UNEXCUSED DELAY Sample Clauses

UNEXCUSED DELAY. Any Delay in the path of activities that is critical to Substantial Completion of the Work within the Contract Time and which Delay is not attributable to the City. An Unexcused Delay shall not entitle Contractor to either an extension of the Contract Time or an adjustment of the Contract Sum. To the extent an Unexcused Delay is concurrent with an Excused Delay, the Excusable Delay shall be conclusively deemed an Unexcused Delay.
AutoNDA by SimpleDocs
UNEXCUSED DELAY. 14.1.1 In the event that the Service Provider cannot meet the TAT commitment in the Section 7 of Annex 1- Airframe Maintenance Agreement, the Customer has the right to claim, and the Service Provider shall pay the amount agreed to in Section 21 of Annex 1 – Airframe Maintenance Agreement.
UNEXCUSED DELAY. Any Delay in the path of activities that is critical to Substantial Completion of the Work within the Contract Time and which Delay is not attributable to the City. An Unexcused Delay shall not entitle DBT to either an extension of the Contract Time or an adjustment of the Contract Sum. To the extent an Unexcused Delay is concurrent with an Excused Delay, the Excusable Delay shall be conclusively deemed an Unexcused Delay. WORK: All labor, materials, equipment, services, permits, fees, licenses and taxes, and all other things necessary for DBT to perform its obligations and to fully design and construct the Project, including, without limitation, any changes or additions requested by City, in accordance with the Contract Documents and all Applicable Code Requirements.
UNEXCUSED DELAY. 17.1.8. Following submission of a notice of delay, Judicial Council may determine whether Contractor is entitled to an extension of the Contract Time, and, if applicable, an increase in the Contract Price arising from any properly noticed and substantiated delay. In making that determination, Judicial Council will consider the following, based on the evidence submitted by Contractor and any investigations performed by Judicial Council:
UNEXCUSED DELAY. It is agreed that time is of the essence in the performance of the Design-Build Work. If Substantial Completion has not occurred on or before the Scheduled Substantial Completion Date, the Design-Builder shall be entitled to complete the Substantial Completion Date Conditions in order to secure Substantial Completion of the Project, subject to the City’s right to terminate this Design-Build Contract in accordance with subsection (D) of this Section. During the Extension Period, the Design-Builder shall pay delay liquidated damages, as and to the extent provided in subsection (C) of this Section.
UNEXCUSED DELAY. The term “Unexcused Delay” means a delay that does not entitle Contractor to an adjustment of the Contract Price and/or to an adjustment of the Contract Time, and for which the Judicial Council may impose Liquidated Damages.

Related to UNEXCUSED DELAY

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.

  • Unexcused Absences Employees who are absent without approved leave (with the exception of emergencies) may be subject to discipline, up to and including discharge from employment.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Concurrent Delay When the completion of the Work is simultaneously delayed by an excusable delay and a delay arising from a cause not designated as excusable, Contractor may not be entitled to a time extension for the period of concurrent delay.

  • Epidemic Failure Warranty Supplier warrants all Products against Epidemic Failure for a period of three years after DXC’s Acceptance. Epidemic Failure means the occurrence of the same failure, defect, or non-conformity with an Order in 2% or more of Products within any three-month period.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!