Owner's Approvals Sample Clauses

Owner's Approvals. The Subcontractor agrees that it will meet all of the requirements imposed by the Owner, Architect, or Owner's representative with respect to approval of subcontractors, materials and performance of this Subcontract. The failure to obtain these approvals shall constitute a breach of this Subcontract entitling the Contractor to exercise all available remedies herein.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Owner's Approvals. The Subcontractor agrees that it will meet all of the requirements imposed by the Owner, Architect, or Owner's representative with respect to approval of subcontractors, materials and performance of this Subcontract. Within one month after executing this Subcontract, the failure to obtain these approvals shall be a material breach of this Subcontract, which shall entitle the Contractor to terminate this Subcontract, without the forty-eight hours notice otherwise required by Article XIII. If this Subcontract is terminated for this reason, the Subcontractor agrees that, unless the Owner/Contractor Contract provides for an adjustment of the Subcontract Amount, it will not be entitled to receive any compensation or any reimbursement of costs in connection with this Subcontract, and shall be liable for the costs of reprocurement and completing the Work covered by this Subcontract, and any damages the Contractor incurred due to the Subcontractor's default.
Sample 1Sample 2Sample 3See All (6)
Owner's Approvals. Project Schedule. The attached project schedule identifies dates and durations for Owner’s approvals and actions. Failure of the Owner to adhere to this schedule shall be cause for time extensions to the Contract Time provided Design/Builder complies with the provisions of Article 16 of this Agreement.
Sample 1Sample 2Sample 3
Owner's Approvals. All approvals required from Owner shall be in writing. The approval by Owner of Deliverables shall not constitute a waiver by Owner of, or require Owner to relinquish, any of its rights under this Agreement, nor shall it relieve Architect or Architect’s Consultants or other Responsible Designers from any of their obligations or liability for the technical or professional adequacy of their services.
Sample 1Sample 2
Owner's Approvals. The CxA acknowledges and agrees that the Owner does not undertake to approve, or pass upon, or undertake to inquire into the adequacy, fitness, suitability, or correctness of any Commissioning conclusions. The CxA acknowledges and agrees that the approval or acceptance of the Commissioning services by the Owner is limited to the function of determining whether there has been compliance with instructions issued to the CxA regarding the Basic and Additional Services to be performed. The CxA agrees that no approval of any Commissioning services, program, document, video, photograph, or deliverables by any person, body, or agency shall relieve the CxA of responsibility for the adequacy, accuracy, fitness, suitability, and correctness of the services performed in accordance with sound and accepted principles applicable to the services.
Sample 1
Owner's Approvals. The Subcontractor agrees that it will meet all of the requirements imposed by the Owner, Architect, or Owner's representative with respect to approval of subcontractors, materials and performance of this Agreement. Within one month after executing this Agreement, the failure to obtain these approvals shall be a material breach of this Agreement, which shall entitle the Contractor to terminate this Agreement, without the forty-eight hours notice otherwise required by Article XIII. If this Agreement is terminated for this reason, the Subcontractor agrees that, unless the Owner/Contractor Contract provides for an adjustment of the contract sum, it will not be entitled to receive any compensation or any reimbursement of costs in connection with this Agreement, and shall be liable for the costs of reprocurement and completing the Work covered by this Agreement, and any damages the Contractor incurred due to the Subcontractor's default.
Sample 1
Owner's Approvals. Within twenty-four (24) hours following the execution and delivery of this Agreement, Sellers shall deliver true, correct and complete copies of (a) a shareholder consent and appraisal rights waiver executed by each of the shareholders of Xxxxxx-Xxxxxx and (b) a member consent executed by each of the members of F-B Building (such consents, the “Owners’ Approvals”).
Sample 1
AutoNDA by SimpleDocs
Owner's Approvals. Whenever in this Agreement Owner is requested or required to provide approvals of the Service or design documents prepared by A/E or A/E’s Consultants, it is understood and agreed that no comment, direction, instruction, review, request, consent or approval issued by Owner or any of its agents or representatives under any of the provisions of this Agreement shall be construed to limit, reduce or relieve the responsibility of A/E under this Agreement. No approval by Owner or request for revisions of any of the Drawings or Specifications shall constitute a warranty or representation by Owner or its agents as to the technical sufficiency or safety of the Project (save for those engaged by Owner specifically to be responsible for such technical sufficiency or safety, if any), or any of its component parts. Owner or Project Manager shall provide prompt written notice to A/E if they become aware of any fault or defect in the Project, including errors, omissions or inconsistencies in A/E’s Issued for Construction Documents, provided nothing in this Agreement shall be construed so as to require Owner or the Project Manager to determine the adequacy, accuracy, or sufficiency of the design, the Issued for Construction Documents, or the A/E’s services.
Sample 1
Owner's Approvals. 4.1 Owner approvals identified in this Exhibit D will be made in Owner’s reasonable business judgment, which approvals will not be unreasonably withheld, conditioned or delayed. If any item requiring Owner’s approval is timely disapproved by Owner, the procedure for preparation of the document and approval thereof will be repeated until the document is approved by Owner (subject to any additional rights or remedies provided herein).
Sample 1

Related to Owner's Approvals

  • Consents; Approvals No consents, filings (other than Federal and state securities filings relating to the issuance of the Shares pursuant to applicable exemptions from registration, which the Company hereby undertakes to make in a timely fashion), authorizations or other actions of any governmental authority are required to be obtained or made by the Company for the Company’s execution, delivery and performance of this Agreement which have not already been obtained or made or will be made in a timely manner following the Closing.

  • Consents, Approvals, Etc No consent, approval, authorization, filing with or order of any court or governmental agency or body is required in connection with the transactions contemplated herein or in the Trust Agreement, the Warrant Agreement, the Securities Subscription Agreement, the Private Placement Warrants Purchase Agreement, the Registration Rights Agreement, or the Insider Letter, except for the registration under the Act and the Exchange Act of the Securities, and such as may be required under the state securities or blue sky laws of any jurisdiction in connection with the purchase and distribution of the Securities by the Underwriters in the manner contemplated herein and in the Registration Statement, Statutory Prospectus and the Prospectus.

  • Consents, Licenses, Approvals, etc Lender shall have received copies of all consents, licenses and approvals, if any, required in connection with the execution, delivery and performance by Borrower, and the validity and enforceability, of the Loan Documents, and such consents, licenses and approvals shall be in full force and effect.

  • Consents, Approvals and Requests Unless otherwise specified in this Agreement, all consents and approvals, acceptances or similar actions to be given by either Party under this Agreement shall not be unreasonably withheld or delayed and each Party shall make only reasonable requests under this Agreement.

  • Approvals No authorization, approval or consent of any court, governmental body, regulatory agency, self-regulatory organization, or stock exchange or market or the stockholders of the Company is required to be obtained by the Company for the issuance and sale of the Securities to the Buyer as contemplated by this Agreement, except such authorizations, approvals and consents that have been obtained.

  • Consents, Approvals and Filings The Company and Evergreen will make ------------------------------- and cause their respective subsidiaries and, to the extent necessary, their other affiliates to make all necessary filings, as soon as practicable, including, without limitation, those required under the HSR Act, the Securities Act, the Exchange Act, and the Communications Act (including filing an application with the FCC for the transfer of control of the Company FCC Licenses and the Evergreen FCC Licenses, which the parties shall file as soon as practicable (and in any event not more than 30 days) after the date of this Agreement), in order to facilitate prompt consummation of the Merger and the other transactions contemplated by this Agreement. In addition, the Company and Evergreen will each use its best efforts, and will cooperate fully and in good faith with each other, (i) to comply as promptly as practicable with all governmental requirements applicable to the Merger and the other transactions contemplated by this Agreement and the Viacom Transaction, and (ii) to obtain as promptly as practicable all necessary permits, orders or other consents of Governmental Entities and consents of all third parties necessary for the consummation of the Merger and the other transactions contemplated by this Agreement and the Viacom Transaction, including without limitation, the consent of the FCC to the transfer of control of the Company FCC Licenses and the Evergreen FCC Licenses, and the transfer of any FCC licenses in connection with the Viacom Transaction. Each of the Company and Evergreen shall use its best efforts to promptly provide such information and communications to Governmental Entities as such Governmental Entities may reasonably request. Each of the parties shall provide to the other party copies of all applications in advance of filing or submission of such applications to Governmental Entities in connection with this Agreement and shall make such revisions thereto as reasonably requested by such other party. Each party shall provide to the other party the opportunity to participate in all meetings and material conversations with Governmental Entities.

  • Permits and Approvals Consultant shall obtain, at its sole cost and expense, all permits and regulatory approvals necessary in the performance of this Agreement. This includes, but shall not be limited to, encroachment permits and building and safety permits and inspections.

  • Governmental Approvals No authorization or approval or other action by, and no notice to or filing with, any Governmental Authority is required in connection with the due execution, delivery and performance by any Loan Party of any Loan Document to which it is or will be a party.

  • Authorization; Approvals The issuance of the Policy and the execution, delivery and performance of this Agreement and the Insurance Agreement have been duly authorized by all necessary corporate proceedings. No further approvals or filings of any kind, including, without limitation, any further approvals of or further filings with any governmental agency or other governmental authority, or any approval of the Insurer’s board of directors or stockholders, are necessary for the Policy, this Agreement and the Insurance Agreement to constitute the legal, valid and binding obligations of the Insurer.

  • Third Party Approvals (a) Subject to the terms and conditions of this Agreement, Parent and the Partnership and their respective Subsidiaries will cooperate and use their respective commercially reasonable efforts to prepare all documentation, to effect all filings, to obtain all permits, consents, approvals and authorizations of all Governmental Authorities and third parties necessary to consummate the transactions contemplated by this Agreement and to comply with the terms and conditions of such permits, consents, approvals and authorizations and to cause the Merger to be consummated as expeditiously as practicable. Each of Parent and the Partnership has the right to review in advance, and to the extent practicable each will consult with the other, in each case subject to applicable Laws relating to the exchange of information, with respect to, all material written information submitted to any third party or any Governmental Authorities in connection with the transactions contemplated by this Agreement. In exercising the foregoing right, each of the Parties agrees to act reasonably and promptly. Each Party agrees that it will consult with the Other Parties with respect to the obtaining of all material permits, consents, approvals and authorizations of all third parties and Governmental Authorities necessary or advisable to consummate the transactions contemplated by this Agreement, and each Party will keep the Other Parties apprised of the status of material matters relating to completion of the transactions contemplated hereby.

Time is Money Join Law Insider Premium to draft better contracts faster.