Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
COMPLIANCE BY CONTRACTOR WITH LAWS AND REGULATIONS/ EQUAL EMPLOYMENT OPPORTUNITY 6.1 In connection with the performance of the Services, the Contractor shall comply with all applicable statutes, laws, regulations, and orders of federal, state, county or municipal authorities which impose any obligation or duty upon the Contractor, including, but not limited to, civil rights and equal employment opportunity laws. In addition, if this Agreement is funded in any part by monies of the United States, the Contractor shall comply with all federal executive orders, rules, regulations and statutes, and with any rules, regulations and guidelines as the State or the United States issue to implement these regulations. The Contractor shall also comply with all applicable intellectual property laws.
Benefit Level Two Health Care Network Determination Issues regarding the health care networks for the 2017 insurance year shall be negotiated in accordance with the following procedures:
CHILD AND DEPENDENT ADULT/ELDER ABUSE REPORTING CONTRACTOR shall establish a procedure acceptable to ADMINISTRATOR to ensure that all employees, agents, subcontractors, and all other individuals performing services under this Agreement report child abuse or neglect to one of the agencies specified in Penal Code Section 11165.9 and dependent adult or elder abuse as defined in Section 15610.07 of the WIC to one of the agencies specified in WIC Section 15630. CONTRACTOR shall require such employees, agents, subcontractors, and all other individuals performing services under this Agreement to sign a statement acknowledging the child abuse reporting requirements set forth in Sections 11166 and 11166.05 of the Penal Code and the dependent adult and elder abuse reporting requirements, as set forth in Section 15630 of the WIC, and shall comply with the provisions of these code sections, as they now exist or as they may hereafter be amended.
Minimum System Requirements The following summarizes the minimum office system requirements for all Contractors and Architect/Engineer to possess in order to participate. It is the responsibility of all Contractors and Architect/Engineer to possess these minimum requirements at no additional cost to Princeton University.
EDD Independent Subrecipient Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, Subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the State.” The term is further defined by the California Employment Development Department to refer specifically to independent Subrecipients. An independent Subrecipient is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
How Are Distributions from a Xxxxxxxxx Education Savings Account Taxed For Federal Income Tax Purposes? Amounts distributed are generally excludable from gross income if they do not exceed the beneficiary’s “qualified higher education expenses” for the year or are rolled over to another Xxxxxxxxx Education Savings Account according to the requirements of Section (4). “Qualified higher education expenses” generally include the cost of tuition, fees, books, supplies, and equipment for enrollment at (i) accredited post-secondary educational institutions offering credit toward a bachelor’s degree, an associate’s degree, a graduate-level or professional degree or another recognized post-secondary credential and (ii) certain vocational schools. In addition, room and board may be covered if the beneficiary is at least a “half-time” student. This amount may be reduced or eliminated by certain scholarships, qualified state tuition programs, HOPE, Lifetime Learning tax credits, proceeds of certain savings bonds, and other amounts paid on the beneficiary’s behalf as well as by any other deductions or credits taken for the same expenses. The definition of “qualified education expenses” includes expenses more frequently and directly related to elementary and secondary school education, including the purchase of computer technology or equipment or Internet access and related services. To the extent payments during the year exceed such amounts, they are partially taxable and partially non-taxable similar to payments received from an annuity. Any taxable portion of a distribution is generally subject to a 10% penalty tax in addition to income tax unless the distribution is (i) due to the death or disability of the beneficiary, (ii) made on account of a scholarship received by the beneficiary, or (iii) is made in a year in which the beneficiary elects the HOPE or Lifetime Learning credit and waives the exclusion from income of the Xxxxxxxxx Education Savings Account distribution. You may be allowed to take both the HOPE or Lifetime Learning credits while simultaneously taking distributions from Xxxxxxxxx Education Savings Accounts. However, you cannot claim a credit for the same educational expenses paid for through Xxxxxxxxx Education Savings Account distributions. To the extent a distribution is taxable, capital gains treatment does not apply to amounts distributed from the account. Similarly, the special five- and ten-year averaging rules for lump-sum distributions do not apply to distributions from a Xxxxxxxxx Education Savings Account. The taxable portion of any distribution is taxed as ordinary income. The IRS does not require withholding on distributions from Xxxxxxxxx Education Savings Accounts.
Payment for Labor and Materials The Contractor agrees and binds itself to pay for all labor done, and for all the materials used in the construction of the work to be completed pursuant to this contract.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
