Project Review A. Programmatic Allowances
Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.
Project Plans The Contractor: must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and for the purposes of subparagraph (i), must: prepare Project Plans based, where applicable, on the draft Project Plans lodged by the Contractor in its tender for the Contractor's Activities, and otherwise in accordance with the requirements of the Contract and submit them to the Contract Administrator so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event no later than the number of days specified in the Contract Particulars after the Award Date for each Project Plan; not commence any of the Contractor's Activities to which any Project Plan applies, unless the Contract Administrator has had the number of days specified in the Contract Particulars for each Project Plan to review the Project Plan and has not rejected the Project Plan; if any Project Plan is rejected, submit an amended Project Plan to the Contract Administrator; in any event, finalise each Project Plan so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event in accordance with the requirements of the Contract to the satisfaction of the Contract Administrator; after each Project Plan has been finalised: regularly review, update and amend each Project Plan in accordance with the process set out in each Project Plan (and otherwise at least on each anniversary of the Award Date); update or amend a Project Plan on request of the Contract Administrator; and continue to correct any defects in or omissions from a Project Plan (whether identified by the Contract Administrator or the Contractor), and submit an updated or amended Project Plan to the Contract Administrator, after which: the Contractor must continue to comply with the requirements of the then current Project Plan until the process in subparagraph (ii) has been completed in respect of the updated or amended Project Plan; and subsubparagraphs B - E will apply (to the extent applicable); and document and maintain detailed records of all: reviews, updates, amendments and submissions of each Project Plan; audits or other monitoring of each Project Plan; and training and awareness programs and communications provided to Contractor and subcontractor personnel in respect of each Project Plan (including each updated or amended Project Plan). The Contractor will not be relieved from compliance with any of its obligations under the Contract or otherwise at law or in equity as a result of: the implementation of, and compliance with, the requirements of any Project Plan; any direction by the Contract Administrator concerning a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; any audit or other monitoring by the Contract Administrator or anyone else acting on behalf of the Commonwealth of the Contractor's compliance with a Project Plan; or any failure by the Contract Administrator, or anyone else acting on behalf of the Commonwealth, to detect any defect in or omission from a Project Plan including where any such failure arises from any negligence on the part of the Contract Administrator or other person.
Development Plans 4.3.1 For each Licensed Indication and corresponding Licensed Product in the Field, Licensee will prepare and deliver to Licensor a development plan and budget (each a “Development Plan”). The initial Development Plans for each Licensed Indication will be delivered within […***…] after the Grant Date for such Licensed Indication.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Contract Area, including its abandonment.
Program Budget A) Contractor will expend funds received for operation of its program and services according to Contractor’s annual operating budget. The portions of said budget, which reflect services performed or money paid to Contractor pursuant to this Agreement shall be subject to the approval of the Human Services Agency. B) In the event Contractor determines a reasonable business necessity to transfer funding between personnel and operating expenses specified in the budget submitted to the Human Services Agency the following will apply: 1. Contractor will notify the Human Services Agency of transfers that in the aggregate are between ten percent (10%) and twenty percent (20%) of the maximum contract amount. 2. Contractor will further notify the Human Services Agency of transfers that in the aggregate equal or exceed twenty percent (20%) of the maximum contract amount. In the event the Director of the Human Services Agency or her designee determines said transfer of twenty percent (20%) or more is inconsistent with the goals and objectives of the County Alcohol and Drug Services, she may require a re-negotiation of the Agreement.
Annual Work Plans and Budgets The Recipient shall furnish to the Association as soon as available, but in any case not later than September 1 of each year, the annual work plan and budget for the Project for each subsequent year of Project implementation, of such scope and detail as the Association shall have reasonably requested, except for the annual work plan and budget for the Project for the first year of Project implementation, which shall be furnished no later than one (1) month after the Effective Date.
Development Budget Attached hereto as Exhibit "B" and incorporated herein by this reference is the Development Budget in an amount equal to $_____________. Owner acknowledges and represents that the attached Development Budget includes the total costs and expenses to acquire, develop, renovate and construct the Real Property and the Apartment Housing.
Marketing Plans Contractor and the Exchange recognize that Enrollees and other health care consumers benefit from efforts relating to outreach activities designed to increase heath awareness and encourage enrollment. The parties shall share marketing plans on an annual basis and with respect to periodic updates of material changes. The marketing plans of the Exchange and Contractor shall include proposed and actual marketing approaches, messaging and channels and provide samples of any planned marketing materials and related collateral as well as planned, and when completed, expenses for the marketing budget. The Contractor shall include this information for both the Exchange and the outside individual market. The Exchange shall treat all marketing information provided under this Section as confidential information consistent with Section 1.4.1. The obligation of the Exchange to maintain confidentiality of this information shall survive termination or expiration of this Agreement.
Program Review The Contracting Officer or other authorized government representative may hold semi- annual program review meetings. Such meetings will be held via telecom or video teleconferencing. However, the Government reserves the right to request a meeting in person. The meetings will include all BPA holders, representatives from prospective customer agencies, a combination of current and prospective customer agencies, or individual BPA holders. Some Federal Government Agencies and any approved State, Local and Tribal agencies may establish a central program management function. Such users may require their primary suppliers to participate in agency program review meetings on a periodic basis, at no additional cost to the Government.
