Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).
Punchlist Upon completion of the Performance Tests and prior to Substantial Completion of a Subproject, Owner and Contractor shall inspect the Subproject, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion of a Subproject to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion of such Subproject that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion of a Subproject sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of a Subproject after Substantial Completion of the Subproject or the Existing Facility and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion of a Subproject, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.
Escrow Deposit Concurrently with the execution and delivery of this Agreement, the Holder will deliver [the sum of ____________________ Dollars ($_____________) in lawful money of the United States of America by wire transfer of immediately available funds] [and] [[ ] Class A Trust Certificates] [and] [[ ] Class B Trust Certificates] in accordance with Section 14 of the Series Supplement] (the "Escrow Deposit"), to Escrow Agent to be held by Escrow Agent in escrow on the terms and conditions hereinafter provided. Escrow Agent hereby acknowledges receipt of the Escrow Deposit. Any cash amounts in the Escrow Deposit may be increased or decreased in accordance with the terms of Section 2.02(i)(vi) of the Warrant Agreement and the terms of this agreement will apply with equal force and effect to any such increased or decreased cash amounts in the Escrow Deposit.
Escrow Amount At the Closing, Seller and Buyer shall enter into an escrow agreement in the form attached hereto as Exhibit A (the “Escrow Agreement”), pursuant to which Seller shall deposit Ninety Thousand Two Hundred Forty-One Dollars ($90,241) (the “Escrow Amount”) with the Escrow Agent, which shall be held by the Escrow Agent in a segregated account as security for Seller’s indemnification obligations under Section 15 hereof. All interest accruing on the Escrow Amount shall be for the benefit of Seller. In the event Buyer makes a written claim or demand for indemnification under Section 15 hereof (an “Indemnification Claim”), and Seller does not dispute such Indemnification Claim, or is determined to be liable for and in respect of such Indemnification Claim by a court of competent jurisdiction, then the Escrow Agent promptly thereafter shall pay such Indemnification Claim in full to Buyer, all as more particularly provided in the Escrow Agreement. On the date which is six (6) months after the Closing Date (as defined in Section 1.06 hereof), fifty percent (50%) of the Escrow Amount then remaining in escrow under the Escrow Agreement and not then subject to an outstanding Indemnification Claim shall be paid by the Escrow Agent to Seller. The Escrow Agreement shall expire upon the termination of the Survival Period (as defined in Section 15.01 hereof), and immediately thereafter the Escrow Agent shall pay the portion, if any, of the then remaining Escrow Amount not in dispute to Seller; provided, however, that if prior to the expiration of the Survival Period, Buyer shall have made an Indemnification Claim or commenced litigation or any other proceeding on account of any such claim, the term of the Escrow Agreement shall be extended, and the Escrow Agent shall continue to hold in escrow the portion of the then Escrow Amount in dispute, in each case until the final resolution of such Indemnification Claim or litigation or proceeding relating thereto, all as more particularly provided in the Escrow Agreement.
Holdback Seller and Buyer agree that (i) a number of Buyer Shares valued at $650,000 (based on the Closing Buyer Share Price) (the “Share Consideration Holdback” or the “Holdback Amount”) shall be retained by Buyer and Buyer Parent until the date that is twelve (12) months following the Closing (the “Holdback Release Date”). The Holdback Amount shall constitute partial security for the satisfaction of claims made by Buyer or any Buyer Affiliate under Section 7.02. If, on the Holdback Release Date, there are any claims that have been notified to Seller and are being actively pursued by Buyer pursuant to and in accordance with Article VII (any such claims, “Unresolved Claims”), Buyer and Buyer Parent may retain, solely until such Unresolved Claims are resolved or satisfied, such portion of the Holdback Amount as it determines would be necessary to satisfy such Unresolved Claims (the “Retained Holdback Amount”), which Retained Holdback Amount shall equal the lesser of (a) the portion of the Holdback Amount then remaining or (b) the amount of the damages sought in connection with such claim(s), as determined in good faith by Buyer in accordance with the terms and conditions of Article VII. In accordance with this Section 1.05, Buyer Parent is authorized to instruct its transfer agent to include a notation on the Buyer Shares constituting the Share Consideration Holdback indicating that such Buyer Shares: (i) may not be sold, transferred or otherwise disposed of without Buyer Parent’s consent and (ii) are subject to the terms of this Agreement (including Buyer’s indemnification rights pursuant to Section 7.05(b)). Subject to the terms and conditions of this Section 1.05, Buyer Parent shall instruct its transfer agent to remove such notation (i) on the Holdback Release Date, with respect to the portion of the Holdback Amount in excess of the Retained Holdback Amount, if any, and (ii) on the date any Unresolved Claim is resolved or satisfied without exhausting the Retained Holdback Amount allocated, with respect to such portion of the Retained Holdback Amount that is in excess of the amount necessary to satisfy any Unresolved Claims (in each such instance, to the extent such Retained Holdback Amount is allocated to the Share Consideration Holdback).
Release of Escrow Fund (a) On the first Business Day after the date that is six (6) months from the closing of the Merger (the “Termination Date”), the Escrow Agent shall distribute and deliver to each Owner certificates representing shares of Parent Common Stock equal to the original number of shares placed in such Owner’s account, less that number of shares in such Owner’s account equal to the sum of (i) the number of shares applied in satisfaction of Indemnification Claims made prior to that date and (ii) the number of shares in the Pending Claims Reserve allocated to such Owner’s account, as provided in the following sentence. If, at such time, there are any Indemnification Claims with respect to which Notices have been received but which have not been resolved pursuant to Section 3 hereof or in respect of which the Escrow Agent has not been notified of, and received a copy of, a final determination (after exhaustion of any appeals) by a court of competent jurisdiction, as the case may be (in either case, “Pending Claims”), and which, if resolved or finally determined in favor of Parent, would result in a payment to Parent in excess of the Deductible, the Escrow Agent shall retain in the Pending Claims Reserve that number of shares of Parent Common Stock having a Fair Market Value equal to the dollar amount for which indemnification is sought in such Indemnification Claim in excess of the Deductible to the extent all Established Claims have not exceeded, in the aggregate, the Deductible, allocated pro rata from the account maintained on behalf of each Owner. The Parent Representative and the Holder Representative shall certify to the Escrow Agent the Fair Market Value to be used in calculating the Pending Claims Reserve, and the number of shares of Parent Common Stock to be retained therefor. Thereafter, if any Pending Claim becomes an Established Claim, the Parent Representative and the Holder Representative shall deliver to the Escrow Agent a Joint Notice directing the Escrow Agent to deliver to Parent the number of shares in the Pending Claims Reserve in respect thereof determined in accordance with paragraph 3(f) above and to deliver to each Owner the remaining shares in the Pending Claims Reserve allocated to such Pending Claim, all as specified in a Joint Notice. If any Pending Claim is resolved against Parent, the Parent Representative and the Holder Representative shall deliver to the Escrow Agent a Joint Notice directing the Escrow Agent to pay to each Owner its pro rata portion of the number of shares allocated to such Pending Claim in the Pending Claims Reserve.
Release of Escrow Funds The Escrow Funds shall be paid by the Escrow Agent in accordance with the following:
Holdback Amount Escrow Agent shall hold back in escrow from Seller’s net proceeds at Closing an amount equal to Seventy-Five Thousand Dollars ($75,000.00) (the “Holdback Amount”). The sole purpose for which the Holdback Amount may be applied is as to any amounts which Seller owes to Purchaser for post-Closing claims to the extent allowed and subject to any limitations set forth in this Agreement. For clarity, the Holdback Amount is intended as a source of payment, but not as a limitation of damages that may be claimed by Purchaser. Except as to any amounts claimed to be owed by Seller to Purchaser which amounts are specifically reflected in a lawsuit commenced against Seller within twelve (12) months after the Closing for damages based upon the post-Closing claim, Escrow Agent shall disburse the balance of the Holdback Amount to Seller immediately following the expiration of the twelve (12) month period. Prior to institution of any such lawsuit, Purchaser shall provide at least ten (10) days prior written notice to Seller, specifying the exact amount and nature of any such claim asserted by Purchaser against the Holdback Amount. Any lawsuit commenced against Seller must specifically set forth the exact amount which is claimed to be owed by Seller to Purchaser, and absent such specific amount being identified, Escrow Agent is authorized to release the entire Holdback Amount to Seller immediately following the expiration of the twelve month (12) month period post-Closing. Any portion of the Holdback Amount which Escrow Agent is entitled to retain pursuant to this Section 3.10 after the passage of the twelve (12) month period, shall continue to be held in escrow pending final and unappealable dismissal or judgment in the action or actions timely commenced by Purchaser or settled pursuant to a written agreement between Seller and Purchaser. If Purchaser obtains a final and unappealable judgment in any such action, Escrow Agent is directed to make a disbursement to Purchaser from the Holdback Amount retained in escrow in the amount of the judgment plus any interest, attorney’s fees, and costs to which it is entitled thereon upon presentation to Escrow Agent and Seller of the court order or other evidence of such final and unappealable judgment. Once all such actions are either finally or unappealably dismissed or a final and unappealable judgment is entered therein or settled pursuant to a written agreement between Seller and Purchaser, and any amount of damages due to Purchaser is paid, whether from the Holdback Amount or otherwise, Escrow Agent is directed to disburse to Seller any remaining balance of the Holdback Amount. The parties shall execute any additional escrow instructions not inconsistent with the foregoing reasonably required by Escrow Agent or either party relating to the Holdback Amount. Escrow Agent’s fees and costs for holding and disbursing the Holdback Amount shall be shared equally by Seller and Purchaser.
Escrow Fund In addition to the initial deposits with respect to Taxes and Insurance Premiums made by Borrower to Lender on the date hereof to be held by Lender in escrow, Borrower shall pay to Lender on the first day of each calendar month (a) one-twelfth of an amount which would be sufficient to pay the Taxes payable, or estimated by Lender to be payable, during the next ensuing twelve (12) months and (b) one-twelfth of an amount which would be sufficient to pay the Insurance Premiums due for the renewal of the coverage afforded by the Policies upon the expiration thereof (the amounts in (a) and (b) above shall be called the "Escrow Fund"). Borrower agrees to notify Lender immediately of any changes to the amounts, schedules and instructions for payment of any Taxes and Insurance Premiums of which it has or obtains knowledge and authorizes Lender or its agent to obtain the bills for Taxes directly from the appropriate taxing authority. The Escrow Fund and the payments of interest or principal or both, payable pursuant to the Note shall be added together and shall be paid as an aggregate sum by Borrower to Lender. Provided there are sufficient amounts in the Escrow Fund and no Event of Default exists, Lender shall be obligated to pay the Taxes and Insurance Premiums as they become due on their respective due dates on behalf of Borrower by applying the Escrow Fund to the payments of such Taxes and Insurance Premiums required to be made by Borrower pursuant to Sections 3.3 and 3.4 hereof. If the amount of the Escrow Fund shall exceed the amounts due for Taxes and Insurance Premiums pursuant to Sections 3.3 and 3.4 hereof, Lender shall, in its discretion, return any excess to Borrower or credit such excess against future payments to be made to the Escrow Fund. In allocating such excess, Lender may deal with the person shown on the records of Lender to be the owner of the Property. If the Escrow Fund is not sufficient to pay the items set forth in (a) and (b) above, Borrower shall promptly pay to Lender, upon demand, an amount which Lender shall reasonably estimate as sufficient to make up the deficiency. The Escrow Fund shall not constitute a trust fund and may be commingled with other monies held by Lender. Unless otherwise required by Applicable Laws (defined in Section 3.11), no earnings or interest on the Escrow Fund shall be payable to Borrower. Notwithstanding the foregoing, so long as (i) no Event of Default has occurred and is continuing, (ii) PETsMART or an Acceptable Replacement Tenant is not in default under the terms of the PETsMART Lease or an Acceptable Replacement Lease beyond any applicable notice and cure periods set forth therein, and (iii) PETsMART or an Acceptable Replacement Tenant is paying the Taxes pursuant to the terms of Section 3.4 hereof and Insurance Premiums in accordance with the terms of the last sentence of Section 3.3(b) hereof, directly pursuant to the terms hereof, and such Taxes are current, then Borrower shall not be required to make monthly payments into the Escrow Fund.
Initial Escrow Amount; Issuance of Escrow Receipts The Escrow Agent hereby directs the Underwriters to, and the Underwriters hereby acknowledge that on the date hereof they shall, irrevocably deliver to the Depositary on behalf of the Escrow Agent, an amount in U.S. dollars (“Dollars”) and immediately available funds equal to $289,358,000 for deposit on behalf of the Escrow Agent with the Depositary in accordance with Section 2.1 of the Deposit Agreement. The Underwriters hereby instruct the Escrow Agent, upon receipt by the Depositary of such sum from the Underwriters, to confirm such receipt by executing and delivering to the Pass Through Trustee an Escrow Receipt in the form of Exhibit A hereto (each, an “Escrow Receipt” and, collectively, the “Escrow Receipts”) (a) to be affixed by the Pass Through Trustee to each Certificate and (b) to evidence the same percentage interest (the “Escrow Interest”) in the Account Amounts (as defined below) as the Fractional Undivided Interest in the Pass Through Trust evidenced by the Certificate to which such Escrow Receipt is to be affixed. The Escrow Agent shall provide to the Pass Through Trustee for attachment to each Certificate newly issued under and in accordance with the Pass Through Trust Agreement an executed Escrow Receipt as the Pass Through Trustee may from time to time request Escrow and Paying Agent Agreement (Class A) (American Airlines 2019-1 Aircraft EETC) of the Escrow Agent. Each Escrow Receipt shall be registered by the Escrow Agent in a register (the “Register”) maintained by the Escrow Agent in the name of the same holder that is the holder of the Certificate to which such Escrow Receipt is attached and may not thereafter be detached from such Certificate to which it is to be affixed. No Escrow Receipt may be assigned or transferred except in connection with the assignment or transfer of the Certificate to which such Escrow Receipt is affixed. After the termination of the Deposit Agreement (or, if applicable, any Replacement Deposit Agreement), no additional Escrow Receipts shall be issued and the Pass Through Trustee shall request the return to the Escrow Agent for cancellation of all outstanding Escrow Receipts.
