Political Force Majeure Events. Political force majeure events shall mean one or more of the following acts or events by or on account of GoI, GoCG or any other governmental agency:
i. Change in law; means a Material Adverse Change resulting from any of the following:
I. adoption, promulgation, modification, reinterpretation or repeal after the date of this Agreement by any Government authority of any statute, rule regulation, order, treaty, convention, directive, guidelines, policies; or
II. the imposition by any Government authority of any material condition in connection with the issuance, renewal or modification of any Approvals after the date of this Agreement which renders the performance by the Lessee of any of the terms of this Agreement impossible.
III. any Approval previously granted, ceasing to remain in full force and effect for reasons other than breach/violation by or the negligence of the Lessee or if granted for a limited period, being renewed on terms different from those previously stipulated Provided this Article 5.1.1 (c) shall not be triggered due to any increase in taxes, duties, cess and the like effected from time to time by any Government authority
ii. compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Lessee or of the Contractors;
iii. unlawful or unauthorized or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Lessee or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Lessee’s or any Contractor’s inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit;
iv. any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Lessee by or on behalf of such Contractor; or
v. any event or circumstance of a nature analogous to any of the foregoing. The Affected Party shall notify the other Party of the same setting out, inter alia, the following in reasonable detail:
I. The date and time the Affected Party was affected by the Force Majeure event.
II. The effect of suc...
Political Force Majeure Events. For purposes of Clause 15.1, Political Event shall mean one or more of the following acts or events by or on account GNCTD, DTIDCL or any other Governmental Agency:
(a) Change in Law;
(b) compulsory acquisition in national interest or expropriation of any project assests or the or rights of the Concessionaire/ Contractor (under any of the Project Agreements);
(c) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or
(d) any event or circumstance of a nature analogous to any of the foregoing.
Political Force Majeure Events. Political force majeure events shall mean one or more of the following acts or events by or on account of GoI, GoCG or any other governmental agency:
(i) Change in law;
(ii) Expropriation or compulsory acquisition by any governmental agency of any project assets or the rights of the Authorisee or of the contractors; and
(iii) Unlawful or unauthorized or without jurisdiction revocation of, refusal to renew or grant without valid cause any consent or approval required by the Authorisee or any of the contractors to perform their respective obligations under the project agreements. Provide that such delay, modification, denial, refusal or revocation did not result from the Authorisee or any contractor’s inability or failure to comply with any condition relating to grant, maintenance or renewal of such consents or permits.
Political Force Majeure Events. A Political Event shall mean one or more of the following acts or events by or on account of Government of India or any other Governmental Agency: expropriation or compulsory acquisition by any Governmental Agency of any Project Assets or rights of the Licensee or of the Contractors; or unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Licensee or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Licensee's or any Contractor's inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, licence, authorisation, no objection certificate, exemption, consent, approval or permit; Any decision or order of a court or tribunal which has the effect of restraining all or any part of the activities concerning the construction, operation or maintenance of the Project including the determination, levy, demand, collection, retention and appropriation of revenue; any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being any event or circumstance of a nature analogous to any of the foregoing.
Political Force Majeure Events. Political force majeure events shall mean one or more of the following acts or events by or on account of GoI, GoCG or any other governmental agency:
I. Change in law; means a Material Adverse Change resulting from any of the following:
a. adoption, promulgation, modification, reinterpretation or repeal after the date of this Agreement by any Government authority of any statute, rule regulation, order, treaty, convention, directive, guidelines, policies; or
b. the imposition by any Government authority of any material condition in connection with the issuance, renewal or modification of any Approvals after the date of this Agreement which renders the performance by the Lessee of any of the terms of this Agreement impossible.
c. any Approval previously granted, ceasing to remain in full force and effect for reasons other than breach/violation by or the negligence of the Lessee or if granted for a limited period, being renewed on terms different from those previously stipulated. Provided this Article 5.1.i (c) shall not be triggered due to any increase in taxes, duties, cess and the like effected from time to time by any Government authority
Political Force Majeure Events. 18.4.1. For purposes of Clause 18.1, Political Event shall mean one or more of the following acts or events by or on account Government Of India (GOI), the Authority, or any other Governmental Agency:
a) Change in Law, only if consequences thereof cannot be dealt with under and in accordance with the provisions of Article 23;
b) expropriation or compulsory acquisition by any Government Agency of any Project Assets or rights of the Concessionaire or of the Contractors; or
c) unlawful or unauthorised or without jurisdiction revocation of, or refusal to renew or grant without valid cause any consent or approval required by the Concessionaire to perform their respective obligations under the Project Agreement (other than a consent the obtaining of which is Condition Precedent) provided that such delay, modification, denial, refusal or revocation did not result from the Concessionaire’s inability or failure to comply with any condition relating to grant, maintenance or renewal of such consents or permits.
d) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor; or
e) any event or circumstance of a nature analogous to any of the foregoing.
Political Force Majeure Events hostilities (whether declared as war or not), riot, civil disturbance, revolution, rebellion, insurrection, act of terrorism, in each case involving the GoP or the GoPb or occurring in Pakistan; or
Political Force Majeure Events. The provisions of Section 15 of the Implementation Agreement shall govern this Agreement with respect to the consequences of a Political Force Majeure Event.
Political Force Majeure Events. Political force majeure events shall mean one or more of the following acts or events by or on account of GoI, GoCG or any other governmental agency:
(i) Change in law;
(ii) compulsory acquisition in national interest or expropriation of any Project Assets or rights of the Lessee or of the Contractors;
(iii) unlawful or unauthorized or without jurisdiction revocation of, or refusal to renew or grant without valid cause, any clearance, licence, permit, authorisation, no objection certificate, consent, approval or exemption required by the Lessee or any of the Contractors to perform their respective obligations under this Agreement and the Project Agreements; provided that such delay, modification, denial, refusal or revocation did not result from the Lessee’s or any Contractor’s inability or failure to comply with any condition relating to grant, maintenance or renewal of such clearance, license, authorization, no objection certificate, exemption, consent, approval or permit;
(iv) any failure or delay of a Contractor but only to the extent caused by another Political Event and which does not result in any offsetting compensation being payable to the Lessee by or on behalf of such Contractor; or
(v) any event or circumstance of a nature analogous to any of the foregoing. The Affected Party shall notify the other Party of the same setting out, inter alia, the following in reasonable detail:
Political Force Majeure Events. Political force majeure events shall mean one or more of the following acts or events by or on account of GoI, GoT or any other governmental agency:
