{"component": "clause", "props": {"groups": [{"snippet_links": [{"key": "the-work", "type": "clause", "offset": [0, 8]}, {"key": "conformity-with", "type": "clause", "offset": [60, 75]}, {"key": "schedule-requirements", "type": "clause", "offset": [80, 101]}, {"key": "statement-of-work", "type": "clause", "offset": [130, 147]}, {"key": "all-deliverables", "type": "clause", "offset": [181, 197]}, {"key": "submitted-by", "type": "definition", "offset": [207, 219]}, {"key": "a-schedule", "type": "clause", "offset": [255, 265]}, {"key": "project-period", "type": "definition", "offset": [270, 284]}, {"key": "item-no", "type": "clause", "offset": [294, 301]}, {"key": "this-agreement", "type": "clause", "offset": [308, 322]}, {"key": "it-is-understood-and-agreed-that", "type": "definition", "offset": [324, 356]}, {"key": "delivery-of-the", "type": "clause", "offset": [361, 376]}, {"key": "the-contractor-shall", "type": "clause", "offset": [426, 446]}, {"key": "in-a-timely-manner", "type": "definition", "offset": [453, 471]}, {"key": "in-accordance-with", "type": "clause", "offset": [476, 494]}, {"key": "requirements-of-the", "type": "clause", "offset": [499, 518]}], "snippet": "The Work shall be performed as expeditiously as possible in conformity with the schedule requirements contained herein and in the Statement of Work. The draft and final versions of all deliverables shall be submitted by the dates specified in the Exhibit A Schedule and Project Period noted in Item No. 7 of this Agreement. It is understood and agreed that the delivery of the draft and final versions of such deliverables by the Contractor shall occur in a timely manner and in accordance with the requirements of the Exhibit A Schedule.", "size": 177, "samples": [{"hash": "emZSx2XzeOL", "uri": "/contracts/emZSx2XzeOL#schedule", "label": "Agreement", "score": 35.2316894531, "published": true}, {"hash": "2zFy4lA4F8F", "uri": "/contracts/2zFy4lA4F8F#schedule", "label": "Contract Agreement", "score": 35.1321220398, "published": true}, {"hash": "gD1Ld6DclIQ", "uri": "/contracts/gD1Ld6DclIQ#schedule", "label": "Contract Agreement", "score": 34.4656219482, "published": true}], "hash": "1b7324a45fb2480aced35bbe2e1c67c5", "id": 1}, {"snippet_links": [{"key": "the-design-professional", "type": "clause", "offset": [0, 23]}, {"key": "required-by", "type": "definition", "offset": [51, 62]}, {"key": "preliminary-design-and-construction-schedule", "type": "clause", "offset": [110, 154]}, {"key": "agrees-to", "type": "clause", "offset": [180, 189]}, {"key": "the-construction-documents", "type": "clause", "offset": [199, 225]}, {"key": "calendar-days", "type": "definition", "offset": [264, 277]}, {"key": "execution-of-this-contract", "type": "clause", "offset": [288, 314]}, {"key": "completion-of-construction", "type": "definition", "offset": [342, 368]}, {"key": "the-owner-and-design", "type": "clause", "offset": [406, 426]}], "snippet": "The Design Professional shall provide the services required by this Contract in conformance with the approved Preliminary Design and Construction Schedule. The Design Professional agrees to complete the Construction Documents not later than or not later than \u0007\u0003 \b calendar days following execution of this Contract. Individual Milestones for completion of construction documents will be mutually agreed by the Owner and Design Professional.", "size": 87, "samples": [{"hash": "f9PPKRL9EXo", "uri": "/contracts/f9PPKRL9EXo#schedule", "label": "Design Professional Services Contract", "score": 34.4833564758, "published": true}, {"hash": "22ANrFaPk7j", "uri": "/contracts/22ANrFaPk7j#schedule", "label": "Design Professional Services Contract", "score": 34.4467887878, "published": true}, {"hash": "isN0dYdqCsR", "uri": "/contracts/isN0dYdqCsR#schedule", "label": "Design Professional Services Contract", "score": 34.389503479, "published": true}], "hash": "9f7f2d6b9a63547399794c5a27874332", "id": 2}, {"snippet_links": [{"key": "of-the-essence", "type": "clause", "offset": [28, 42]}, {"key": "performance-of-this-contract", "type": "clause", "offset": [50, 78]}, {"key": "seller-shall", "type": "clause", "offset": [83, 95]}, {"key": "adhere-to", "type": "clause", "offset": [105, 114]}, {"key": "the-schedules", "type": "definition", "offset": [115, 128]}, {"key": "in-this-contract", "type": "clause", "offset": [139, 155]}, {"key": "failure-to-deliver", "type": "definition", "offset": [157, 175]}, {"key": "in-accordance-with", "type": "clause", "offset": [176, 194]}, {"key": "contract-schedule", "type": "clause", "offset": [199, 216]}, {"key": "breach-of-this", "type": "clause", "offset": [260, 274]}, {"key": "in-the-event-of", "type": "clause", "offset": [285, 300]}, {"key": "actual-delay", "type": "clause", "offset": [320, 332]}, {"key": "not-limited", "type": "clause", "offset": [348, 359]}, {"key": "labor-disputes", "type": "definition", "offset": [384, 398]}, {"key": "promptly-notify", "type": "definition", "offset": [418, 433]}, {"key": "in-writing", "type": "definition", "offset": [440, 450]}, {"key": "the-actions", "type": "clause", "offset": [484, 495]}, {"key": "recovery-schedule", "type": "definition", "offset": [577, 594]}, {"key": "by-buyer", "type": "clause", "offset": [620, 628]}, {"key": "no-additional-cost", "type": "clause", "offset": [668, 686]}, {"key": "to-buyer", "type": "definition", "offset": [687, 695]}, {"key": "prior-to-the", "type": "clause", "offset": [793, 805]}, {"key": "scheduled-delivery-dates", "type": "clause", "offset": [806, 830]}, {"key": "procurement-representative", "type": "definition", "offset": [882, 908]}], "snippet": "a. Time is and shall remain of the essence in the performance of this Contract and Seller shall strictly adhere to the schedules specified in this Contract. Failure to deliver in accordance with the Contract schedule, if unexcused, shall constitute a material breach of this Contract. In the event of any anticipated or actual delay, including but not limited to delays attributed to labor disputes, Seller shall: (i) promptly notify Buyer in writing of the reasons for the delay and the actions being taken to overcome or minimize the delay; (ii) provide Buyer with a written recovery schedule; and (iii), if requested by Buyer, ship via air or expedited routing, at no additional cost to Buyer, to avoid or minimize delay to the maximum extent possible.\nb. Seller shall not deliver Services prior to the scheduled delivery dates unless authorized in writing by \u2587\u2587\u2587\u2587\u2587\u2019s Authorized Procurement Representative.", "size": 62, "samples": [{"hash": "5AOOn6PYnYm", "uri": "/contracts/5AOOn6PYnYm#schedule", "label": "Purchase Agreement", "score": 28.0274982452, "published": true}, {"hash": "e2z6nW8TDFK", "uri": "/contracts/e2z6nW8TDFK#schedule", "label": "Purchase Agreement", "score": 25.3645343781, "published": true}, {"hash": "iMp1DIvBeej", "uri": "/contracts/iMp1DIvBeej#schedule", "label": "Purchase Agreement", "score": 23.7768650055, "published": true}], "hash": "18235831855b63ec1e96fa179294d040", "id": 5}, {"snippet_links": [{"key": "the-contractor-shall", "type": "clause", "offset": [0, 20]}, {"key": "on-december", "type": "clause", "offset": [39, 50]}, {"key": "all-services", "type": "definition", "offset": [72, 84]}, {"key": "by-november", "type": "clause", "offset": [85, 96]}, {"key": "other-items", "type": "clause", "offset": [118, 129]}, {"key": "in-accordance-with", "type": "clause", "offset": [162, 180]}, {"key": "detailed-schedule", "type": "clause", "offset": [185, 202]}, {"key": "any-order", "type": "definition", "offset": [229, 238]}, {"key": "effective-date-of-this-contract", "type": "clause", "offset": [257, 288]}, {"key": "not-completed", "type": "clause", "offset": [294, 307]}, {"key": "by-the-contractor", "type": "clause", "offset": [347, 364]}, {"key": "the-county", "type": "definition", "offset": [450, 460]}, {"key": "rights-and-obligations", "type": "clause", "offset": [463, 485]}, {"key": "to-the-extent", "type": "clause", "offset": [499, 512]}, {"key": "if-the-order", "type": "clause", "offset": [516, 528]}, {"key": "performance-period", "type": "definition", "offset": [566, 584]}], "snippet": "The CONTRACTOR shall commence services on December 1, 2020 and complete all services by November 30, 2021 Reports and other items shall be delivered or completed in accordance with the detailed schedule set forth in Exhibit \u201cA\u201d. Any order issued during the effective date of this contract, but not completed within that period, shall be completed by the CONTRACTOR within the time specified in the order. The contract shall govern the CONTRACTOR and the COUNTY\u2019S rights and obligations with respect to the extent as if the order were completed during the contract\u2019s performance period.", "size": 66, "samples": [{"hash": "lWnCrH4hp0Z", "uri": "/contracts/lWnCrH4hp0Z#schedule", "label": "Contract for Plumbing Services", "score": 24.2388782501, "published": true}, {"hash": "lNJwws0MuCZ", "uri": "/contracts/lNJwws0MuCZ#schedule", "label": "Contract", "score": 24.2388782501, "published": true}, {"hash": "abNQsGi3v5Y", "uri": "/contracts/abNQsGi3v5Y#schedule", "label": "Contract for Plumbing Services", "score": 24.2388782501, "published": true}], "hash": "1e4c9865ec5396f6a1106907aa32a137", "id": 3}, {"snippet_links": [{"key": "to-the-authority", "type": "clause", "offset": [38, 54]}, {"key": "task-order-proposal", "type": "definition", "offset": [64, 83]}, {"key": "satisfactorily-complete", "type": "definition", "offset": [126, 149]}, {"key": "the-contractor-shall", "type": "clause", "offset": [196, 216]}, {"key": "work-completed", "type": "clause", "offset": [255, 269]}, {"key": "required-by", "type": "definition", "offset": [293, 304]}, {"key": "approved-project-schedule", "type": "definition", "offset": [309, 334]}, {"key": "rate-of-progress", "type": "definition", "offset": [343, 359]}, {"key": "amount-of-work", "type": "clause", "offset": [383, 397]}, {"key": "by-the-contractor", "type": "clause", "offset": [411, 428]}, {"key": "any-time", "type": "definition", "offset": [436, 444]}, {"key": "to-be-completed", "type": "clause", "offset": [522, 537]}, {"key": "the-authority-may", "type": "clause", "offset": [561, 578]}, {"key": "in-default", "type": "clause", "offset": [624, 634]}, {"key": "article-xi", "type": "definition", "offset": [650, 660]}, {"key": "section-2", "type": "definition", "offset": [662, 671]}, {"key": "termination-for-convenience", "type": "clause", "offset": [673, 700]}, {"key": "contract-no", "type": "clause", "offset": [782, 793]}, {"key": "one-week", "type": "definition", "offset": [805, 813]}, {"key": "the-notice-to-proceed", "type": "clause", "offset": [820, 841]}, {"key": "by-the-authority", "type": "clause", "offset": [855, 871]}, {"key": "of-the-authority", "type": "clause", "offset": [907, 923]}, {"key": "the-project", "type": "definition", "offset": [932, 943]}, {"key": "contractor-and-its-subcontractors", "type": "clause", "offset": [975, 1008]}, {"key": "shift-work-and-overtime", "type": "clause", "offset": [1034, 1057]}, {"key": "time-limits", "type": "definition", "offset": [1131, 1142]}, {"key": "approved-by", "type": "clause", "offset": [1184, 1195]}, {"key": "reasonable-cause", "type": "clause", "offset": [1222, 1238]}, {"key": "complete-the-work", "type": "clause", "offset": [1428, 1445]}, {"key": "remedial-work", "type": "definition", "offset": [1457, 1470]}, {"key": "final-completion-date", "type": "clause", "offset": [1499, 1520]}, {"key": "additional-compensation", "type": "definition", "offset": [1530, 1553]}, {"key": "it-is-understood-and-agreed-that", "type": "definition", "offset": [1555, 1587]}, {"key": "milestone-dates", "type": "clause", "offset": [1596, 1611]}, {"key": "and-the-contractor", "type": "clause", "offset": [1687, 1705]}, {"key": "the-guaranteed-maximum-price", "type": "clause", "offset": [1722, 1750]}, {"key": "all-costs", "type": "definition", "offset": [1751, 1760]}, {"key": "overtime-work", "type": "clause", "offset": [1777, 1790]}, {"key": "contractor-understands", "type": "clause", "offset": [1862, 1884]}, {"key": "facility-will", "type": "clause", "offset": [1905, 1918]}, {"key": "certain-areas", "type": "clause", "offset": [1949, 1962]}, {"key": "performance-of-the-work", "type": "clause", "offset": [2032, 2055]}, {"key": "a-day", "type": "definition", "offset": [2084, 2089]}, {"key": "day-basis", "type": "definition", "offset": [2093, 2102]}, {"key": "satisfaction-of", "type": "clause", "offset": [2130, 2145]}, {"key": "in-accordance-with", "type": "clause", "offset": [2160, 2178]}, {"key": "work-day-schedule", "type": "definition", "offset": [2183, 2200]}, {"key": "continuing-operations", "type": "definition", "offset": [2209, 2230]}, {"key": "avoid-conflicts", "type": "clause", "offset": [2322, 2337]}, {"key": "other-users", "type": "definition", "offset": [2343, 2354]}, {"key": "contractor-must", "type": "clause", "offset": [2404, 2419]}, {"key": "contractors-and-subcontractors", "type": "definition", "offset": [2482, 2512]}, {"key": "no-delays", "type": "clause", "offset": [2525, 2534]}, {"key": "cooperate-with", "type": "clause", "offset": [2626, 2640]}, {"key": "the-authority-and-other", "type": "clause", "offset": [2641, 2664]}, {"key": "construction-requirements", "type": "definition", "offset": [2700, 2725]}, {"key": "other-public-agencies", "type": "clause", "offset": [2742, 2763]}, {"key": "other-parties", "type": "definition", "offset": [2808, 2821]}, {"key": "other-infrastructure", "type": "clause", "offset": [2841, 2861]}, {"key": "other-improvements", "type": "definition", "offset": [2866, 2884]}, {"key": "affected-by", "type": "definition", "offset": [2898, 2909]}, {"key": "the-construction", "type": "clause", "offset": [2910, 2926]}, {"key": "from-time-to-time", "type": "clause", "offset": [2988, 3005]}, {"key": "duration-of-this-contract", "type": "clause", "offset": [3017, 3042]}, {"key": "the-contractor-and-the", "type": "clause", "offset": [3085, 3107]}, {"key": "work-activities", "type": "clause", "offset": [3136, 3151]}, {"key": "directly-or-indirectly", "type": "clause", "offset": [3243, 3265]}, {"key": "work-interruption", "type": "clause", "offset": [3299, 3316]}, {"key": "labor-dispute", "type": "definition", "offset": [3326, 3339]}, {"key": "epidemic-or-pandemic", "type": "clause", "offset": [3362, 3382]}, {"key": "exercise-of-due-diligence", "type": "clause", "offset": [3452, 3477]}], "snippet": "The Contractor submitted its Schedule to the Authority with its Task Order proposal. It is the Contractor\u2019s responsibility to satisfactorily complete the entire Project within the time specified. The Contractor shall prosecute the Work so that the actual Work completed shall be not less than required by the approved Project Schedule. If the rate of progress is such that the total amount of Work accomplished by the Contractor within any time mentioned in the approved Project Schedule is less than the amount specified to be completed within such time, then the Authority may declare this Contract or any portion thereof in default as provided in Article XI, Section 2 \u201cTermination for Convenience\u201d herein. The Contractor shall commence performance of its obligations under this Contract no later than one week after the Notice to Proceed is delivered by the Authority. Contractor may, with the approval of the Authority, adjust the Project Schedule as the Work proceeds. Contractor and its subcontractors shall furnish sufficient shift work and overtime as necessary to not exceed, nor permit its Subcontractors to exceed, the time limits established by this Project Schedule, as approved by the Authority, except for reasonable cause as determined by the Authority. The Contractor and its Subcontractors shall anticipate and furnish sufficient coordination, scheduling, supervision, labor, overtime labor and shift work to complete the Work, including remedial work, if necessary, prior to the Final Completion Date, without additional compensation. It is understood and agreed that certain milestone dates included in the Contractor's schedule will be relied upon by the Authority and the Contractor has included in the Guaranteed Maximum Price all costs for shift work, overtime work, additional forces and resources to achieve those milestone dates. The Contractor understands and agrees that the Facility will remain occupied and in use in certain areas and at times as determined by the Authority and Metra throughout the performance of the Work and the Contractor shall on a day-to-day basis coordinate its Work to the satisfaction of the Authority in accordance with the Work Day Schedule and the continuing operations of the Authority. The Contractor shall plan and coordinate its Work under this Contract to avoid conflicts with other users, lessees, licensees and patrons of the Facility. Contractor must coordinate its Work with the Authority, the Authority's other contractors and subcontractors, if any, so no delays or interference will occur in the Authority's projects or operations. The Contractor shall cooperate with the Authority and other contractors in the coordination of construction requirements and with Metra, other public agencies, utilities, transportation entities and all other parties either involved in other infrastructure and other improvements or otherwise affected by the construction requirements. The Authority may revise the Work Day Schedule from time to time during the duration of this Contract. In such event the Authority shall notify the Contractor and the Contractor shall revise its Work activities without additional compensation. Contractor shall not be liable for damage or delay caused directly or indirectly by embargoes, strikes, lockouts, work interruption or other labor dispute, fire, theft, floods, epidemic or pandemic, or any cause, beyond Contractor\u2019s control, which Contractor, by the exercise of due diligence and care, would not reasonably have been expected to foresee or avoid.", "size": 41, "samples": [{"hash": "hCRlwI27qGu", "uri": "/contracts/hCRlwI27qGu#schedule", "label": "Rapid Response Construction Services Contract", "score": 34.5169487, "published": true}, {"hash": "iSEqWNs9krg", "uri": "/contracts/iSEqWNs9krg#schedule", "label": "Master Contract for Rapid Response Construction Services", "score": 25.3750858307, "published": true}, {"hash": "glMDC5fPknr", "uri": "/contracts/glMDC5fPknr#schedule", "label": "Master Contract for Rapid Response Construction Services", "score": 24.4661197662, "published": true}], "hash": "932eea8d1b67e3b85dd4d271b9afdd3d", "id": 10}, {"snippet_links": [{"key": "developer-shall", "type": "clause", "offset": [0, 15]}, {"key": "to-district", "type": "clause", "offset": [24, 35]}, {"key": "construction-manager", "type": "definition", "offset": [37, 57]}, {"key": "a-schedule", "type": "clause", "offset": [73, 83]}, {"key": "the-contract-documents", "type": "definition", "offset": [104, 126]}, {"key": "as-required", "type": "clause", "offset": [131, 142]}, {"key": "construction-provisions", "type": "definition", "offset": [152, 175]}], "snippet": "Developer shall provide to District, Construction Manager, and Architect a schedule in conformance with the Contract Documents and as required in these Construction Provisions.", "size": 57, "samples": [{"hash": "7ATFWtsh7Sc", "uri": "/contracts/7ATFWtsh7Sc#schedule", "label": "General Construction Agreement", "score": 36.2792816162, "published": true}, {"hash": "ee2NkyGwuqJ", "uri": "/contracts/ee2NkyGwuqJ#schedule", "label": "Facilities Lease", "score": 36.1906509399, "published": true}, {"hash": "gdxEJxrEVcr", "uri": "/contracts/gdxEJxrEVcr#schedule", "label": "Facilities Lease", "score": 36.179851532, "published": true}], "hash": "3639de8c100b87ce39b91719e0ffe8ba", "id": 6}, {"snippet_links": [{"key": "the-services", "type": "definition", "offset": [0, 12]}, {"key": "the-project", "type": "definition", "offset": [57, 68]}, {"key": "in-accordance-with", "type": "clause", "offset": [105, 123]}], "snippet": "The Services will be undertaken in a manner that ensures the Project is completed timely and efficiently in accordance with the Project.", "size": 50, "samples": [{"hash": "kcOli5aN2ka", "uri": "/contracts/kcOli5aN2ka#schedule", "label": "Professional Services", "score": 32.8747024536, "published": true}, {"hash": "7g0xH9HajOh", "uri": "/contracts/7g0xH9HajOh#schedule", "label": "Professional Services Agreement", "score": 31.1309967041, "published": true}, {"hash": "iudwPLICbU6", "uri": "/contracts/iudwPLICbU6#schedule", "label": "Professional Services", "score": 31.022518158, "published": true}], "hash": "2d715a463a1c1ccba1ddc0e130a85d9f", "id": 7}, {"snippet_links": [{"key": "board-shall", "type": "definition", "offset": [11, 22]}, {"key": "the-arbitration-process", "type": "clause", "offset": [41, 64]}, {"key": "all-events", "type": "clause", "offset": [84, 94]}, {"key": "the-arbitration-hearing", "type": "clause", "offset": [125, 148]}, {"key": "after-receipt-of", "type": "clause", "offset": [197, 213]}, {"key": "notice-of-dispute", "type": "clause", "offset": [218, 235]}, {"key": "arbitration-administrator", "type": "clause", "offset": [243, 268]}], "snippet": "The Review Board shall assume control of the arbitration process and shall schedule all events as expeditiously as possible. The Arbitration Hearing shall commence within ninety (90) Business Days after receipt of the Notice of Dispute by the Arbitration Administrator.", "size": 43, "samples": [{"hash": "8Igv83XYklj", "uri": "/contracts/8Igv83XYklj#schedule", "label": "Purchase and Assumption Agreement (HCBF Holding Company, Inc.)", "score": 28.2991104126, "published": true}, {"hash": "lmFvgVuVEzY", "uri": "/contracts/lmFvgVuVEzY#schedule", "label": "Purchase and Assumption Agreement (FCB Financial Holdings, Inc.)", "score": 25.4654350281, "published": true}, {"hash": "8gEVDjyz4X", "uri": "/contracts/8gEVDjyz4X#schedule", "label": "Purchase and Assumption Agreement (FCB Financial Holdings, Inc.)", "score": 25.4654350281, "published": true}], "hash": "97c7e4533ab664547b4270cb77d23af9", "id": 9}, {"snippet_links": [{"key": "the-project", "type": "definition", "offset": [18, 29]}, {"key": "the-scope-of-services", "type": "clause", "offset": [43, 64]}, {"key": "according-to", "type": "definition", "offset": [84, 96]}], "snippet": "The components of the project described in the Scope of Services shall be completed according to Term, above.", "size": 63, "samples": [{"hash": "kfZhnmGcixt", "uri": "/contracts/kfZhnmGcixt#schedule", "label": "Personal Services Agreement", "score": 33.2644233704, "published": true}, {"hash": "dIApmflRVxz", "uri": "/contracts/dIApmflRVxz#schedule", "label": "Personal Services Agreement", "score": 33.0852050781, "published": true}, {"hash": "4aGBP4H07OJ", "uri": "/contracts/4aGBP4H07OJ#schedule", "label": "Personal Services Agreement", "score": 33.0645942688, "published": true}], "hash": "49bb7d7bfc2878aca1d12ed00af59f48", "id": 4}, {"snippet_links": [{"key": "consultant-shall", "type": "clause", "offset": [0, 16]}, {"key": "adhere-to", "type": "clause", "offset": [17, 26]}, {"key": "the-schedule", "type": "clause", "offset": [27, 39]}, {"key": "exhibit-a", "type": "definition", "offset": [53, 62]}, {"key": "city-shall", "type": "clause", "offset": [79, 89]}, {"key": "extensions-of-time", "type": "clause", "offset": [107, 125]}, {"key": "the-performance", "type": "clause", "offset": [130, 145]}, {"key": "governmental-reviews", "type": "clause", "offset": [177, 197]}, {"key": "work-product", "type": "definition", "offset": [214, 226]}, {"key": "unavoidable-delays", "type": "definition", "offset": [236, 254]}, {"key": "work-stoppages", "type": "clause", "offset": [340, 354]}, {"key": "labor-disturbances", "type": "clause", "offset": [365, 383]}, {"key": "on-behalf-of", "type": "definition", "offset": [401, 413]}, {"key": "officers-or-employees", "type": "clause", "offset": [428, 449]}, {"key": "city-of", "type": "clause", "offset": [493, 500]}, {"key": "project-schedule", "type": "clause", "offset": [508, 524]}, {"key": "agrees-to", "type": "clause", "offset": [529, 538]}, {"key": "efforts-to-perform", "type": "clause", "offset": [571, 589]}, {"key": "services-under-this-agreement", "type": "clause", "offset": [594, 623]}, {"key": "consistent-with", "type": "clause", "offset": [636, 651]}], "snippet": "CONSULTANT shall adhere to the schedule set forth in Exhibit A; provided, that CITY shall grant reasonable extensions of time for the performance of such services occasioned by governmental reviews of CONSULTANT\u2019s work product or other unavoidable delays; provided, further, that such unavoidable delay shall not include strikes, lockouts, work stoppages, or other labor disturbances conducted by, or on behalf of, CONSULTANT\u2019s officers or employees. CONSULTANT acknowledges the importance to CITY of CITY\u2019s Project schedule and agrees to put forth its best professional efforts to perform its services under this Agreement in a manner consistent with that schedule.", "size": 44, "samples": [{"hash": "3JuiGyQRZz2", "uri": "/contracts/3JuiGyQRZz2#schedule", "label": "Professional Services", "score": 33.6969108582, "published": true}, {"hash": "k5OPnhzRXIh", "uri": "/contracts/k5OPnhzRXIh#schedule", "label": "Professional Services", "score": 32.3333435059, "published": true}, {"hash": "lflFlDrM4lX", "uri": "/contracts/lflFlDrM4lX#schedule", "label": "Professional Services", "score": 32.2931022644, "published": true}], "hash": "2915f9f499dcdc8d716e72f66d2c5f64", "id": 8}], "next_curs": "ClESS2oVc35sYXdpbnNpZGVyY29udHJhY3Rzci0LEhZDbGF1c2VTbmlwcGV0R3JvdXBfdjU2IhFzY2hlZHVsZSMwMDAwMDAwYQyiAQJlbhgAIAA=", "clause": {"parents": [["representations-and-warranties-of-the-company", "REPRESENTATIONS AND WARRANTIES OF THE COMPANY"], ["performance", "Performance"], ["audit", "Audit"], ["employee-benefit-plans-and-compensation", "Employee Benefit Plans and Compensation"], ["miscellaneous", "Miscellaneous"]], "title": "Schedule", "size": 10354, "children": [["", ""], ["time-is-of-the-essence", "Time is of the Essence"], ["mobilization", "Mobilization"], ["work-schedule", "Work Schedule"], ["time-of-the-essence", "Time of the Essence"]], "id": "schedule", "related": [["schedule-b", "Schedule B", "<strong>Schedule</strong> B"], ["pay-schedule", "Pay Schedule", "Pay <strong>Schedule</strong>"], ["schedule-c", "Schedule C", "<strong>Schedule</strong> C"], ["time-schedule", "Time Schedule", "Time <strong>Schedule</strong>"], ["wage-schedule", "Wage Schedule", "Wage <strong>Schedule</strong>"]], "related_snippets": [], "updated": "2026-04-18T05:49:41+00:00", "also_ask": ["What are the essential elements that must be included in a Schedule to ensure clarity and enforceability?", "How can Schedules be strategically used or negotiated to allocate risk or obligations between parties?", "What are common drafting pitfalls or ambiguities in Schedules that could undermine the main agreement?", "How do courts typically interpret inconsistencies between a Schedule and the main contract body?", "Are there jurisdictional differences in the legal status or enforceability of Schedules attached to contracts?"], "drafting_tip": "Specify deadlines precisely to prevent misunderstandings, align milestones with deliverables to track progress, and include consequences for delays to ensure accountability.", "explanation": "The Schedule clause defines the timeline and key dates for the performance of obligations under the agreement. It typically outlines milestones, deadlines, and the sequence of deliverables or services, ensuring all parties are aware of when specific actions must occur. By clearly setting out these timeframes, the clause helps coordinate activities, manage expectations, and prevent disputes related to timing or delays."}, "json": true, "cursor": ""}}