PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries Latent defects liability period (Clause 27). Clause 27.0 is amended by the addition of the following clauses:
PRELIMINARIES AND GENERAL. Bill No. 1
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries Payment will be made for materials and goods:- Yes Dispute resolution :- Mediation (in terms of clause 40) followed by litigation. Arbitration rules as recommended by the Association of Arbitrators (SA) :- N/A Clause 42.2.5 Date on which possession of the site is intended to be given on :- 5 working days from the date of the letter of appointment to the Contractor. Clause 42.2.6 Period for the commencement of the works after the contractor takes possession of the site :- 2 Working days. Completion in Sections are required : NO Clause 42.2.7 Intended date of practical completion and the penalty per calendar day for the works as a whole :- To be advised. Penalty amount to be advised. Clause 42.2.8 Intended dates of practical completion and the penalties per calendar day for the works in sections : N/A Clause 42.2.9 The law applicable to this agreement shall be that of - South Africa. Carried to Collection R PRELIMINARIES AND GENERAL Bill No. 1 Preliminaries INSURANCES (Clause 42.3) Clause 42.3.1 Contract works insurance to be effected by Contractor for the sum of: Contract Sum plus 20% With a deductible of : to be determined by the Contractor but not greater than the maximum of R50,000.00 as stipulated by the Municipality. Clause 42.3.2 Supplementary insurance is required : Yes SASRIA insurance required to be effected by the Contractor for the amount of: Contract Sum plus 20% (with a deductable to be determined by the Insurance company issueing the policy). Clause 42.3.3 Public liability insurance to be effected by Contractor For the amount of: R 10 million With a deductible of: R 2,500.00 DOCUMENTS (Clause 42.4) Clause 42.4.1 Waiver of the contractor's lien is required :- YES Clause 42.4.2 Number of construction document copies to be supplied to the Contractor free of charge :- 3 Clause 42.4.3 Bills of Quantities drawn up in accordance with :- Standard System of Measuring Building Work - Seventh Edition including all amendments Carried to Collection R PRELIMINARIES AND GENERAL Bill No. 1 Preliminaries Clause 42.4.4 Number of days for submission of priced documents : 5 working days from the Letter of Appointment. Clause 42.4.5 JBCC Engineering General Conditions are to be included in the documents :- No Clause 42.4.6 The contract value is to be adjusted using CPAP:- NO SECTION B: PRELIMINARIES DEFINITIONS AND INTERPRETATION (B1) Definitions and Interpretation (B1) 1 F: ……….… V: ….……… T: ….……... Item DOCUMENTS (B2) Checking of documen...
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries The Contractor shall record in triplicate in a suitable A4 size triplicate book kept at the site, a daily record of work done, all site visits by the Principal Agent and other professional personnel and all events affecting the Works, such as progress, issue of plans, breakdown of machinery, etc. The labour, plant and material on site shall be recorded as well as work performed. Entries must be made by the Contractor and must be signed and forwarded to the Principal Agent for his counter- signature on a daily basis. Copies of these records shall be for the Architect, Quantity Surveyor and Contractor. 1 F: ……….… V: ….……… T: ….……... Item C7. Labour record At the end of each week the contractor shall provide the principal agent with a written record, in schedule form, reflecting the number and description of tradesmen and labourers employed by him and all subcontractors on the works each day. 2 F: ……….… V: ….……… T: ….……... Item
PRELIMINARIES AND GENERAL. Bill No. 1 Preliminaries The Council shall at all times have the right to summarily suspend the performance of the Contractor hereunder pending compliance by the Contractor with any requirement, regulation and/or direction referred to. The Council shall be entitled to set-off against any amount owed by the Council to the Contractor hereunder any loss or damage suffered by it as a result of the suspension of the Contractor's performance in the circumstances envisaged above. The Tenderer shall price for all necessary items to comply with the Occupational Health and Safety. 1 F: ……….… V: ….……… T: ….……... Item C16. Covid-19 Compliance Measures The Contractor is required to price for Covid 19 compliance and the pricing thereof shall be deemed to include all the mandatory requirements.
PRELIMINARIES AND GENERAL. NOTES All prices/rates to be net, excluding Value Added Tax PREAMBLES
PRELIMINARIES AND GENERAL. BUILDING AGREEMENT AND PRELIMINARIES The JBCC Principal Building Agreement (March 2014 Edition 6.1) prepared by the Joint Building Contracts Committee shall be the applicable building agreement, amended as hereinafter described The JBCC Principal Building Agreement contract data form an integral part of this agreement The Preliminaries revision 1 (February 2016) published by the Association of South African Quantity Surveyors for use with the JBCC Principal Building Agreement Edition 6.1 shall be deemed to be incorporated in these bills of quantities, amended as hereinafter described The contractor is deemed to have referred to the abovementioned documents for the full intent and meaning of each clause The clauses in the abovementioned documents are hereinafter referred to by clause number and heading only Where any item is not relevant to this agreement such item is marked N/A signifying "not applicable" Note : The amendments contained herein or in the single referenced Annexure constitute the only amendments to the standard JBCC Agreement that will apply. No other amendments shall be of any force or effect Should quantity surveyors wish to adhere to the system of inserting amendments, modifications, corrections or supplements to the JBCC documentation under the listed clause headings in Bill No. 1 (Preliminaries) then it is suggested that the following clause be inserted in the space provided in the contract data where changes made to the JBCC documentation are to be recorded: It is specifically agreed that the note below calling for amendments to the standard JBCC Agreement to be listed in the space provided in the contract data or recorded in 'the single referenced Annexure' shall not apply. Where standard clauses or alternatives are not entirely applicable to this agreement such amendments, modifications, corrections or supplements as will apply are given under each relevant clause heading in Bill No 1 (Preliminaries) and such amendments, modifications, corrections or supplements shall take precedence notwithstanding the note below and notwithstanding the provisions of clause 5.6 of the JBCC Principal Building Agreement Where standard clauses or alternatives are not entirely applicable to this agreement such amendments, modifications, corrections or supplements as will apply are given under each relevant clause heading and such amendments, modifications, corrections or supplements shall take precedence notwithstanding anything to the contrary containe...
PRELIMINARIES AND GENERAL. 19.5.4 The preparation of the practical completion list may include items identified by the representatives of the employer. F:........................ V:........................T:......................... Item 21 Clause 20.0 - Completion in Sections F:........................ V:........................T:......................... Item 22 Clause 21.0 - Defects Liability Period and Final completion Clause 21.8 is amended by the addition of the following to the end thereof: The contractor shall attend to defects during the defects liability period on a progressive basis, to the satisfaction of the principal agent, and will not be permitted to wait until the end of the defects liability period or until the amount of defects accumulates in order to attend to a comprehensive list of defects Clause 21.9 is amended by the addition of the following to the end thereof: The preparation of the final completion list may include items identified by the representatives of the employer F:........................ V:........................T:......................... Item 23 Clause 22.0 - Latent defects liability period F:........................ V:........................T:......................... Item 24 Clause 23.0 - Revision of date for practical completion Clause 23.0 is amended by the following:
PRELIMINARIES AND GENERAL. The JBCC Minor Works Agreement (Edition 5.2 – May 2018) prepared by the Joint Building Contracts Committee shall be the applicable building agreement, amended as hereinafter described The JBCC General Preliminaries (May 2018) published by the Joint Building Contracts Committee for use with the JBCC Minor Works Agreement (Edition 5.2 – May 2018) shall be deemed to be incorporated in this project specific preliminaries, amended as hereinafter described Tenderers are referred to the above mentioned documents for the full intent and meaning of each clause thereof (hereinafter referred to by heading and clause number only) for which such allowance must be made as may be considered necessary. Copies of both documents and a full set of the drawings are available for scrutiny at the Office of the Principal Agent. Where standard clauses or alternatives are not entirely applicable to this contract, such modifications, corrections or supplements as will apply are given under each relevant clause heading. Where any item is not relevant to this specific contract, such item is marked N/A (signifying Not Applicable). Carried Forward SECTION NO. 1 BILL NO. 1 PRELIMINARIES AND GENERAL Quantity Rate R Amount Brought Forward SECTION A:
