Owner Indemnity. Owner shall indemnify, defend and hold harmless Distribution Company and Distribution Company’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, a “Distribution Company Indemnified Party”) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party, including any such liabilities incurred by a Distribution Company Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Distribution Company Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Distribution Company Indemnified Party.
Owner Indemnity. Subject to the limitations of liability set forth in Section 9.2, Owner agrees to indemnify and hold Xxxxxx and Xxxxxx’x subconsultants and their Personnel harmless from Damages due to bodily injury (including death) or third-party tangible property damage to the extent caused by the negligent acts, errors, or omissions of Owner or any other party for whom Owner is legally liable, in the performance of Owner’s obligations under this Agreement.
Owner Indemnity. Owner shall indemnify, hold harmless and defend Contractor and all Contractor Parties from and against the following:
Owner Indemnity. Owner shall indemnify, defend and hold harmless Purchaser and Purchaser’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives and permitted successors and assigns (each, a “Purchaser Indemnified Party”) from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities or damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party, including any such liabilities incurred by a Purchaser Indemnified Party under the PPA, and arising out of the negligence, willful misconduct or criminal misconduct of Owner or its agents, including such claims, costs and expenses arising from environmental liabilities or from property damage, in each case to the extent related to the NECEC Transmission Line. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party are caused by or arise from the negligence, willful misconduct or criminal misconduct of, or breach or default of contract by, a Purchaser Indemnified Party. This Section 20.2 shall not apply to any claims for delay damages, cover damages, termination payments or other liquidated damages, in each case, that are asserted by any RFP Sponsor under the PPA, the Additional PPAs, the Distribution Company TSA or the Additional RFP Sponsor TSAs.
Owner Indemnity. Owner shall indemnify, defend and hold harmless Purchaser and Purchaser’s Affiliates and their respective officers, directors, shareholders, managers, members, partners, agents, employees, representatives, and permitted successors and assigns (each, a "Purchaser Indemnified Party"), from and against any and all claims, demands, suits, proceedings, judgments, losses, liabilities, damages, in each case, resulting from any third-party claims, together with any costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party, and arising out of the gross negligence, willful misconduct or criminal misconduct of Owner, other than Excluded Claims. Owner shall have no obligations under the immediately preceding sentence to the extent any claims, demands, suits, proceedings, judgments, losses, liabilities, damages, costs and expenses (including reasonable attorneys’ fees) incurred by any such Purchaser Indemnified Party are caused by or arise from the gross negligence, willful misconduct or criminal misconduct of, or breach of contract by, a Purchaser Indemnified Party.
Owner Indemnity. Owner shall indemnify, defend and hold harmless Operator and its Affiliates and partners, joint venturers, officers, agents, employees, successors, and assigns (collectively, the "Operator Indemnitees") from and against any and all suits, actions, legal or administrative proceedings, claims, demands, penalties, costs, and expenses (including attorneys' fees, court costs and all costs or expenses related to environmental clean-up, containment, remediation or removal of hazardous waste or pollution to property of third parties) of any nature for personal injury or death or physical damage to property of any third party (including employees of Owner and its subcontractors) arising out of or resulting from the performance or non- performance of Owner of its obligations hereunder or any of Owner's activities on or about the Site or other location where Owner is to perform its obligations hereunder to the extent that the same is caused by any negligent act or negligent omission of, or willful misconduct or intentional act by, Owner, its subcontractors (other than subcontractors of Operator) or suppliers (other than suppliers of Operator), or anyone employed by any of them, or anyone for whose acts any of them may be liable, unless solely caused by the negligence of any of the Operator Indemnitees. In the event that such damage or injury is caused by the joint or concurrent negligence of Operator or its employees, contractors, subcontractors or agents, the loss shall be borne by Operator and Owner proportionately to their degree of fault.
Owner Indemnity. Owner shall indemnify, defend and hold harmless the Manager Persons from and against any and all Liabilities to the extent attributable to or resulting in any way from or in connection with any Property, the management of such Property, or the performance or exercise by Manager of the Services, except to the extent Manager has acted with fraud, negligence or willful misconduct.
Owner Indemnity. OWNER SHALL DEFEND, INDEMNIFY AND HOLD HARMLESS THE OPERATOR GROUP FROM AND AGAINST ALL DAMAGES, LOSSES, COSTS AND EXPENSES (INCLUDING ALL REASONABLE ATTORNEYS’ FEES, AND LITIGATION OR ARBITRATION EXPENSES) ARISING OUT OF OR RESULTING FROM OR RELATED TO (I) INJURY TO OR DEATH OF ANY MEMBER OF THE OWNER GROUP OR (II) DAMAGE TO OR DESTRUCTION OF PROPERTY OF OWNER GROUP (EXCLUDING THE FACILITY) OCCURRING IN CONNECTION WITH THE SERVICES, REGARDLESS OF THE CAUSE OF SUCH INJURY, DEATH, PHYSICAL DAMAGE OR DESTRUCTION, INCLUDING THE SOLE OR JOINT NEGLIGENCE, BREACH OF CONTRACT OR OTHER BASIS OF LIABILITY OF ANY MEMBER OF THE OPERATOR GROUP. Owner shall indemnify, defend, and hold harmless Operator against any and all claims for Losses of whatever kind and nature, including all related costs and expenses incurred in connection therewith, in respect of personal injury to or death of third parties and in respect of loss of or damage to any third party property to the extent that the same arises out of:
Owner Indemnity. Property Manager agrees:
Owner Indemnity. Up to the proceeds received from the insurances placed by GEC and Owner hereunder, Owner, on behalf of itself, its affiliates, successors, assigns, officers, directors, employees, and agents (each an “Owner Indemnitor”), agrees to indemnify, defend and hold harmless the GEC, its affiliates, successors, assigns, officers, directors, employees, Contractor or Subcontractors and agents, from and LIMA/GEC/EPC 65 Confidential Business Information against any claims, demands, losses, damages, causes of action, suits, and liabilities (including expenses of litigation, court costs and reasonable attorneys’ fees) (a) attributable to bodily injury (including death) or property damage of third parties to the extent caused by the negligence or willful misconduct of an Owner Indemnitor or (b) attributable to bodily injury (including death) or property damage (including property of GEC or Owner) caused by any Hazardous Substances not brought onto the Site by GEC or its Contractor or Subcontractors.
