Modification of the Contract Time Sample Clauses

Modification of the Contract Time. 9.6.1 Delays and extension of time as hereinafter described are valid only if executed in accordance with provisions set forth in Article 11.
AutoNDA by SimpleDocs
Modification of the Contract Time. Delays and extensions of Contract Time are valid only if properly noticed and documented by Change Order.

Related to Modification of the Contract Time

  • Variation of the contract The parties undertake not to vary or modify the Clauses. This does not preclude the parties from adding clauses on business related issues where required as long as they do not contradict the Clause. Clause 11

  • Duration of the contract This contract becomes effective on , and will continue in effect for 365 days from the above date. Either party may terminate treatment with reasonable notice to the other party, as provided in the agreement. Notwithstanding this right to terminate treatment, both Provider and Beneficiary agree that the obligation not to pursue Medicare reimbursement for items and services provided under this contract will survive this contract.

  • Termination of the Contract 11.1. The Coordinator may terminate the contract if the Co-beneficiary has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Co-beneficiary by registered letter has remained without effect for one month.

  • Conclusion of the contract 1. An Agreement is deemed to be concluded with the Contractor only after the Principal accepts an offer by the Contractor without reservations or if the Principal receives a written order confirmation from the Contractor or if the Contractor commences the provision of the service. If the Contractor issues a written order confirmation, such order confirmation is decisive in terms of content and scope of the Agreement unless expressly negotiated otherwise.

  • – SUSPENSION OF THE CONTRACT Without prejudice to the Agency's right to terminate the Contract, the Agency may at any time and for any reason suspend execution of the tasks under the Contract or any part thereof. Suspension shall take effect on the day the Contractor receives notification by registered letter with acknowledgment of receipt or equivalent, or at a later date where the notification so provides. The Agency may at any time following suspension give notice to the Contractor to resume the work suspended. The Contractor shall not be entitled to claim compensation on account of suspension of the Contract or of part thereof.

  • Cancellation of the Contract You are responsible for paying the full Contract Rate for the entire Contract Period, unless the Contract is canceled in accordance with one of the provisions below. Depending on when and how the Contract is canceled, you may owe the University a Cancellation Fee. The “Cancellation Fee” charged by the University constitutes an amount that will compensate the University for the costs it will incur and/or losses it will suffer as a result of your cancellation, which costs and losses are difficult to quantify. As provided in Section III.e. above, your Deposit may be used to partially defray the Cancellation Fee.

  • ADMINISTRATION OF THE CONTRACT 2.2.1 The Architect will provide administration of the Contract as hereinafter described.

  • Contract Modifications It is understood that changes are inherent in operations of the type covered by this contract. The number of changes, the scope of those changes, and the impact they have on the progress of the original operations cannot be defined at this time. The PURCHASER is notified that changes are anticipated and that there will be no compensation made to the PURCHASER directly related to the number of changes made. Each change will be evaluated for extension of contract time and increase or decrease in compensation based on its own merit. STATE reserves the right to make, at any time during the contract, such modifications as are necessary or desirable; provided such modifications shall not change the character of the operations to be done nor increase the cost, unless such operations or cost increase is approved in writing by PURCHASER. Any modifications so made shall not invalidate this contract nor release PURCHASER of obligations under the performance bond. PURCHASER agrees to do the modified operations as if it had been a part of the original contract. If any change under this section causes an increase or decrease in the PURCHASER's cost of, or the time required for the performance of any part of the operations, the PURCHASER must submit a written statement setting forth the nature and specific extent of the claim. Such claim shall include all time and cost impacts against the contract and be submitted as soon as possible, but no later than 30 days after receipt of any written notice of modification of the contract. If the PURCHASER discovers site conditions which differ materially from what was represented in the contract or from conditions that would normally be expected to exist and be inherent to the activities defined in the contract, the PURCHASER shall notify the STATE's Authorized Representative immediately and before the area has been disturbed. The STATE's Authorized Representative will investigate the area and make a determination as to whether or not the conditions differ materially from either the conditions stated in the contract or those which could reasonably be expected in execution of this particular contract. If it is determined that a differing site condition exists, any compensation or credit will be determined based on an analysis by STATE's Authorized Representative. If the PURCHASER does not concur with the decision of the STATE's Authorized Representative and/or believes that it is entitled to additional compensation, the PURCHASER may proceed to file a claim. Claims Review Process. All PURCHASER claims shall be referred to the STATE's Authorized Representative for review. All claims shall be made in writing to the STATE's Authorized Representative not more than ten days from the date of the occurrence of the event which gives rise to the claim or not more than ten days from the date that the PURCHASER knew or should have known of the problem. Unless the claim is made in accordance with these time requirements, it shall be waived. All claims shall be submitted in writing and shall include a detailed, factual statement of the basis of the claim, pertinent dates, contract provisions which support or allow the claim, reference to or copies of any documents which support the claim, the exact dollar value of the claim, and specific time extension requested for the claim. If the claim involves operations to be completed by subcontractors, the PURCHASER will analyze and evaluate the merits of the subcontractor's claim. PURCHASER shall forward the subcontractor's claim and PURCHASER's evaluation of such claim to STATE's Authorized Representative. The STATE's Authorized Representative will not consider direct claims from subcontractors, suppliers, manufacturers, or others not a party to this contract. The decision of the STATE shall be final and binding unless the PURCHASER requests mediation.

  • Contract Modification The conditions of this timber sale are completely set forth in this contract. Except as provided in B8.32 and B8.33, this contract can be modified only by written agreement between the parties. Only Contracting Officer may make contract modifications, with compensating adjustments to Current Contract Rates where appropriate, on behalf of Forest Service.

  • Control of the Contract F1 Transfer and Sub-Contracting

Time is Money Join Law Insider Premium to draft better contracts faster.