NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
Notice of Appeal In the event that an employee who has been laid off out of seniority order believes the decision based upon performance and/or qualifications is incorrect, the employee may request that the Association appeal the Sheriff’s determination. If the Association finds there is good reason to believe that the Sheriff has erred in his decision, it may appeal through the process set forth in this Article. Such appeal shall be filed within five (5) working days of delivery of the layoff notice to the employee.
Notice of Complaints Each Purchaser shall promptly notify the applicable Seller upon becoming aware of any complaint concerning any Serviced Appointment made by any party to the Serviced Corporate Trust Contract, any Securityholder, any Credit Enhancement Provider or any rating agency.
Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must:
Notice of Completion The Interconnection Customer shall notify the Transmission Provider and the Interconnected Transmission Owner in writing when it has completed construction of (i) the Customer Facility;
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Notice of Commencement A Notice of Commencement shall be filed by the Contractor with the Clerk of the Superior Court in the county in which the Project is located, pursuant to O.C.G.A. §13-10-62.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Notice of Overtime The Agency shall give as much notice as possible of overtime to be worked.