Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject the Contractor to penalties, to be determined by the County Manager, including but not limited to i) termination of this Agreement;
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject the Contractor to penalties, to be determined by the County Manager, including but not limited to i) termination of this Agreement; ii) disqualification of the Contractor from bidding on or being awarded a County contract for a period of up to 3 years; iii) liquidated damages of $2,500 per violation; iv) imposition of other appropriate contractual and civil remedies and sanctions, as determined by the County Manager. To effectuate the provisions of this section, the County Manager shall have the authority to examine Contractor’s employment records with respect to compliance with this paragraph and/or to set off all or any portion of the amount described in this paragraph against amounts due to Contractor under the Contract or any other Contract between Contractor and County. Contractor shall report to the County Manager the filing by any person in any court of any complaint of discrimination or the filing by any person of any and all charges with the Equal Employment Opportunity Commission, the Fair Employment and Housing Commission or any other entity charged with the investigation of allegations within 30 days of such filing, provided that within such 30 days such entity has not notified Contractor that such charges are dismissed or otherwise unfounded. Such notification shall include the name of the complainant, a copy of such complaint, and a description of the circumstance. Contractor shall provide County with a copy of their response to the Complaint when filed.
Violation of Non-discrimination provisions. Intentional violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and may result in termination of this Agreement, at the discretion of County, and /or legal action to recover from Town any Court-imposed damages incurred by County as a result of Town’s violation(s). To effectuate the provisions of this section, the County Manager may request authorization to examine Town’s employment records with respect to compliance with this paragraph, and Town shall not unduly withhold authorization.
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject the Consultant to penalties, including but not limited to: (a) termination of this Agreement; (b) disqualification of the Consultant from bidding on or being awarded a City contract for a period of up to 3 years; (c) liquidated damages of $2,500 per violation; and/or (d) imposition of other appropriate contractual and civil remedies and sanctions. To effectuate the provisions of this section, the City shall have the authority to examine Consultant's employment records with respect to compliance with this paragraph and/or to set off all or any portion of the amount described in this paragraph against amounts due to Consultant under this Agreement or any other agreement between Consultant and City. Consultant shall report to the City the filing by any person in any court of any complaint of discrimination or the filing by any person of any and all charges with the Equal Employment Opportunity Commission, the Fair Employment and Housing Commission or any other entity charged with the investigation of allegations within 30 calendar days of such filing, provided that within such 30 days such entity has not notified Consultant that such charges are dismissed or otherwise unfounded. Such notification shall include the name of the complainant, a copy of such complaint, and a description of the circumstance. Consultant shall provide City with a copy of their response to the complaint when filed.
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and may subject the Architect to penalties, to be determined by District’s Vice Chancellor of Administrative Services including, without limitation: (a) termination of this Agreement; (b) disqualification of the Architect from bidding on or being awarded a District contract for a period of up to 3 years; (c) liquidated damages of $2,500 per violation; and/or (d) imposition of other appropriate contractual and civil remedies and sanctions, as determined by the Vice Chancellor of Administrative Services. To effectuate the provisions of this section, the Vice Chancellor shall have the authority to examine Architect’s employment records with respect to compliance with this paragraph and/or to set off all or any portion of the amount described in this paragraph against amounts due to Architect under this Agreement or any other agreement between Architect and District. Architect shall report to the Vice Chancellor the filing by any person in any court of any complaint of discrimination or the filing by any person of any and all charges with the Equal Employment Opportunity Commission, the Fair Employment and Housing Commission or any other entity charged with the investigation of allegations within 30 days of such filing, provided that within such 30 days such entity has not notified Architect that such charges are dismissed or otherwise unfounded. Such notification shall include the name of the complainant, a copy of such complaint, and a description of the circumstance. Architect shall provide District with a copy of its response to the complaint when filed.
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject BHRS to penalties, to be determined by the HPSM Executive Director, including but not limited to:
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject the CM to penalties, including but not limited to: (a) termination of this Agreement; (b) disqualification of the CM from bidding on or being awarded a District contract for a period of up to 3 years; (c) liquidated damages of $2,500 per violation; and/or (d) imposition of other appropriate contractual and civil remedies and sanctions. To effectuate the provisions of this section, the District shall have the authority to examine Construction Manager's employment records with respect to compliance with this paragraph and/or to set off all or any portion of the amount described in this paragraph against amounts due to Construction Manager under this Agreement or any other agreement between Construction Manager and District. CM shall report to the District the filing by any person in any court of any complaint of discrimination or the filing by any person of any and all charges with the Equal Employment Opportunity Commission, the Fair Employment and Housing Commission or any other entity charged with the investigation of allegations within 30 calendar days of such filing, provided that within such 30 days such entity has not notified Construction Manager that such charges are dismissed or otherwise unfounded. Such notification shall include the name of the complainant, a copy of such complaint, and a description of the circumstance. CM shall provide District with a copy of their response to the complaint when filed.
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject EAI to penalties, to be determined by COUNTY’s County Manager, including but not limited to:
Violation of Non-discrimination provisions. In the event of a dispute between SIS and any person on the grounds of a violation of the non-discrimination provisions of paragraphs A - C of this Section, SIS shall use good faith efforts to attempt to resolve the dispute promptly. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and subject the Contractor to penalties, to be determined by the County Manager, including but not limited to:
Violation of Non-discrimination provisions. Violation of the non-discrimination provisions of this Agreement shall be considered a breach of this Agreement and may result in termination of this MOU, and /or legal action to recover any Court imposed damages incurred as a result of said violation(s). To effectuate the provisions of this section, the County Manager and Superintendent and SCVF may request authorization to examine employment records relating to this MOU, as the case may be with respect to compliance with this paragraph, and all parties shall not unduly withhold authorization.
