Submit Quarterly Status Reports Sample Clauses

Submit Quarterly Status Reports. (a) Beginning on the first day of the calendar quarter following the effective date of this Agreement, and continuing on the first day of each calendar quarter thereafter until Seller has achieved Initial Operation in accordance with Section 5.6, Seller shall submit to Edison a complete and accurate Quarterly Status Report in the form attached as Appendix C. Seller's Quarterly Status Report shall describe the progress of project development and shall include without limitation: (1) the current status of and schedule for project development;
Sample 1Sample 2
AutoNDA by SimpleDocs
Submit Quarterly Status Reports. (a) Beginning on the first day of the calendar quarter following the effective date of this Agreement, and continuing on the first day of each calendar quarter thereafter until Seller has achieved Initial Operation in accordance with Section 5.6, Seller shall submit to Edison a complete and accurate Quarterly Status Report in the form attached as Appendix C. Seller's Quarterly Status Report shall describe the progress of project development and shall include without limitation: (1) the current status of and schedule for project development; (2) Seller's progress since the last submitted Quarterly Status Report; and (3) an explanation of any changes to the project development schedule since Seller's last submitted Quarterly Status Report. If, in Edison's judgment, the scheduled development of the Generating Facility places Seller in jeopardy of missing a Project Development Milestone under this Section 5, Seller shall, upon request, provide a summary of the steps which Seller has taken and proposes to take to ensure timely Initial Operation of the Generating Facility.
Sample 1

Related to Submit Quarterly Status Reports

  • Monthly Status Reports 19.1.1 During the Operation Period, the Concessionaire shall, no later than 7 (seven) days after the close of each month, furnish to the Authority and the Independent Engineer a monthly report stating in reasonable detail the condition of the Project including its compliance or otherwise with the Maintenance Requirements, Maintenance Manual, Maintenance Program and Safety Requirements, and shall promptly give such other relevant information as may be required by the Independent Engineer or the Authority. In particular, such report shall separately identify and state in reasonable detail the defects and deficiencies that require rectification.

  • Quarterly Sales Reports The Contractor shall submit a completed Quarterly Sales Report electronically, in the required format, to the Department’s Contract Manager within thirty (30) calendar days after close of each quarter. The quarterly sales report can be found here: xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. The Contract Quarterly Sales Report will include all sales and orders associated with this Contract from Customers received during the reporting period. Initiation and submission of the Sales Report is the responsibility of the Contractor without prompting or notification from the DMS Contract Manager. Failure to provide the quarterly sales report will result in the imposition of financial consequences and may result in the Contractor being found in default and the termination of the Contract. Initiation and submission of the quarterly sales report are the responsibility of the Contractor without prompting or notification by the Department. Sales will be reviewed on a quarterly basis. If no sales are recorded during the period, the Contractor must submit a report stating that there was no activity. If no sales are recorded in two consecutive quarters, the Contractor may be placed in probationary status or the Department may terminate the Contract. Quarter 1 – (July-September) – due 30 calendar days after the close of the period Quarter 2 – (October-December) – due 30 calendar days after the close of the period Quarter 3 – (January-March) – due 30 calendar days after the close of the period Quarter 4 – (April-June) due 30 calendar days after the close of the period Exceptions may be made if a delay in submitting reports is attributable to circumstances that are clearly beyond the control of the Contractor. The burden of proof of unavoidable delay shall rest with the Contractor and shall be supplied in a written form and submitted to the Department. The Department reserves the right to request additional sales information as needed.

  • Status Reports DSI will issue to Depositor and Preferred Beneficiary a report profiling the account history at least semi-annually. DSI may provide copies of the account history pertaining to this Agreement upon the request of any party to this Agreement.

  • FINANCIAL STATUS REPORTS (FSRS Except as otherwise provided, for contracts with categorical budgets, Grantee shall submit quarterly FSRs to System Agency by the last business day of the month following the end of each quarter for System Agency review and financial assessment. Grantee shall submit the final FSR no later than forty-five (45) calendar days following the end of the applicable term.

  • Quarterly Progress Reports The goal of this task is to periodically verify that satisfactory and continued progress is made towards achieving the objectives of this Agreement on time and within budget. The objectives of this task are to summarize activities performed during the reporting period, to identify activities planned for the next reporting period, to identify issues that may affect performance and expenditures, and to form the basis for determining whether invoices are consistent with work performed. The Recipient shall: • Prepare a Quarterly Progress Report which summarizes all Agreement activities conducted by the Recipient for the reporting period, including an assessment of the ability to complete the Agreement within the current budget and any anticipated cost overruns. Progress reports are due to the CAM the 10th day of each January, April, July, and October. The Quarterly Progress Report template can be found on the ECAMS Resources webpage available at xxxxx://xxx.xxxxxx.xx.xxx/media/4691. Product: • Quarterly Progress Reports

  • Contract Quarterly Sales Reports The Contractor shall submit complete Quarterly Sales Reports to the Department’s Contract Manager within 30 calendar days after the close of each State fiscal quarter (the State’s fiscal quarters close on September 30, December 31, March 31, and June 30). Reports must be submitted in MS Excel using the DMS Quarterly Sales Report Format, which can be accessed at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/ state_purchasing/vendor_resources/quarterly_sales_report_format. Initiation and submission of the most recent version of the Quarterly Sales Report posted on the DMS website is the responsibility of the Contractor without prompting or notification from the Department’s Contract Manager. If no orders are received during the quarter, the Contractor must email the DMS Contract Manager confirming there was no activity.

  • Monthly Statement The Contractor shall submit a statement to the Engineer at the end of each month, in a tabulated form approved by the Engineer, showing the amounts to which the Contractor considers himself to be entitled. The statement shall include the following items, as applicable; - the value of the Permanent Work executed up to the end of previous month - such an amount (not exceeding 75 percent of the value) as the Engineer may consider proper on account of materials for permanent work delivered by the Contractor in the site - such amount as the Engineer may consider fair and reasonable for any Temporary Works for which separate amounts are provided in the Bill of Quantities - adjustments under Clause 70 - any amount to be withheld under retention provisions of Sub-clause 60.3 - any other sum to which the Contractor may be entitled under the Contract If the Engineer disagrees with or cannot verify any part of the statement, the Contractor shall submit such further information as the Engineer may reasonably require and shall make such changes and corrections in the statement as may be directed by the Engineer. In cases where there is difference in opinion as to the value of any item, the Engineer’s view shall prevail.

  • Monthly Statements Each month we will send you a statement showing purchases, cash advances, payments, and credits made to your Account during the billing cycle, as well as your “New Balance”, any Finance Charge and any late charges. Your statement also will identify the minimum monthly payment you must make for that billing period and the date it is due. You agree to retain for statement verification copies of transaction slips resulting from each purchase, each advance, and other transactions on your Account. Unless you notify us of a billing error in accordance with the section entitled “Your Billing Rights”, you accept your monthly statement as an accurate statement of your Account with us.

  • Monthly Progress Reports During the Construction Period, the Concessionaire shall, no later than 7 (seven) days after the close of each month, furnish to the Authority and the Independent Engineer a monthly report on progress of the Construction Works and shall promptly give such other relevant information as may be required by the Independent Engineer.

  • Quarterly Financial Reports The School shall prepare and submit quarterly financial reports to the Commission within 45 days of the end of each fiscal year quarter.

Time is Money Join Law Insider Premium to draft better contracts faster.