Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.
Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Landlord’s Work (a) For purposes of this lease, "Landlord's Work" means, collectively, the alterations and improvements to the demised premises to be constructed and/or installed by Landlord in accordance with the terms and conditions of this lease, as more particularly described in Exhibit ________ attached to and hereby made a part of this lease. Landlord shall use commercially reasonable efforts to "Substantially Complete" the Landlord's Work not later than ________, 20________ (the "Substantial Completion Target Date"). For purposes of this lease, Landlord's Work shall be deemed to be "Substantially Complete" as of the date on which the general contractor or the architect employed by Landlord with respect to the construction and/or installation of Landlord's Work shall certify in writing to Landlord that: (i) Landlord's Work has been substantially completed in all material respects substantially in accordance with the approved plans and specifications therefor, if any; and (ii) a temporary or permanent certificate of occupancy has been issued by the governmental authority having jurisdiction with respect to Landlord's Work or the governmental authority having jurisdiction with respect to Landlord's Work has otherwise evidenced its approval of Landlord's Work. Landlord shall have no liability whatsoever to Tenant in the event that Landlord shall fail for any reason whatsoever to Substantially Complete Landlord's Work on or before the Substantial Completion Target Date (including, without limitation, for any damages that Tenant may suffer as a result thereof or in connection therewith); provided, however, in such event, Landlord shall use commercially reasonable efforts to Substantially Complete Landlord's Work as soon as possible thereafter. Landlord shall use commercially reasonable efforts to complete any portions or aspects of Landlord's Work which shall be incomplete as of the date of Substantial Completion of Landlord's Work as soon as possible thereafter. Notwithstanding anything to the contrary set forth elsewhere in this lease, Tenant hereby acknowledges and agrees that the construction and/or installation of Landlord's Work by Landlord shall not be deemed in any way to constitute a condition precedent to the occurrence of the Commencement Date (as such date is set forth in Paragraph 1.3 of this lease) or to the effectiveness of any of the agreements or obligations of Tenant set forth in this lease with respect to the demised premises (including, without limitation, the commencement of the obligation to pay Rent by Tenant as of the Commencement Date).
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.
Landlord Improvements Landlord will construct a laboratory build-out for the Premises ("Landlord Improvements") pursuant to plans submitted by Landlord to Tenant and reasonably approved by Tenant ("Plans"), which shall be consistent with the floor plan attached hereto as Exhibit "C." The Plans generally shall provide for the Landlord Improvements to be constructed in order to accommodate generally accepted generic biotechnical laboratory uses, except as Landlord may otherwise agree. Unless otherwise determined by Landlord, the Tenant Improvements shall include the construction of an energy efficient electronically controlled central HV/AC plant. Within five (5) days after the Effective Date, Tenant shall provide to Landlord for Landlord's review and approval the following: (i) a proposed detailed list of equipment for the Premises, with the make, model, and specifications, and (ii) a detailed chemical inventory, with all codes and classifications. Tenant shall provide to Landlord such other information as Landlord may reasonably request for construction of the Landlord Improvements within five (5) days after written request therefor. Tenant shall provide written notice of its disapproval of the Plans within five (5) days after the Plans have been submitted detailing its precise reasons for disapproval. The failure of Tenant to disapprove the Plans in writing within a five (5) day period shall be conclusively deemed Tenant's approval of the Plans. Landlord shall have its architect revise the Plans to remedy any reasonable objections of Tenant, and Tenant shall have an additional five (5) day period to review the revised Plans to reasonably determine if such objections were satisfied; provided, however, Tenant shall make no new objections to the Plans. If there are any reasonable objections not addressed by revised Plans, the review procedure shall be repeated until all Tenant's objections are reasonably satisfied. If Tenant has not fully approved the Plans within sixty (60) days after the date such plans were first submitted to Tenant hereunder, Landlord at its sole election may terminate this Lease. Tenant shall timely sign and submit to Landlord a Certificate of Approval of Tenant Improvement Plans in the form as shown in Exhibit "F" attached to this Lease and incorporated herein by this reference ("Certificate"). In the case where Tenant is deemed to have approved the Plans on account of Tenant's failure to timely respond following the delivery of the Plans, such approval shall be deemed to have been given in accordance with the terms of the Certificate. Tenant acknowledges that Landlord may reasonably change the Plans as required by Applicable Law or unforeseen circumstances.
Lessee Improvements Lessee shall not make or allow to be made any alterations or physical additions in or to the leased premises without first obtaining the written consent of Lessor, which consent shall not be unreasonably withheld. Any alterations, physical additions or improvements to the leased premises made by Lessee shall at once become the property of Lessor and shall be surrendered to Lessor upon the termination of this Lease provided that Lessee shall be entitled to retain the property listed on Exhibit A attached hereto, and provided further that, Lessor, at its option, may require Lessee to remove any physical additions and/or repair any alterations in order to restore the leased premises to the condition existing at the time Lessee took possession, reasonable wear and tear excepted, all costs of removal and/or alterations to be borne by Lessee. This clause shall not apply to moveable equipment of furniture owned by Lessee, which may be removed by Lessee at the end of the term of this Lease if Lessee is not then in default and if such equipment and furniture are not then subject to any other rights, liens and interests of Lessor.
