{"component": "clause", "props": {"groups": [{"snippet_links": [{"key": "the-architect", "type": "clause", "offset": [15, 28]}, {"key": "the-contract-documents", "type": "definition", "offset": [47, 69]}, {"key": "engineering-surveys", "type": "definition", "offset": [74, 93]}, {"key": "to-establish", "type": "definition", "offset": [104, 116]}, {"key": "for-construction", "type": "clause", "offset": [151, 167]}, {"key": "contractor-to", "type": "clause", "offset": [222, 235]}, {"key": "the-work", "type": "definition", "offset": [249, 257]}, {"key": "contractor-shall", "type": "clause", "offset": [259, 275]}, {"key": "responsible-for", "type": "clause", "offset": [279, 294]}, {"key": "no-changes", "type": "clause", "offset": [415, 425]}, {"key": "approval-of-owner", "type": "clause", "offset": [467, 484]}, {"key": "report-to", "type": "definition", "offset": [503, 512]}, {"key": "changes-in", "type": "definition", "offset": [638, 648]}, {"key": "qualified-personnel", "type": "definition", "offset": [803, 822]}], "size": 14, "snippet": "Owner, through the Architect, shall provide in the Contract documents the engineering surveys necessary to establish pre-construction reference points for construction which in Architect's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Architect whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel.", "samples": [{"hash": "gRc5papa7MC", "uri": "/contracts/gRc5papa7MC#reference-points", "label": "Construction Contract", "score": 26.7132110596, "published": true}, {"hash": "cl7WfNNa7oP", "uri": "/contracts/cl7WfNNa7oP#reference-points", "label": "Construction Agreement", "score": 25.1670093536, "published": true}, {"hash": "e2ZXpQ1mEMc", "uri": "/contracts/e2ZXpQ1mEMc#reference-points", "label": "Construction Agreement", "score": 25.069814682, "published": true}], "hash": "d34242eef73549226fd1425b2f8df549", "id": 1}, {"snippet_links": [{"key": "responsible-for", "type": "clause", "offset": [27, 42]}, {"key": "the-construction", "type": "clause", "offset": [54, 70]}, {"key": "by-owner", "type": "definition", "offset": [135, 143]}, {"key": "pursuant-to-paragraph", "type": "clause", "offset": [144, 165]}, {"key": "no-changes", "type": "clause", "offset": [192, 202]}, {"key": "approval-of-owner", "type": "clause", "offset": [244, 261]}, {"key": "report-to-owner", "type": "clause", "offset": [284, 299]}, {"key": "changes-in", "type": "definition", "offset": [415, 425]}, {"key": "qualified-personnel", "type": "definition", "offset": [580, 599]}], "size": 11, "snippet": "A. DESIGN/BUILDER shall be responsible for laying out the Construction and shall protect and preserve the reference points established by OWNER pursuant to paragraph 8.01.A.6.e and shall make no changes or relocations without the prior written approval of OWNER. DESIGN/BUILDER shall report to OWNER whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel.", "samples": [{"hash": "jPPuNpCi4Tk", "uri": "/contracts/jPPuNpCi4Tk#reference-points", "label": "Construction Contract (Show Me Ethanol, LLC)", "score": 19.0, "published": true}, {"hash": "2TlTnwtmVOG", "uri": "/contracts/2TlTnwtmVOG#reference-points", "label": "Design/Build Agreement (Advanced BioEnergy, LLC)", "score": 19.0, "published": true}, {"hash": "1DlpJvxFf7C", "uri": "/contracts/1DlpJvxFf7C#reference-points", "label": "Design/Build Agreement (Husker Ag  LLC)", "score": 19.0, "published": true}], "hash": "2a269dd4a461776d285b60b0e88ba377", "id": 2}, {"snippet_links": [{"key": "engineering-surveys", "type": "definition", "offset": [23, 42]}, {"key": "to-establish", "type": "definition", "offset": [43, 55]}, {"key": "for-construction", "type": "clause", "offset": [73, 89]}, {"key": "contractor-to", "type": "clause", "offset": [143, 156]}, {"key": "the-work", "type": "definition", "offset": [170, 178]}, {"key": "contractor-shall", "type": "clause", "offset": [180, 196]}, {"key": "responsible-for", "type": "clause", "offset": [200, 215]}, {"key": "no-changes", "type": "clause", "offset": [336, 346]}, {"key": "approval-of-owner", "type": "clause", "offset": [388, 405]}, {"key": "report-to-engineer", "type": "clause", "offset": [424, 442]}, {"key": "changes-in", "type": "definition", "offset": [558, 568]}, {"key": "qualified-personnel", "type": "definition", "offset": [723, 742]}], "size": 10, "snippet": "A. Owner shall provide engineering surveys to establish reference points for construction which in Engineer\u2019s judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel.", "samples": [{"hash": "gdbcfG2QxP8", "uri": "/contracts/gdbcfG2QxP8#reference-points", "label": "Construction Contract", "score": 36.1477966309, "published": true}, {"hash": "gYjg5Tdwr1a", "uri": "/contracts/gYjg5Tdwr1a#reference-points", "label": "Construction Contract", "score": 36.0908317566, "published": true}, {"hash": "bkzRwFTtTFE", "uri": "/contracts/bkzRwFTtTFE#reference-points", "label": "Construction Agreement", "score": 31.8844623566, "published": true}], "hash": "282473341a511c2adc552b5be32682cf", "id": 3}, {"snippet_links": [{"key": "engineering-surveys", "type": "definition", "offset": [23, 42]}, {"key": "to-establish", "type": "definition", "offset": [43, 55]}, {"key": "for-construction", "type": "clause", "offset": [73, 89]}, {"key": "the-work", "type": "definition", "offset": [172, 180]}, {"key": "contractor-shall", "type": "clause", "offset": [182, 198]}, {"key": "responsible-for", "type": "clause", "offset": [202, 217]}, {"key": "no-changes", "type": "clause", "offset": [338, 348]}, {"key": "approval-of-owner", "type": "clause", "offset": [390, 407]}, {"key": "report-to-engineer", "type": "clause", "offset": [426, 444]}, {"key": "changes-in", "type": "definition", "offset": [560, 570]}, {"key": "qualified-personnel", "type": "definition", "offset": [725, 744]}], "size": 9, "snippet": "A. OWNER shall provide engineering surveys to establish reference points for construction which in ENGINEER\u2019s judgment are necessary to enable CON- TRACTOR to proceed with the Work. CONTRACTOR shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of OWNER. CONTRACTOR shall report to ENGINEER whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel.", "samples": [{"hash": "9y0bfwLdqkI", "uri": "/contracts/9y0bfwLdqkI#reference-points", "label": "Maintenance Contract", "score": 29.4813804626, "published": true}, {"hash": "qBv7nbnZBN", "uri": "/contracts/qBv7nbnZBN#reference-points", "label": "Maintenance Contract", "score": 29.2723083496, "published": true}, {"hash": "hiki7pEsqYN", "uri": "/contracts/hiki7pEsqYN#reference-points", "label": "Maintenance Contract", "score": 29.2723083496, "published": true}], "hash": "f12a712ee0ea40933ae1b8240a26d177", "id": 4}, {"snippet_links": [{"key": "the-contract-documents", "type": "definition", "offset": [35, 57]}, {"key": "lay-out", "type": "clause", "offset": [76, 83]}, {"key": "by-the-county", "type": "clause", "offset": [136, 149]}, {"key": "responsible-for", "type": "clause", "offset": [163, 178]}, {"key": "in-connection", "type": "definition", "offset": [196, 209]}, {"key": "the-contracts", "type": "clause", "offset": [256, 269]}, {"key": "upon-request", "type": "clause", "offset": [305, 317]}, {"key": "by-the-contractor", "type": "clause", "offset": [318, 335]}, {"key": "necessary-for", "type": "definition", "offset": [377, 390]}, {"key": "execution-of-the-work", "type": "clause", "offset": [395, 416]}, {"key": "bench-marks", "type": "clause", "offset": [418, 429]}, {"key": "control-of", "type": "definition", "offset": [493, 503]}, {"key": "the-contractor-shall", "type": "clause", "offset": [589, 609]}, {"key": "proper-execution", "type": "clause", "offset": [914, 930]}, {"key": "lines-and-grades", "type": "clause", "offset": [951, 967]}, {"key": "other-marks", "type": "clause", "offset": [986, 997]}, {"key": "at-any-time", "type": "clause", "offset": [1114, 1125]}, {"key": "for-any-reason", "type": "clause", "offset": [1131, 1145]}, {"key": "reasonable-time", "type": "clause", "offset": [1241, 1256]}, {"key": "in-advance", "type": "clause", "offset": [1257, 1267]}, {"key": "the-record", "type": "clause", "offset": [1441, 1451]}, {"key": "to-the-contractor", "type": "clause", "offset": [1524, 1541]}, {"key": "report-to-the-county", "type": "clause", "offset": [1570, 1590]}, {"key": "changes-in", "type": "definition", "offset": [1676, 1686]}], "size": 7, "snippet": "4.3.1 Unless otherwise provided in the Contract Documents, Contractor shall lay out its Work from base lines and benchmarks established by the County and shall be responsible for all measurements in connection therewith.\n4.3.2 Unless otherwise provided in the Contracts Documents, the County will furnish upon request by the Contractor, all location and limit marks reasonably necessary for the execution of the Work. Bench marks will also be established by the County at pertinent points for control of elevations and for grades unless otherwise provided in the Contract Documents.\n4.3.3 The Contractor shall, at its own expense, furnish all stakes, templates, patterns, platforms, equipment, and labor that may be required in setting and cutting, or laying out any part of the Work. After base lines and bench marks for the Work have been provided by the County, the Contractor shall be held responsible for the proper execution of the Work to such lines and grades and all stakes or other marks shall be preserved by the Contractor until removal is authorized. The County may require that the Work be suspended at any time when for any reason such marks cannot be properly followed.\n4.3.4 The Contractor shall keep the County informed, a reasonable time in advance, of the times and places at which it intends to do Work in order that lines and grades may be furnished, that inspection may be provided and that necessary measurements for the record may be made with the minimum of inconvenience to the County or of delay to the Contractor.\n4.3.5 The Contractor shall report to the County whenever any reference point is lost or destroyed, or requires relocation because of changes in grades or locations. The Contractor shall replace and accurately relocate all reference points so lost, destroyed or moved.", "samples": [{"hash": "kGx7VWIWZ8R", "uri": "/contracts/kGx7VWIWZ8R#reference-points", "label": "Construction Contract", "score": 19.0, "published": true}, {"hash": "j1Nn4QKWZ4t", "uri": "/contracts/j1Nn4QKWZ4t#reference-points", "label": "Construction Contract", "score": 19.0, "published": true}, {"hash": "eucKzjbxy7g", "uri": "/contracts/eucKzjbxy7g#reference-points", "label": "Construction Contract", "score": 19.0, "published": true}], "hash": "4ba9a5e48758fa38e70c7aa409aff70e", "id": 5}, {"snippet_links": [{"key": "hazardous-environmental-condition-at-site", "type": "clause", "offset": [11, 52]}, {"key": "other-bonds", "type": "definition", "offset": [190, 201]}, {"key": "licensed-sureties-and-insurers", "type": "clause", "offset": [317, 347]}, {"key": "certificates-of-insurance", "type": "clause", "offset": [481, 506]}, {"key": "liability-insurance", "type": "definition", "offset": [662, 681]}, {"key": "property-insurance", "type": "definition", "offset": [966, 984]}, {"key": "waiver-of-rights", "type": "clause", "offset": [1136, 1152]}, {"key": "receipt-and-application-of-insurance-proceeds", "type": "clause", "offset": [1308, 1353]}, {"key": "bonds-and-insurance", "type": "clause", "offset": [1474, 1493]}, {"key": "option-to", "type": "clause", "offset": [1495, 1504]}, {"key": "partial-utilization", "type": "clause", "offset": [1605, 1624]}, {"key": "acknowledgment-of", "type": "clause", "offset": [1626, 1643]}, {"key": "supervision-and-superintendence", "type": "clause", "offset": [1752, 1783]}, {"key": "working-hours", "type": "definition", "offset": [1919, 1932]}, {"key": "and-equipment", "type": "clause", "offset": [2099, 2112]}, {"key": "progress-schedule", "type": "definition", "offset": [2238, 2255]}, {"key": "patent-fees-and-royalties", "type": "clause", "offset": [2571, 2596]}, {"key": "laws-and-regulations", "type": "clause", "offset": [2915, 2935]}, {"key": "use-of-site-and-other-areas", "type": "clause", "offset": [3126, 3153]}, {"key": "safety-and-protection", "type": "clause", "offset": [3291, 3312]}, {"key": "safety-representative", "type": "clause", "offset": [3460, 3481]}], "size": 6, "snippet": "GC-13 4.06 Hazardous Environmental Condition at Site ................................................................................................... GC-13 5.01 Performance, Payment, and Other Bonds........................................................................................................ GC-14 5.02 Licensed Sureties and Insurers ......................................................................................................................... GC-15 5.03 Certificates of Insurance................................................................................................................................... GC-15 5.04 CONTRACTOR\u2019s Liability Insurance .............................................................................................................. GC-15 5.05 OWNER\u2019s Liability Insurance .......................................................................................................................... GC-16 5.06 Property Insurance ........................................................................................................................................... GC-16 5.07 Waiver of Rights................................................................................................................................................ GC-17 5.08 Receipt and Application of Insurance Proceeds .............................................................................................. GC-17 5.09 Acceptance of Bonds and Insurance; Option to Replace ................................................................................ GC-18 5.10 Partial Utilization, Acknowledgment of Property Insurer ............................................................................... GC-18 6.01 Supervision and Superintendence .................................................................................................................... GC-18 6.02 Labor; Working Hours ..................................................................................................................................... GC-18 6.03 Services, Materials, and Equipment ................................................................................................................. GC-18 6.04 Progress Schedule............................................................................................................................................. GC-19 6.05 Substitutes and \u201cOr-Equals\u201d............................................................................................................................ GC-19 6.07 Patent Fees and Royalties ................................................................................................................................ GC-21 6.08 Permits .............................................................................................................................................................. GC-21 6.09 Laws and Regulations GC-21 6.10 Taxes ................................................................................................................................................................. GC-22 6.11 Use of Site and Other Areas ............................................................................................................................. GC-22 6.13 Safety and Protection........................................................................................................................................ GC-22 6.14 Safety Representative ........................................................................................................................................ GC-23", "samples": [{"hash": "9y0bfwLdqkI", "uri": "/contracts/9y0bfwLdqkI#reference-points", "label": "Maintenance Contract", "score": 29.4813804626, "published": true}, {"hash": "qBv7nbnZBN", "uri": "/contracts/qBv7nbnZBN#reference-points", "label": "Maintenance Contract", "score": 29.2723083496, "published": true}, {"hash": "hiki7pEsqYN", "uri": "/contracts/hiki7pEsqYN#reference-points", "label": "Maintenance Contract", "score": 29.2723083496, "published": true}], "hash": "fe729349ffd66d680935a4633655e607", "id": 6}, {"snippet_links": [{"key": "the-contractor-shall", "type": "clause", "offset": [0, 20]}, {"key": "survey-control", "type": "clause", "offset": [54, 68]}, {"key": "bench-marks", "type": "clause", "offset": [91, 102]}, {"key": "line-of", "type": "definition", "offset": [138, 145]}, {"key": "by-the-contractor", "type": "clause", "offset": [166, 183]}, {"key": "necessary-for", "type": "definition", "offset": [233, 246]}, {"key": "the-construction", "type": "clause", "offset": [247, 263]}, {"key": "contractor-or-subcontractor", "type": "definition", "offset": [272, 299]}, {"key": "contract-unit-price", "type": "definition", "offset": [430, 449]}, {"key": "of-work", "type": "clause", "offset": [472, 479]}], "size": 5, "snippet": "The Contractor shall locate and reference the project survey control network and establish bench marks at appropriate intervals along the line of the project for use by the Contractor in establishing horizontal and vertical controls necessary for the construction. If the Contractor or subcontractor destroys these locations, the Contractor shall re-establish these points. The Contractor's stakeout work shall be included in the contract unit price for the various items of work to which it is incidental.", "samples": [{"hash": "jiracgatahd", "uri": "/contracts/jiracgatahd#reference-points", "label": "Professional Services", "score": 23.1656398773, "published": true}, {"hash": "iFXBJqrtq2X", "uri": "/contracts/iFXBJqrtq2X#reference-points", "label": "Professional Services", "score": 23.1656398773, "published": true}, {"hash": "jRezJGllrSz", "uri": "/contracts/jRezJGllrSz#reference-points", "label": "Professional Services", "score": 21.1656398773, "published": true}], "hash": "e501baa091ff47b39ea4b52dc4ad6a6a", "id": 7}, {"snippet_links": [{"key": "general-condition", "type": "clause", "offset": [0, 17]}, {"key": "part-f", "type": "definition", "offset": [19, 25]}, {"key": "article-7", "type": "definition", "offset": [27, 36]}], "size": 4, "snippet": "GENERAL CONDITION, PART F, ARTICLE 7, REFERENCE POINTS, \u201cReference Points\u201d is appended as follows:", "samples": [{"hash": "auqlPrjVIrX", "uri": "/contracts/auqlPrjVIrX#reference-points", "label": "Contract", "score": 26.4228801727, "published": true}, {"hash": "2MVwFYbElLF", "uri": "/contracts/2MVwFYbElLF#reference-points", "label": "Contract", "score": 24.2272415161, "published": true}, {"hash": "4aZvPfh0h0z", "uri": "/contracts/4aZvPfh0h0z#reference-points", "label": "Contract", "score": 24.0643386841, "published": true}], "hash": "801a74ceaf564f493ee1f9b1595e6a68", "id": 8}, {"snippet_links": [{"key": "engineering-surveys", "type": "definition", "offset": [25, 44]}, {"key": "for-construction", "type": "clause", "offset": [75, 91]}, {"key": "contractor-to", "type": "clause", "offset": [148, 161]}, {"key": "the-work", "type": "definition", "offset": [170, 178]}, {"key": "responsible-for", "type": "clause", "offset": [200, 215]}, {"key": "work-and", "type": "clause", "offset": [231, 239]}, {"key": "changes-to-the", "type": "definition", "offset": [306, 320]}, {"key": "consistent-with", "type": "definition", "offset": [520, 535]}, {"key": "professional-standards", "type": "definition", "offset": [536, 558]}, {"key": "based-on", "type": "definition", "offset": [599, 607]}, {"key": "notice-to-owner", "type": "clause", "offset": [648, 663]}, {"key": "qualified-personnel", "type": "definition", "offset": [848, 867]}], "size": 3, "snippet": "Contractor shall confirm engineering surveys establishing reference points for construction, which in Contractor\u2019s judgment are necessary to enable Contractor to perform the Work. Contractor shall be responsible for laying out the Work and shall protect and preserve such established reference points. Any changes to the established reference points shall require Contractor to update all Submittals (including those previously submitted) reflecting the new reference points. Such updating shall be undertaken promptly, consistent with Professional Standards, and without delaying Work that will be based on such updating. Contractor shall provide Notice to Owner whenever any reference point is lost or destroyed or requires relocation and shall be responsible for the accurate replacement or relocation of such reference points by professionally qualified Personnel.", "samples": [{"hash": "l0ZgZjikW0M", "uri": "/contracts/l0ZgZjikW0M#reference-points", "label": "Engineering, Procurement and Construction Agreement (Ada-Es Inc)", "score": 22.245721817, "published": true}, {"hash": "egHZs8Mk48k", "uri": "/contracts/egHZs8Mk48k#reference-points", "label": "Engineering, Procurement and Construction Agreement (Ada-Es Inc)", "score": 21.0, "published": true}, {"hash": "42JkU0B2VvS", "uri": "/contracts/42JkU0B2VvS#reference-points", "label": "Engineering, Procurement and Construction Agreement (Ada-Es Inc)", "score": 21.0, "published": true}], "hash": "c1d77f19848f1456b34859641b78db63", "id": 9}, {"snippet_links": [{"key": "the-architect", "type": "clause", "offset": [15, 28]}, {"key": "the-contract-documents", "type": "definition", "offset": [47, 69]}, {"key": "engineering-surveys", "type": "definition", "offset": [74, 93]}, {"key": "to-establish", "type": "definition", "offset": [104, 116]}, {"key": "contractor-to", "type": "clause", "offset": [229, 242]}, {"key": "demolition-work", "type": "clause", "offset": [260, 275]}, {"key": "contractor-shall", "type": "clause", "offset": [288, 304]}, {"key": "responsible-for", "type": "clause", "offset": [308, 323]}, {"key": "no-changes", "type": "clause", "offset": [455, 465]}, {"key": "approval-of-owner", "type": "clause", "offset": [507, 524]}, {"key": "report-to", "type": "definition", "offset": [554, 563]}, {"key": "changes-in", "type": "definition", "offset": [689, 699]}, {"key": "qualified-personnel", "type": "definition", "offset": [880, 899]}], "size": 3, "snippet": "Owner, through the Architect, shall provide in the Contract documents the engineering surveys necessary to establish pre-demolition reference points for demolition which in Architect's judgment are necessary to enable Demolition Contractor to proceed with the Demolition Work. Demolition Contractor shall be responsible for laying out the Demolition Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Demolition Contractor shall report to Architect whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and the Demolition Contractor shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel.", "samples": [{"hash": "fYuw7iQuVbv", "uri": "/contracts/fYuw7iQuVbv#reference-points", "label": "Demolition Contractor Services Agreement", "score": 25.7227916718, "published": true}, {"hash": "3xkfgae8yef", "uri": "/contracts/3xkfgae8yef#reference-points", "label": "Demolition Contractor Services Agreement", "score": 25.5694732666, "published": true}, {"hash": "cv0jmiuZv64", "uri": "/contracts/cv0jmiuZv64#reference-points", "label": "Demolition Contractor Services Agreement", "score": 25.2819976807, "published": true}], "hash": "01b59e872a1c2b52ee56fdcfd2510fbe", "id": 10}], "next_curs": "ClkSU2oVc35sYXdpbnNpZGVyY29udHJhY3RzcjULEhZDbGF1c2VTbmlwcGV0R3JvdXBfdjU2IhlyZWZlcmVuY2UtcG9pbnRzIzAwMDAwMDBhDKIBAmVuGAAgAA==", "clause": {"size": 103, "title": "Reference Points", "children": [["", ""], ["bond-requirements", "Bond Requirements"], ["construction-office", "Construction Office"], ["supervision-and-superintendence", "Supervision and Superintendence"], ["additional-insurance-and-bonds", "Additional Insurance and Bonds"]], "parents": [["miscellaneous", "MISCELLANEOUS"], ["indemnification", "Indemnification"], ["commencement-and-progress-of-the-work", "Commencement and Progress of the Work"], ["initial-acceptance-of-schedules", "Initial Acceptance of Schedules"], ["reuse-of-documents", "Reuse of Documents"]], "id": "reference-points", "related": [["reference-period", "Reference Period", "Reference Period"], ["number-resources-rate-center-areas-and-routing-points", "Number Resources, Rate Center Areas and Routing Points", "Number Resources, Rate Center Areas and Routing Points"], ["annual-percentage-rate", "Annual Percentage Rate", "Annual Percentage Rate"], ["measurement", "Measurement", "Measurement"], ["points", "Points", "Points"]], "related_snippets": [], "updated": "2025-07-24T06:48:53+00:00"}, "json": true, "cursor": ""}}