Termination for Excessive Force Majeure Sample Clauses

Termination for Excessive Force Majeure. Customer may, upon written notice to Boeing, terminate this Contract immediately with respect to an unlaunched Satellite if and when THE SECURITIES EXCHANGE ACT. the delays to such Satellite due to a Force Majeure event for the claiming Party total, or will be likely to total, (***) consecutive days or more. Such termination by Customer for excessive Force Majeure shall be deemed as a Customer termination for convenience and the Parties shall proceed in accordance with Article 19 (Termination for Convenience). If Customer fails to exercise its right to terminate for excessive Force Majeure within thirty (30) days after Customer is entitled to terminate pursuant to this Article 13.2 (Termination for Excessive Force Majeure), such right to terminate shall be deemed waived.
Sample 1
AutoNDA by SimpleDocs
Termination for Excessive Force Majeure. Customer may, upon written notice to Boeing, terminate this Contract immediately with respect to an unlaunched Satellite if and when the delays to such Satellite due to a Force Majeure event for the claiming Party total, or will be likely to total, (***) consecutive days or more. Such termination by Customer for excessive Force Majeure shall be deemed as a Customer termination for convenience and the Parties shall proceed in accordance with Article 19 (Termination for Convenience). If INFORMATION IN THIS AGREEMENT. THIS INFORMATION HAS BEEN REDACTED AND DENOTED BY ASTERISKS (***). COPIES OF THE EXHIBIT CONTAINING THE REDACTED PORTIONS HAVE BEEN FILED SEPARATELY WITH THE COMMISSION SUBJECT TO A REQUEST FOR CONFIDENTIAL TREATMENT PURSUANT TO RULE 24B-2 UNDER THE SECURITIES EXCHANGE ACT. Customer fails to exercise its right to terminate for excessive Force Majeure within thirty (30) days after Customer is entitled to terminate pursuant to this Article 13.2 (Termination for Excessive Force Majeure), such right to terminate shall be deemed waived.
Sample 1
Termination for Excessive Force Majeure. Purchaser may, upon written notice to Contractor, terminate this Contract immediately with respect to unlaunched Satellites if and when the delays due to a Force Majeure event affecting Contractor total, or will be likely to total, six (6) consecutive months or more. In the event of such a termination, Contractor shall submit a final invoice to Purchaser within sixty (60) days after the termination date, which shall specify the amount due to Contractor from Purchaser pursuant to this Article 16.2. Purchaser shall pay such invoice, to the extent undisputed by Purchaser, within thirty (30) days after receipt. Notwithstanding the foregoing, Purchaser may dispute the amount of such invoice by giving Contractor notice of such dispute within thirty (30) days after receipt of the invoice. Contractor’s invoice shall be in an amount equal to the sum of: (i) for each Milestone accepted, the respective Milestone payment; and (ii) for each Milestone not accepted, a percentage of the Milestone payment, where such percentage equals the percentage of the Milestone completed, both less the sum of all amounts received by Contractor under this Contract. Iridium / Thales Alenia Space Confidential & Proprietary 61 Concurrently with such payment, Contractor shall promptly deliver in the manner and to the extent directed by Purchaser all completed Work and Work-in-Process to Purchaser or Purchaser’s designee (including all applicable licenses and warranties), subject to applicable governmental approvals, permits and licenses. Alternatively, Purchaser may request Contractor to purchase any such Work or Work-in-Process that Contractor agrees to re-use or use reasonable efforts to sell any such items, in which case Contractor shall remit any sales proceeds to Purchaser, less, where Contractor sells such items on behalf of Purchaser, a deduction for the Actual Costs of disposition (without mxxx-up, margin or administrative charges), resale and storage reasonably incurred by Contractor for such efforts. Payment of the amount payable by Purchaser under this Article shall constitute a total discharge of Purchaser’s liabilities to Contractor under this Contract. If this Contract is terminated as provided in this Article, Contractor shall protect and preserve property in the possession of Contractor in which Purchaser has an interest. Nothing in this Paragraph shall limit Purchaser’s rights to terminate this contract for convenience pursuant to Article 20. For the avoidance of doubt, Pu...
Sample 1
Termination for Excessive Force Majeure. Purchaser may, upon written notice to Contractor, terminate this Contract immediately with respect to unlaunched Satellites if and when the delays due to a Force Majeure event affecting Contractor total, or will be likely to total, [***…***] consecutive months or more.
Sample 1

Related to Termination for Excessive Force Majeure

  • Termination for Force Majeure In the event of a force majeure that lasts longer than thirty (30) days from the date that a Party claiming relief due to the force majeure event gives notice to the other Party, the Party not claiming relief under the force majeure event may terminate this Agreement upon written notice to the other Party. For the avoidance of doubt, the COVID-19 pandemic does not constitute a force majeure event.

  • Termination Payment for Force Majeure Event 34.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 90% (ninety per cent) of the Debt Due less Insurance Cover.

  • Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination for continuing Force Majeure Event Either Party may, by written notice to the other, terminate this Framework Agreement if a Force Majeure Event endures for a continuous period of more than one hundred and twenty (120) Working Days.

  • Termination for Catastrophe In event of Catastrophic Damage, this contract may be modified un- der B8.32, following rate redetermination under B3.32, or terminated under this Subsection. Such termination shall not be considered a termination under B8.34.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:

  • Duration/Termination 1. This License Agreement is concluded for an indefinite period, subject to termination in accordance with the provisions of article 6.2 and 6.3. Except based on these provisions, parties are not allowed to terminate the License Agreement.

  • Termination for fault 19.3.1 The Commonwealth may terminate this Agreement by notice where the Grantee has:

Time is Money Join Law Insider Premium to draft better contracts faster.