Transition Reports Clause Samples
Transition Reports. In order to assist Buyer in preparing for the transition of ownership upon Closing (and for such limited purpose only), from the date of this Agreement until Closing, Sellers shall provide to Buyer a monthly report no later than the 20th day of each month (relating to the prior month) for each the Company and its Subsidiaries, which report shall be substantially similar to, and prepared on substantially the same basis as the Financial Statements. For purposes of clarity, Buyer hereby agrees and acknowledges that Sellers shall deliver the aforementioned monthly reports solely as an accommodation to Buyer, that Sellers shall not be deemed to provide any warranties whatsoever as to the information contained in such reports or provided in any discussions of such reports and that Sellers shall have no liability of any type whatsoever relating to or arising from such reports or information, save in respect of fraud, willful misconduct or gross negligence by or on behalf of Sellers, the Company and/or its Subsidiaries.
Transition Reports. Service Levels and Service delivery results (as required).
Transition Reports. Delegating any powers it considers appropriate to the Service Delivery Committee. RESTRICTED - PROPRIETARY INFORMATION The information contained herein is for use by authorized employees of AT&T, Amdocs and their Affiliated Companies only, and is not for general distribution within those companies or for distribution outside those companies except by written agreement. Schedule E, Part 5 Governance Contract No. 02026409 Amendment No. 02026409.A.010
Transition Reports. TRANSITION GANTT CHART UPDATE. In conjunction with the Infrastructure Supplier, ▇▇ ▇he last day of each month during the Transition Period, Supplier shall provide PacifiCare with an updated hard copy Gantt chart detailing the current status of all transition tasks ("T▇▇▇▇▇CAL GANTT CHART UPDATE").
Transition Reports. CONTRACTOR shall submit periodic 26 transition status reports to CITY. CONTRACTOR shall provide these reports monthly 27 from October 2006 through February 2007; biweekly in March 2007 and April 2007; 28 and weekly from May 2007 through October 2007. In addition, CONTRACTOR shall 29 continue periodic reporting as requested by CITY June 30, 2008.
Transition Reports. (a) The Service Provider shall provide transition related reports in accordance with the schedule and frequency determined by the Transition Working Committee. In addition, the Service Provider shall provide such additional reports as OLG or its Transition Representative may reasonably request regarding the performance of the Service Provider Transition Activities and the then current status with respect to the timetable, in each case, as set forth in the Transition Plan. In any event, the Service Provider shall provide regular disclosure to OLG and the Transition Working Committee regarding the feasibility and achievement of the timetable set out in the Transition Plan.
(b) Promptly upon the Service Provider or the Service Provider Transition Representative receiving any information indicating that the Service Provider or OLG will not be able to perform any of the Transition Activities or meet the timetable set out in the Transition Plan, the Service Provider shall notify OLG and its Transition Representative in writing of such delays and shall work with the OLG Transition Representative to identify and implement specific measures to address such delays and mitigate the risks associated therewith, and in the case of the Day 1 Critical Transition Activities, alternative work-around plans or other means of achieving the Day 1 Critical Transition Activities.
(c) Promptly upon OLG or the OLG Transition Representative receiving any information indicating that OLG or the Service Provider will not be able to perform any of the Transition Activities or meet the timetable set out in the Transition Plan, OLG shall notify the Service Provider and its Transition Representative in writing of such delays and shall work with the Service Provider to identify and implement specific measures to address such delays and mitigate the risks associated therewith, and in the case of the Day 1 Critical Transition Activities, alternative work-around plans or other means of achieving the Day 1 Critical Transition Activities.
Transition Reports. If requested by Immunomedics, the Transition Managers will meet on a monthly basis (or more frequent, as mutually agreed) during the Term. On a monthly basis (whether or not the Transition Managers meet), Everest’s Transition Manager shall provide Immunomedics’ Transition Manager with a detailed description of all Transition Services performed during the previous month and an update with respect to Everest’s progress in the performance of Transition Services compared to the then- current timelines and budget set forth in the Transition Plan. Everest shall provide a final read-out to Immunomedics within thirty (30) calendar days following completion of all activities set forth in the Transition Plan.
Transition Reports. The Contractor must provide the State with a written Transition Report on a monthly basis (at a time reasonably required by the State) and at such other times as reasonably required by the State. Each Transition Report must:
(i) address progress against each of the Transition Obligations;
(ii) contain an estimate of when Operational Readiness is anticipated to be achieved; and
Transition Reports