Modifications to the Premises Sample Clauses

Modifications to the Premises. Lessee has the right, but not the obligation, to build structures on the Premises, including but not limited to any payment booth, welcome center, a tourist services center, or any combination of the foregoing. Further, the Town may improve the Premises to make it suitable for operating a public parking lot, including but not limited to marking parking areas and stalls, installing markers or barriers, and posting signage. The Town will remove any structure at the termination of the Lease term only upon the written request of the Lessor. If such a request is made, the Lessee has 90 days from the date of the request to remove the structure.
Sample 1
AutoNDA by SimpleDocs
Modifications to the Premises. Lessee has the right, but not the obligation, to build structures on the Premises, including but not limited to any payment booth, welcome center, a tourist services center, or any combination of the foregoing. Further, the Town may improve the Premises to make it suitable for operating a public parking lot, including but not limited to paving the Premises, marking parking areas and stalls, installing markers or barriers, and posting signage. Lessee is not required at the end of the Lease term to remove any work or improvements associated with fill, changing the grade, adding to the grade, or other modification considered “below grade.” Lessee is not required to remove any pavement or similar improvement at the Premises. The parties may later agree in writing that a contemplated improvement may remain on the Premises without removal, and with that writing in place, Lessee is not required to remove any so-approved improvement at the termination of this Lease or any other time. Except as provided otherwise in the foregoing sentence, upon the written request of the Lessor, within 15 days of the termination of the Lease, Lessee must remove any structure built on the Premises during the term of the Lease. If such a request is made, the Lessee has 90 days from the date of the request to remove the structure.
Sample 1
Modifications to the Premises. The Company may build facilities with a square meterage equal to up to 70% of the Premises' square meterage in up to four stories above ground level (the "Built Area"). Of the Built Area, 50% may be designated as the main activity area and the remaining 20% as ancillary services area. In addition the Company may build underground parking under the Built Area without any meter age limitation. The Addendum Under the terms of the Addendum, signed by the Company and the Landlord on August 14, 2013, the following terms in the Original Lease have been amended: · Premises Covered by the Addendum: Under the Addendum, approximately 20,000 square meters (or 215,278 square feet) of land, including the Premises and an additional 10,000 square meters (or 107,600 square feet) of land (the "Extension"), located in the Jezreel Valley Regional Council, Israel, is leased to the Company (the "Amended Premises"). 1 The Lease amount due has not been stipulated in the Lease Agreement, the full lease amount, for the Lease Agreement and the Addendum to the Lease Agreement appear in the Addendum of the Lease Agreement.
Sample 1
Modifications to the Premises. The TENANT must not install any fixtures or make any alteration, addition, installation or renovation to the premises without the LANDLORD'S consent, which must not be unreasonably refused. The LANDLORD and the TENANT agree and the LANDLORD consents to the alterations, additions, installations and renovations set out in Part E of this agreement. The LANDLORD and the TENANT must complete, sign and date Part E of this agreement prior to the TENANT making any alteration, addition, installation or renovation to the premises referred to in Part E. At the expiry or earlier termination of the tenancy agreement, the TENANT must undertake the restoration requirements (if any) or pay to the LANDLORD the amount (if any), specified in Part E of this agreement.
Sample 1
Modifications to the Premises. The LESSEE is prohibited from making physical modifications or improvements to the Premises absent prior written approval from the LESSOR.
Sample 1
Modifications to the Premises. Subject to Landlord's prior written approval, and the provisions of paragraphs 5.2 and 5.3 hereof, Tenant shall have the right to:
Sample 1
Modifications to the Premises. The Company may build facilities with a square meterage equal to up to 70% of the Premises' square meterage in up to four stories above ground level (the "Built Area"). Of the Built Area, 50% may be designated as the main activity area and the remaining 20% as ancillary services area. In addition the Company may build underground parking under the Built Area without any meter age limitation. The Addendum Under the terms of the Addendum, the following terms in the Original Lease have been amended: · Premises Covered by the Addendum: Under the Addendum, approximately 20,000 square meters (or 215,278 square feet) of land, including the Premises and an additional 10,000 square meters (or 107,600 square feet) of land (the "Extension"), located in the Jezreel Valley Regional Council, Israel, is leased to the Company (the "Amended Premises"). 1 The Lease amount due has not been stipulated in the Lease Agreement, the full lease amount, for the Lease Agreement and the Addendum to the Lease Agreement appear in the Addendum of the Lease Agreement.
Sample 1
AutoNDA by SimpleDocs
Modifications to the Premises. The LESSEE is prohibited from making physical modifications or improvements to the premises except as authorized in writing by the LESSOR. The LESSOR reserves the absolute right to accept or reject any modifications proposed by the LESSEE.
Sample 1

Related to Modifications to the Premises

  • Access to the Premises Except as provided by local ordinance, after a good faith effort to give notice, the Lessor, its agents or employees shall have access at all reasonable hours to the leased premises for the purpose of examining or exhibiting the premises to prospective buyers or prospective residents, or for making alterations or repairs on the premises which the Lessor deems necessary. Lessor shall have access at all reasonable hours to perform Lessee requested repairs, unless indicated to the contrary by Lessee. In the event of an emergency, Lessor, its agents or employees shall have immediate access without notice.

  • Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the “Renovations”) the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord’s actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Renovations or Landlord’s actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord’s actions.

  • Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.

  • Alterations Tenant shall not permit alterations in or to the Leased Premises unless and until the plans have been approved by Landlord in writing, which approval as to interior non-structural alterations shall not be unreasonably withheld, conditioned or delayed. Notwithstanding the foregoing, Tenant shall have the right without Landlord's consent, and in compliance with all other provisions of this Section, to make any non-structural alterations to the Leased Premises which do not materially impact the Building's mechanical or electrical systems, do not adversely affect the Building's appearance or value, and the cost of which does not exceed Forty Five Thousand and 00/100 Dollars ($45,000.00) in the aggregate, provided that Tenant gives Landlord fifteen (15) days prior written notice of any such alterations, along with copies of plans and specifications relating thereto. As a condition of such approval (or, with respect to any alterations permitted to be made by Tenant hereunder without Landlord's approval), Landlord hereby agrees that, upon written request by Tenant, at the time that Tenant is contemplating alterations, Landlord will inform Tenant as to whether such proposed alterations will be required to be removed by Tenant and restore the Leased Premises at the end of the Lease Term; otherwise, all such alterations shall at Landlord's option become a part of the realty and the property of Landlord, and shall not be removed by Tenant. Tenant shall ensure that all alterations shall be made in accordance with all applicable laws, regulations and building codes, in a good and workmanlike manner and of quality equal to or better than the original construction of the Building. No person shall be entitled to any lien derived through or under Tenant for any labor or material furnished to the Leased Premises, and nothing in this Lease shall be construed to constitute a consent by Landlord to the creation of any lien. If any lien is filed against the Leased Premises for work claimed to have been done for or material claimed to have been furnished to Tenant, Tenant shall cause such lien to be discharged of record within thirty (30) days after filing. Tenant shall indemnify Landlord from all costs, losses, expenses and attorneys' fees in connection with any construction or alteration under this Section 7.03, not performed by Landlord or an affiliate, and any related lien.

  • Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:

  • Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.

  • Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.

  • LANDLORD'S ACCESS TO PREMISES Landlord reserves and shall at any time upon reasonable notice and in compliance with Tenant’s reasonable security measures have the right to enter the Premises to inspect the same, to supply any service to be provided by Landlord to Tenant hereunder to service and repair HVAC units, water pipes and sprinkler mains, and electrical and telephone risers servicing other parts of the Building, to show said Premises to prospective purchasers or tenants, to alter or repair the Premises or any portion of the Building, and to place “for sale” or “for rent” signs on the Building, all without being deemed guilty of an eviction of Tenant and without abatement of Rent, provided that the business of Tenant shall be interfered with as little as is reasonably practicable. Tenant hereby waives any claim for damages or any inconvenience to or interference with Tenant’s business, any loss of quiet enjoyment of the Premises and any other loss occasioned thereby. For each of the aforesaid purposes, Landlord shall at all times have and retain a key with which to unlock the main door to the Premises but not Tenant’s vaults and safes, and Landlord shall have the right to use any and all means which Landlord may deem proper to open said door in an emergency in order to obtain entry to the Premises, and any entry to the Premises obtained by Landlord by any of said means shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of the Premises, or any eviction of Tenant from the Premises or any portion thereof. No provision of this Lease shall be construed as obligating Landlord to perform any repairs, alterations or decoration except as otherwise expressly agreed to be performed by Landlord.

  • Landlord Improvements Landlord will construct a laboratory build-out for the Premises ("Landlord Improvements") pursuant to plans submitted by Landlord to Tenant and reasonably approved by Tenant ("Plans"), which shall be consistent with the floor plan attached hereto as Exhibit "C." The Plans generally shall provide for the Landlord Improvements to be constructed in order to accommodate generally accepted generic biotechnical laboratory uses, except as Landlord may otherwise agree. Unless otherwise determined by Landlord, the Tenant Improvements shall include the construction of an energy efficient electronically controlled central HV/AC plant. Within five (5) days after the Effective Date, Tenant shall provide to Landlord for Landlord's review and approval the following: (i) a proposed detailed list of equipment for the Premises, with the make, model, and specifications, and (ii) a detailed chemical inventory, with all codes and classifications. Tenant shall provide to Landlord such other information as Landlord may reasonably request for construction of the Landlord Improvements within five (5) days after written request therefor. Tenant shall provide written notice of its disapproval of the Plans within five (5) days after the Plans have been submitted detailing its precise reasons for disapproval. The failure of Tenant to disapprove the Plans in writing within a five (5) day period shall be conclusively deemed Tenant's approval of the Plans. Landlord shall have its architect revise the Plans to remedy any reasonable objections of Tenant, and Tenant shall have an additional five (5) day period to review the revised Plans to reasonably determine if such objections were satisfied; provided, however, Tenant shall make no new objections to the Plans. If there are any reasonable objections not addressed by revised Plans, the review procedure shall be repeated until all Tenant's objections are reasonably satisfied. If Tenant has not fully approved the Plans within sixty (60) days after the date such plans were first submitted to Tenant hereunder, Landlord at its sole election may terminate this Lease. Tenant shall timely sign and submit to Landlord a Certificate of Approval of Tenant Improvement Plans in the form as shown in Exhibit "F" attached to this Lease and incorporated herein by this reference ("Certificate"). In the case where Tenant is deemed to have approved the Plans on account of Tenant's failure to timely respond following the delivery of the Plans, such approval shall be deemed to have been given in accordance with the terms of the Certificate. Tenant acknowledges that Landlord may reasonably change the Plans as required by Applicable Law or unforeseen circumstances.

  • Condition of Subleased Premises (a) Subtenant shall maintain and repair the Subleased Premises in a manner consistent with Sublandlord’s obligations under the Lease. Sublandlord shall have the right to enter the Subleased Premises from time to time upon reasonable prior notice to Subtenant, during normal business hours and escorted by Subtenant (if Subtenant makes such escort reasonably available). Sublandlord’s right of entry shall include the right of inspection to confirm that Subtenant is in compliance with all applicable maintenance and repair obligations set forth in the Lease. In the event that Sublandlord determines, in Sublandlord’s reasonable opinion, that Subtenant is in default of any maintenance and/or repair obligation set forth in the Lease which first arises after the Commencement Date, and such default may incur liability to Sublandlord upon the surrender of the Subleased Premises upon the expiration or earlier termination of the Lease (a “Required Repair Item”), then Sublandlord shall have the right to notify Subtenant of any such Required Repair Items. Subtenant shall be obligated to cure such Required Repair Items within thirty (30) days of such notice from Sublandlord, or, if such Required Repair Items cannot be reasonably completed in such thirty (30) day period, such longer period as reasonably necessary to cure such Required Repair Items, so long as Subtenant has commenced such cure and diligently pursues such cure to completion. In no event shall Sublandlord’s rights hereunder impose any additional and/or greater repair or maintenance standards from those set forth in the Lease. In the event Subtenant fails to cure such Required Repair Items as set forth above, then such failure shall be deemed a default under this Sublease, entitling Sublandlord to exercise any of its rights and remedies herein, including, without limitation, the self help rights set forth above.

Time is Money Join Law Insider Premium to draft better contracts faster.