Project Personnel It is understood and agreed that the Project Director identified at Item 3, Page One of this Agreement shall be responsible for the overall supervision and conduct of the Work on behalf of the Contractor and that the persons described in the Statement of Work shall serve in the capacities described therein. Any change of Project Director by the Contractor shall be subject to the prior written approval of NYSERDA. Such approval shall not be unreasonably withheld, and, in the event that notice of approval or disapproval is not received by the Contractor within thirty (30) days after receipt of request for approval by NYSERDA, the requested change in Project Director shall be considered approved. In the event that NYSERDA requires additional time for considering approval, NYSERDA shall notify the Contractor within thirty (30) days of receipt of the request for approval that additional time is required and shall specify the additional amount of time necessary up to thirty (30) days.
Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history. (2) If Contractor receives information that a covered employee subsequently has a reported criminal history, Contractor will immediately remove the covered employee from contract duties and notify the District in writing within 3 business days. (3) Upon request, Contractor will provide the District with the name and any other requested information of covered employees so that the District may obtain criminal history record information on the covered employees. (4) If the District objects to the assignment of a covered employee on the basis of the covered employee's criminal history record information, Contractor agrees to discontinue using that covered employee to provide services at the District. Noncompliance or misrepresentation regarding this certification may be grounds for contract termination. None Texas Business and Commerce Code § 272 Requirements as of 9-1-2017 SB 807 prohibits construction contracts to have provisions requiring the contract to be subject to the laws of another state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract with such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The term also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLICABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WHEN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 7 5 Texas Government Code 2270 Verification Form Texas Government Code 2270 Verification Form Texas 2017 House Xxxx 89 has been signed into law by the governor and as of September 1, 2017 will be codified as Texas Government Code § 2270 and 808 et seq. The relevant section addressed by this form reads as follows: Texas Government Code Sec. 2270.002. PROVISION REQUIRED IN CONTRACT. A governmental entity may not enter into a contract with a company for goods or services unless the contract contains a written verification from the company that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract engaged by: ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx,XX,00000 I verify by this writing that the above-named company affirms that it (1) does not boycott Israel; and (2) will not boycott Israel during the term of this contract, or any contract with the above-named Texas governmental entity in the future. I further affirm that if our company’s position on this issue is reversed and this affirmation is no longer valid, that the above-named Texas governmental entity will be notified in writing within one (1) business day and we understand that our company’s failure to affirm and comply with the requirements of Texas Government Code 2270 et seq. shall be grounds for immediate contract termination without penalty to the above-named Texas governmental entity. AND Our company is not listed on and we do not do business with companies that are on the the Texas Comptroller of Public Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://xxxxxxxxxxx.xxxxx.xxx/purchasing/docs/foreign-terrorist.pdf I swear and affirm that the above is true and correct. YES
Administrative Controls The Contractor must have the following controls in place:
Stock Plan Administration Service Provider The Company transfers the Participant's Personal Information to Fidelity Stock Plan Services LLC, an independent service provider based in the United States, which assists the Company with the implementation, administration and management of the Plan (the “Stock Plan Administrator”). In the future, the Company may select a different Stock Plan Administrator and share the Participant's Personal Information with another company that serves in a similar manner. The Stock Plan Administrator will open an account for the Participant to receive and trade Shares acquired under the Plan. The Participant will be asked to agree on separate terms and data processing practices with the Stock Plan Administrator, which is a condition to the Participant’s ability to participate in the Plan. (c)
Service Provider The Service Provider also represents at the date this Agreement is entered into and any Service is used or provided:
Contractor Key Personnel The Contractor shall assign a Corporate OASIS Program Manager (COPM) and Corporate OASIS Contract Manager (COCM) as Contractor Key Personnel to represent the Contractor as primary points-of-contact to resolve issues, perform administrative duties, and other functions that may arise relating to OASIS and task orders solicited and awarded under XXXXX. Additional Key Personnel requirements may be designated by the OCO at the task order level. There is no minimum qualification requirements established for Contractor Key Personnel. Additionally, Contractor Key Personnel do not have to be full-time positions; however, the Contractor Key Personnel are expected to be fully proficient in the performance of their duties. The Contractor shall ensure that the OASIS CO has current point-of-contact information for both the COPM and COCM. In the event of a change to Contractor Key Personnel, the Contractor shall notify the OASIS CO and provide all Point of Contact information for the new Key Personnel within 5 calendar days of the change. All costs associated with Contractor Key Personnel duties shall be handled in accordance with the Contractor’s standard accounting practices; however, no costs for Contractor Key Personnel may be billed to the OASIS Program Office. Failure of Contractor Key Personnel to effectively and efficiently perform their duties will be construed as conduct detrimental to contract performance and may result in activation of Dormant Status and/or Off-Ramping (See Sections H.16. and H.17.).
Critical Illness b. On payment of a Claim under Benefit I, the cover will cease in respect for that Insured Person.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
DESIGNATED PERSONNEL The Contractor will provide the Designated Personnel listed below for the duration of the Contract at no charge to the State. Information regarding the Designated Personnel is set forth in Appendix D – Contractor and Reseller Information. Contractor must notify OGS within five (5) business days if any of the Designated Personnel change, and provide an interim contact person until the position is filled. Contractor may submit a Designated Personnel change by submission electronically via e-mail of a revised Appendix D – Contractor and Reseller Information to the OGS Contract Administrator. The Designated Personnel must have the authority to act on behalf of the Contractor: Account Manager The Account Manager is responsible for the overall relationship with the State during the course of the Contract and shall act as the central point of contact. Contract Administrator The Contract Administrator is responsible for the updating and management of the Contract on a timely basis. Sales Manager The Sales Manager is responsible for the overall relationship with the Authorized Users for matters relating to RFQs.
Project Employment 1. The Employer may appoint employees into project positions for which employment is contingent upon state, federal, local, grant, or other special funding of specific and of time-limited duration. The Employer will notify the employees, in writing, of the expected ending date of the project employment.
