials and related fees, costs and expenses, and will
indemnify, defend and hold harmless the Agricultural Association, the Trustees
of the California State University, California State University, Fresno, CATI,
the State of California (together, the "University Parties"), and each of said
entities' employees, agents, representatives, divisions, directors, officers,
and attorneys (hereinafter, an "Agent") from and against such installation,
installation materials and related fees, costs and expenses (including, but
not limited to, the cost of the Equipment, the Contractor's fees and costs,
and all other related costs and expenses), as well as all liability, suits,
claims and damages arising from or relating to such installation. In
conformity with this paragraph 3, the Agricultural Foundation, the Contractor
and BION will enter into a separate written agreement in compliance with the
policies and procedures of the Agricultural Foundation, Trustees of the
California State University, CATI, and California State University, Fresno,
which written agreement shall detail the rights and responsibilities of the
parties thereto, as it applies to the Equipment installation goods and
services to be provided by the Contractor, in a form to be mutually agreed
upon by the party (the "Construction Agreement").
4. Title to Equipment; License to use Equipment and Technology. (a) Title
to such of the Equipment (the "Transferred Equipment") that is listed on
Exhibit A but that is not listed on Exhibit B shall pass to the Agricultural
Foundation upon delivery of the Equipment to Premises, provided however, that
should the Agricultural Foundation substantially fail to perform its duties or
obligations hereunder, or otherwise materially breach this Agreement, (i) as a
result of conditions that are not beyond the control of the Agricultural
Foundation, and (ii) at a time when BION is not in material breach of this
Agreement that resulted in the University Parties' above-referenced failure to
perform or breach, then title to the Transferred Equipment shall be conveyed
back to BION, and the University Parties agree to timely execute any documents
and take any actions reasonably requested by BION to accomplish such
conveyance. With respect to those items listed on Exhibit B (the "Bion
Equipment"), BION shall at all times retain title thereto. BION will be
solely responsible for the removal of the Bion Equipment from the Premises
following the Completion Date and all costs attendant thereto. Any and all
taxes payable in connection with the transfer of title to the Transferred
Equipment shall be borne such that BION will pay one-half of such taxes, and
the remaining one-half shall be paid by the Agricultural Foundation.
(b) BION hereby grants to the Agricultural Foundation and CATI, as designee of
the Agricultural Foundation, (i) a royalty-free license, which may not be
assigned or sublicensed, to use the Equipment solely to conduct the Research
at the Premises, pursuant to the protocol set forth on Exhibit C hereto and
the other terms and conditions hereof during the Term, and (ii) a
non-exclusive, royalty-free license, which may not be assigned or sublicensed,
to use the Know-How (as defined below) solely at the Premises and pursuant to
the protocol set forth on Exhibit C hereto and the other terms and conditions
hereof, (x) to operate the BION Equipment during the Term, and (y) to operate
the Transferred Equipment during the Term and for purposes of the Fresno
Research for a period of 20 years commencing upon the end of the Term.
"Know-How" shall mean all technical data, information, drawings and designs,
know-how, trade secrets, procedures, protocols, software object and source
code, algorithms and instructions constituting part of or used in connection
with the Bion System (as defined below) that is in the possession of the
Licensor, to the extent that same is required for the use of the Bion System
at the Premises pursuant to the terms of this Agreement. In the event that
the Agricultural Foundation or CATI, as its designee, materially fails to
comply with the operating conditions set forth on Exhibit C hereto, and such
failure results in damage to the Bion System or interferes with the effective
operation of the Bion System, then BION shall have the right to immediately
terminate the licenses granted pursuant to this Section 4(b).
5. Damage to Property. (a) At no time during the Term will BION commit
any act, or fail to perform any act, that damages the Premises or other
property of the University Parties. Following the Completion Date and during
the Term, BION will be responsible for the removal of the Bion Equipment from
the Premises, and for the return of the Premises to such condition as existed
prior to the execution of this Agreement, normal wear and tear excepted.
Notwithstanding the foregoing, BION will promptly replace the master research
control panel (which it will remove and retain following the Completion Date)
with an operational control panel capable of properly controlling and
monitoring the Transferred Equipment. In this regard, BION agrees that
immediately following its execution of this Agreement, it will place on
deposit in a trust account with the California State University, Fresno
Foundation ("Foundation"), the sum of Twenty Thousand Dollars ($20,000.00)
(hereinafter the "Deposit") to be held by the Foundation during the Term, as a
security deposit to guarantee BION's faithful compliance with this Section
5(a). The Agricultural Foundation and BION shall both be required to execute
any documents necessary for disbursements to be made from said trust account.
Should BION, or anyone hired by and/or acting on behalf of BION, at any time
during the Term damage the Premises or other property of the University
Parties, the Agricultural Foundation shall notify BION in writing of the type
and amount of such claim, including any supporting documents, and indicate
that it is the intention of the Agricultural Foundation, on behalf of such
damaged entity, to satisfy such claim, in whole or in part, through the
appropriation of all or a portion of the Deposit. If the Agricultural
Foundation does not receive written notification in accordance with Section 10
hereof of BION's objection to the claim within thirty (30) calendar days
following BION's receipt of the claim, BION will be deemed to have consented
to settlement of the claim out of the Deposit, and BION will thereafter
execute any documents as may be necessary to disburse such funds out of the
Deposit to satisfy the claim. If BION does send the Agricultural Foundation
notice that it objects to the claim within such thirty-day period, then the
dispute shall be settled by arbitration pursuant to Section 9 hereof. BION's
obligations referred to in this Section 5(a) shall not be limited to the
amount of the Deposit. Any Deposit monies remaining at the end of the Term
shall be returned to BION within ten (10) calendar days after the end of the
Term.
(b) The Agricultural Foundation agrees that to the extent reasonably
practicable, it shall ensure that, at no time during the Term will any
University Party commit any act, or fail to perform any act, that damages the
Equipment, unreasonably interferes with the operation of the Equipment, or
otherwise compromises the integrity of the Bion System Research and/or Bion
System Results (as such terms are defined below).
6. Research; Results; Ownership. (a) The Agricultural Foundation shall,
and/or shall cause CATI, as designee of the Agricultural Foundation, to,
utilize the Equipment on the Premises for the purpose of conducting
independent, scientifically-based evaluations of the BION Nutrient Management
Waste Treatment System (as further defined in Exhibit D hereto, the "Bion
System") under the conditions described as "Core Conditions" in Exhibit C
hereto, in order to determine the Bion System's efficacy in reducing potential
pollutants released into the air, surface waters or groundwater from dairy
effluents (the "Phase One Research"). In addition, the Agricultural
Foundation and CATI, as designee, shall provide unrestricted access to the
Premises to such persons as BION shall designate in order to enable BION to
monitor the operations of the Bion System, perform maintenance, conduct
evaluations of the Bion System (including under the conditions described as
"Stress Conditions" in Exhibit C hereto (the "Phase Two Research" and,
together with the Phase One Research, the "Bion System Research")) and for all
other purposes contemplated by this Agreement. The Agricultural Foundation
and CATI, as its designee, may also conduct research the focus of which is not
the Bion Technology (the "Fresno Research" and, together with the Bion System
Research, the "Research"). The Phase One Research shall be conducted in
accordance with the protocol and within the time periods set forth in Exhibit
C hereto. The Agricultural Foundation and CATI, as its designee, shall not
commence the Phase One Research until BION advises them in writing that the
Bion System has reached equilibrium. Copies of any and all raw data, analyses
and lab results resulting from or relating to the Research or any other
analyses of the BION System, or collected from the Bion System by any of the
University Parties, their contracted researchers, and/or any other Agents
thereof (the "Data"), shall be submitted to BION immediately. The parties
agree that the Agricultural Foundation or CATI, as its designee, shall
complete the Phase One Research and deliver to BION a final written report
thereon (the "Phase One Report"), which shall set forth in detail the findings
of the Phase One Research, within a period of sixty (60) days from the date on
which the Phase One Research is completed in accordance with Exhibit C hereto.
The date on which BION has received the Phase One Report shall hereinafter be
referred to as the "Completion Date." BION shall have the right to approve or
disapprove of the Phase One Report for any reason whatsoever. If BION
approves of the Phase One Report, it shall deliver a written notice so
indicating to the Agricultural Foundation. Failure of BION to notify the
Agricultural Foundation or CATI of BION's approval or disapproval of the Phase
One Report within fourteen (14) calendar days following the Completion Date
shall be deemed to be an approval of the Phase One Report. Upon the actual or
deemed approval of BION in accordance with this Subsection, the Agricultural
Foundation and/or CATI shall have the right to publish the Phase One report
pursuant to this Section 6. In the event that BION disapproves of the Phase
One Report by so notifying the Agricultural Foundation or CATI within the
14-day period described above, BION shall have the right to append comments to
the Phase One Report, which shall in all cases be published or disseminated
with the Phase One Report. BION shall provide such comments to the
Agricultural Foundation or CATI within thirty (30) days following the
Completion Date. In the event that the Agricultural Foundation and/or CATI,
to their knowledge, substantially fails to adhere to the protocol relative to
the Phase One Research set forth on Exhibit C hereto, then the Agricultural
Foundation and/or CATI shall (i) promptly disclose such failure to BION and
(ii) include in their portion of the Phase One Report a clear statement that,
and the manner in which, such protocol materially was not followed. The
laboratory costs and all other costs of the Phase One Research and any Fresno
Research, and delivery of the Phase One Report and any other Data to BION,
shall be borne by the Agricultural Foundation. The laboratory costs and all
other costs of the Phase Two Research shall be borne by BION.
(b) BION shall own all rights, title and interest in and to the results of the
Bion System Research and the Data related thereto, including the Phase One
Report, and any interim reports (collectively, the "Bion System Results").
The Agricultural Foundation shall own all rights, title and interest in and to
the Fresno Research. However, the University Parties shall have a
non-exclusive right to publish and otherwise disseminate the Phase One Report,
provided that (i) such Phase One Report is delivered to BION at least fourteen
(14) days prior to its dissemination and (ii) if BION disapproves of the
report pursuant to Subsection 6(a) above, then BION shall be permitted to
append comments and/or require the Agricultural Foundation and/or CATI to
include a statement in the Phase One Report in accordance with the provisions
of Subsection 6(a) above. The University Parties will, at any time at BION's
request and at BION's cost, execute and deliver to BION such assignments,
certificates or other instruments as BION may from time to time deem necessary
or desirable to evidence, establish, maintain, perfect, protect, enforce or
defend BION's right, title and interest in and to the Bion System Results.
(c) The Bion Equipment, the Bion System, the Know-How and any and all
Improvements (defined below) (collectively, the "Bion Technology") are and
shall remain the sole and exclusive property of BION. For purposes hereof,
"Improvements" shall mean any version, enhancement, modification or refinement
of the Bion System, the Know-How and/or technologies related to biological
nutrients, odor, air emission and residuals conversion and/or control
processes, anaerobic treatment processes, residuals/waste management and water
reuse, whether patented or not, which is capable of improving the technical
and/or economic characteristics of the Bion System and the Know-How or such
technologies. Intellectual property rights regarding products, procedures,
processes, or inventions developed through use of the Transferred Equipment
following the Term that do not relate to the Bion Technology shall be solely
owned by the Agricultural Foundation and CATI. Intellectual property rights
regarding products, procedures, processes, or inventions developed through use
of the Equipment during or following the Term that relate to the Bion
Technology shall be solely owned by BION. Notwithstanding the foregoing, (i)
for a period of twenty (20) years following the Term, the Agricultural
Foundation and/or CATI may engage in research using the Transferred Equipment
and/or any aspect of the Know-How for the development of a theretofore unique
application/use thereof with regard to dairy air and/or water emissions,
residual/waste treatment, water reuse, anaerobic treatment, or related dairy
purposes/uses, (ii) prior to engaging in such research, the Agricultural
Foundation or CATI shall offer BION a right of first refusal to partner in
such research and jointly own any intellectual property developed thereby, and
(iii) should BION decline to exercise the aforementioned right of first
refusal, then all intellectual property developed through such research shall
be solely owned by the Agricultural Foundation and/or CATI.
7. Confidential Information. (a) Each party will, and shall cause its
Agents to (and, in the case of the Agricultural Foundation, will cause the
other University Parties and their Agents to), maintain all information
received by it from the other party in trust and confidence and will not
disclose any such information ("Confidential Information") to any third party
or use any such Confidential Information for any purposes other than those
purposes permitted under this Agreement, all under terms and conditions
similar to those specified in that certain "Confidentiality/Proprietary
Information Agreement," dated April 24, 2002, executed by and between BION and
California State University, Fresno and incorporated herein by this reference
(the "Confidentiality Agreement"). Each party may use the other party's
Confidential Information only to the extent explicitly permitted under this
Agreement or required to accomplish the purposes of this Agreement. Except as
otherwise explicitly provided herein, all information related to the Bion
System Research, Bion System Results and the Bion Technology shall be treated
as the Confidential Information of BION for purposes of this provision. Each
party shall, and shall cause its Agents to (and, in the case of the
Agricultural Foundation, will cause the other University Parties and their
Agents to), use at least the same standard of care as it uses to protect its
own Confidential Information of a similar nature to ensure that its Agents do
not disclose or make any unauthorized use of such Confidential Information,
but in any event no less than reasonable care. Each party will promptly
notify the other upon discovery of any unauthorized use or disclosure of the
other party's Confidential Information.
(b) Confidential Information shall not include any information that the
receiving party can demonstrate by competent written records: (i) is now, or
hereafter becomes, through no act or failure to act on the part of the
receiving party in breach hereof, generally known or available; (ii) is known
by the receiving party, through a third party source, at the time of receiving
such information, as evidenced by its written records; (iii) is hereafter
furnished to the receiving party by a third party, as a matter of right and
without restriction on disclosure; (iv) is independently developed by the
receiving party without use of the Confidential Information of the other party
or any breach of this Agreement; or (v) is the subject of a written permission
to disclose provided by the disclosing party.
(c) Notwithstanding any other provision of this Agreement, each party may
disclose Confidential Information if such disclosure: (i) is in response to
an apparently valid subpoena, or order of a court or other governmental body
of the United States or a foreign country, or any political subdivision
thereof; provided, however, that the responding party shall first have given
notice to the other party hereto; (ii) is otherwise required by law or
regulation; provided, however, that the responding party shall first have
given notice to the other Party hereto; or (iii) is otherwise necessary to
establish rights or enforce obligations under this Agreement, but only to the
extent that any such disclosure is necessary under the circumstances.
(d) In the event this Agreement is terminated, each Party shall return to the
other party all Confidential Information received by it from the other party,
provided, however, that each party may keep one copy of such Confidential
Information for legal archival purposes. Access to the copy so retained by
each party's legal department shall be restricted to counsel and such
Confidential Information shall not be used except in the resolution of any
claims or disputes arising out of this Agreement.
8. Indemnification. BION shall indemnify, defend and hold harmless the
Trustees of the California State University, the State of California, and all
of said entities' Agents from and against any and all claims, damages, suits,
costs, expenses and liabilities arising out of BION's breach of any of its
obligations contained in this Agreement. BION shall indemnify, defend and
hold harmless the Agricultural Foundation and CATI, and all of said entities'
Agents from and against any and all claims, damages, suits, costs, expenses
and liabilities arising out of BION's breach of any of its obligations
contained herein. The Agricultural Foundation shall indemnify, defend and
hold harmless BION, and all of its Agents from and against any and all claims,
damages, suits, costs, expenses and liabilities arising out of a University
Party's breach of any of their obligations contained herein.
9. Dispute Settlement. Any dispute regarding the construction or
application of any of the terms, provisions, or conditions of this Agreement
shall on the written request of either party served on the other, be resolved
by arbitration in accordance with the rules and procedures set forth in
California Code of Civil Procedure Sections 1280-1294.2, including the right
to conduct the discovery specified in C.C.P. Section 1283.05. All such
disputes shall be arbitrated in Fresno, California. The arbitration shall be
before one neutral arbitrator to be selected in accordance with the Commercial
Rules of the American Arbitration Association, which shall assume
responsibility for administering said arbitration. The arbitrator shall be a
member of the California State bar actively engaged in the practice of law; or
a retired member of the state or federal judiciary. The substantive law of
the State of California, including its statue of limitations applicable to the
commencement of a lawsuit, shall apply to the arbitration. The arbitrator
shall follow the rules of evidence of the State of California relating to the
trial of a civil action. The arbitrator is empowered to grant summary rulings
in response to motions filed by a party prior to the final decision of the
arbitrator and may grant any remedy or relief that a court of the State of
California may grant under the circumstances. The cost of the arbitration
shall be borne by the losing party or in such proportions, as the arbitrator
deems appropriate. Judgment on the arbitration award may be entered in any
court having jurisdiction over the subject matter of the controversy. The
parties hereto understand that by signing this Agreement, they are waiving any
rights they may possess to have such disputes litigated in a court or by jury
trial.
10. Notices. All notices and demands which either party is required to or
desires to give to the other shall be given in writing by personal delivery,
express courier service or by telecopy to the address or telecopy number set
forth below for the respective party, provided that if any party gives notice
of a change of name, address or telecopy number, notices to that party shall
thereafter be given as demanded in that notice. All notices and demands so
given shall be effective upon receipt by the party to whom notice or a demand
is being given.
The Agricultural Foundation:
The Agricultural Foundation of California State University, Fresno
Attn.: Executive Director
0000 Xxxx Xxxx Xxxxxx
Xxxxxx, XX 00000-0000
(000) 000-0000 (phone)
(000) 000-0000 (fax)
With courtesy copy to:
CATI
Attention: Xxx Xxxxxxx
0000 X. Xxxxxxx Xxx.
Xxxxxx, XX 00000-0000
(000) 000-0000
BION:
Bion Environmental Technologies, Inc.
Attn.: Xxxxx Xxxxxxxx, Chief Executive Officer
Address: 00 Xxxx 00xx Xxxxxx, 00xx Xxxxx
Xxx Xxxx, Xxx Xxxx 00000
Phone Number: (000) 000-0000
Fax Number: (000) 000-0000
11. Entire Agreement. This Agreement and any and all documents/materials
referenced herein shall constitute the entire agreement between the parties on
the subject matter hereof. This Agreement supersedes all prior understandings
or agreements, oral, parole, or otherwise, except that the Confidentiality
Agreement shall remain in full force and effect to the extent it is not
inconsistent with the terms and conditions of Section 7 hereof. No such
understanding or agreement not incorporated herein shall be binding upon the
parties hereto. This Agreement may be amended only in a writing signed by
the parties hereto.
12. Relationship of Parties. This Agreement is not intended to
constitute, create, give rise to, or otherwise recognize a joint venture,
partnership or formal business entity of any kind. Neither party hereto shall
have the authority to enter into any obligation on behalf of the other, or to
represent itself as an agent or representative of the other.
13. Attorney Fees. In any action or proceeding brought by a party hereto,
seeking to enforce any of its rights or obligations incurred hereunder, the
prevailing party in such action shall be entitled to reasonable attorney fees
and costs incurred therein in addition to any other relief to which such party
may be entitled.
14. Due Investigation. Unless otherwise expressly provided herein, the
parties and signatories hereto and each of them expressly acknowledge and
agree that it:
a) Is separately represented and advised as to the subject matter hereof;
b) Has undertaken its own investigation of this transaction and the
possible effects/consequences thereof;
c) Has been afforded an opportunity to consult with respective counsel,
advisors, and/or consultants; and
d) Has not relied upon any claim, representation, and/or warranty made by
any party hereto, or the agent thereof, except to the extent expressly set
forth herein.
15. Construction. The parties and signatories and each of them further
acknowledge and agree that this Agreement has been jointly prepared by the
parties hereto, that it will be construed fairly as to both parties, and that
it shall not be construed against either party solely as a result of the
drafting thereof.
16. Amendments. No amendment, modification, or assignment of this
Agreement shall be valid unless made in a writing signed by the parties.
17. Due Authorization, Etc. The parties represent and warrant that the
execution, delivery, and performance of this Agreement are within their
respective powers, have been duly authorized by all necessary action, do not
require any consent or other action by or in respect of or filing with, any
third party or governmental body or agency, and do not contravene, violate or
conflict with, or constitute a default under, any provision of applicable law
or regulation or charter or bylaws, or any agreement, judgment, injunction,
order, decree or other instrument binding upon the parties or any of them.
18. Survival. Sections 5(a), 6(b), 6(c), 7, 8, and 9 shall survive the
termination of this Agreement; and the licenses granted in Section 4(b) shall
survive for the periods set forth therein.
19. Counterparts. This Agreement may be executed in separate
counterparts, and by the Parties on separate counterparts, each of which when
so executed and delivered shall be an original, but all of which together
shall constitute one and the same instrument.
IN WITNESS WHEREOF, this Agreement has been entered in counterparts on the
date first set forth above and is effective upon its full execution.
Signed:
BION
BION ENVIRONMENTAL TECHNOLOGIES, INC.
By: /s/ Xxxxx Xxxxxxxx
Name: Xxxxx Xxxxxxxx
Title: Chief Executive Officer
Date: 12/9, 2002
AGRICULTURAL FOUNDATION
THE AGRICULTURAL FOUNDATION OF CALIFORNIA STATE UNIVERSITY, FRESNO
By: /s/ D.S. Adishan-Xxxxxx
Xxxxxxx X. Xxxxxxxx-Xxxxxx, Executive Director
Date: 12/5, 2002
Approved by:
/s/ Xxxx Xxxxxxx
Xxxx Xxxxxxx, Agricultural Operations
Date: 12/3, 2002
/s/ Xxx Xxxxxxx
Xxx Xxxxxxx, CATI
Date: 12/4, 2002
EXHIBITS
Exhibit A: Equipment
Exhibit B: Bion Equipment
Exhibit C: (i) Protocol for influent sampling, testing procedures, and
interpretation of data; etc.
(ii) Description of "Core Conditions," and "Stress Conditions"
(iii) Timing of two phases and related protocol
(iv) Research purposes
(v) General operating parameters during and following Term of
Agreement (e.g., include operating manual)
Exhibit D: Definition of Bion System