Suspension of Project. The Judicial Council may, in its sole discretion, suspend the Project by written Notice. The Criteria Architect will be compensated for Services performed prior to Notice of suspension. If the Project is suspended by the Judicial Council for less than one hundred and eighty (180) consecutive days, the Criteria Architect will reduce or suspend its services as directed by the Judicial Council. If the Project is suspended by the Judicial Council for more than one hundred and eighty (180) consecutive days, then when the Project is resumed, the schedule will be adjusted, and the Criteria Architect’s compensation will be equitably adjusted to provide for expenses incurred in the resumption of the Criteria Architect’s Services. Upon resumption of the Project after suspension, the Criteria Architect will take all reasonable efforts to maintain the same Project personnel.
Suspension of Project. The DISTRICT may suspend this AGREEMENT at any time without penalty by written notice to ARCHITECT of such suspension. The Suspension Notice shall set forth the reason for the suspension, the anticipated term of the suspension and shall be provided to the ARCHITECT not less than fifteen days prior to the suspension date. If the PROJECT is suspended by the DISTRICT for more than ninety consecutive days, the ARCHITECT shall be compensated for services satisfactorily performed prior to such suspension. When the PROJECT is resumed, the ARCHITECT'S compensation shall be equitably adjusted to provide for expenses incurred in the interruption and resumption of the ARCHITECT'S services.
Suspension of Project. The Council may, in its sole discretion, suspend the Project by written notice. The Construction Manager will be compensated for Services performed prior to notice of suspension.
Suspension of Project. Contractor may not suspend performance of any part of the Project except as directed and authorized by OMPA. OMPA may, at any time and in its sole discretion, suspend performance of all or part of the Project, as follows:
Suspension of Project. The Judicial Council may, in its sole discretion, suspend the Project by written Notice. The Construction Manager will be compensated for Services performed prior to Notice of suspension. If the Project is suspended by the Judicial Council for less than one hundred and eighty (180) consecutive days, the Construction Manager will reduce or suspend its services as directed by the Judicial Council. If the Project is suspended by the Judicial Council for more than one hundred and eighty (180) consecutive days, then when the Project is resumed, the schedule will be adjusted, and the Construction Manager’s compensation will be equitably adjusted to provide for expenses incurred in the resumption of the Construction Manager’s Services. Upon resumption of the Project after suspension, the Construction Manager will take all reasonable efforts to maintain the same Project personnel. CONSTRUCTION MANAGER’S INSURANCE General Requirements. General Requirements for Construction Manager's Insurance: Construction Manager must maintain the required insurance for its operations with an insurance company or companies that are rated “A-VII” or higher by A. M. Best’s key rating guide and are authorized to do business in the State of California. For all insurance policies required by this Article, the Construction Manager must declare any deductible or self-insured retention (SIR). Any deductible or SIR must be clearly stated on the appropriate certificate of insurance. If self-insured, the Construction Manager agrees to administer its self-insurance program in a commercially reasonable manner so as to ensure the availability of funds to cover losses required to be insured against by Construction Manager under the terms of this Article. Construction Manager, prior to commencement of the Work under this Agreement, must provide the Judicial Council with certificates of insurance and signed insurance policy endorsements, on forms acceptable to the Judicial Council, as evidence that the required insurance is in full force and effect. Where applicable, each certificate of insurance and signed insurance policy endorsement must specifically provide verification that the State of California, the Judicial Council of California, the Superior Court of California in the County in which the Project is located, and their respective elected and appointed officials, judges, officers, and employees have been added as additional insureds on the insurance policy being referenced. The Certificates...
Suspension of Project. The District may suspend this Agreement at any time without penalty by written notice to CM of such suspension. The Suspension Notice shall set forth the reason for the suspension, the anticipated term of the suspension and shall be provided to the CM not less than fifteen days prior to the suspension date. If the PROJECT is suspended by the DISTRICT for more than ninety consecutive days, the CM shall be compensated for services satisfactorily performed prior to such suspension. When the PROJECT is resumed, the CM's compensation shall be equitably adjusted to provide for expenses incurred in the interruption and resumption of the CM's services.
Suspension of Project. Water Service in the Event of Non-Payment of the Water Charge. A Project Participant that fails to pay its Water Charge or any portion thereof by the due date shall be in default of this Agreement and upon fifteen (15) days written notice, the Cooperative may suspend Project Water Service to a Project Participant and prohibit a Project Participant from using Water Offsets unless there is in mediation a good faith dispute or suspension of service compromises the health, safety, and welfare of the end water users. Suspension of Project Water Service to a Project Participant or prohibition of the use of Water Offsets by a Project Participant because of its failure to pay the Water Charge or any portion thereof shall not excuse the Project Participant from paying the Base Rate Charge, when it becomes due nor prohibit the Cooperative from continuing to charge interest on the unpaid amount. Upon payment of all outstanding Water Charges, including any interest, the Cooperative shall immediately resume Project Water Service to the Project Participant or immediately allow a Project Participant to use a Water Offset. The Cooperative’s decision to suspend Project Water Service to a Project Participant or to prohibit Water Offsets use by a Project Participant under this Section shall not be subject to the dispute resolution process in Section 17 and shall not be considered a default under Section 18. However, the Cooperative’s failure to resume Project Water Service or to allow a Project Participant to use Water Offsets upon payment of all outstanding Water Charges, including any interest, may constitute a default under Section 18 andshall be subject to the dispute resolution process specified in Section 17.
Suspension of Project. 15.1. Under the LP scheme, if any of the Specified Personnel on a Project is not able to perform the Project for a period or periods of time the Project may be suspended for a period or periods totalling up to 12 months. The duration of a Project may be extended for a period equal to the duration of the approved suspension(s). The Funds for the Project which would otherwise have been payable during the suspension period(s) will continue to be paid to the Administering Organisation during the suspension period(s) and the ARC will not supplement the Funds to cover any additional costs incurred as a result of the suspension or delay in finalisation of the Project.
Suspension of Project. The District may suspend this Agreement at any time without penalty by written notice to IT Consultant of such suspension. The Suspension Notice shall set forth the reason for the suspension, the anticipated term of the suspension and shall be provided to the IT Consultant not less than fifteen days prior to the suspension date. If the Project is suspended by the District for more than ninety consecutive days, the IT Consultant shall be compensated for services satisfactorily performed prior to such suspension. When the Project is resumed, the IT Consultant’s compensation shall be equitably adjusted to provide for expenses incurred in the interruption and resumption of the IT Consultant’s services.
Suspension of Project. Contractor may not suspend performance of any part of the Project except as directed and authorized by GRDA. GRDA may, at any time and in its sole discretion, suspend performance of all or part of the Project, using the following procedure:
