Material Occurrences Promptly notify Agent in writing upon the occurrence of (a) any Event of Default or Default; (b) any event, development or circumstance whereby any financial statements or other reports furnished to Agent fail in any material respect to present fairly, in accordance with GAAP consistently applied, the financial condition or operating results of any Borrower as of the date of such statements; (c) any accumulated retirement plan funding deficiency which, if such deficiency continued for two plan years and was not corrected as provided in Section 4971 of the Code, could subject any Borrower to a tax imposed by Section 4971 of the Code; (d) each and every default by any Borrower which might result in the acceleration of the maturity of any Indebtedness, including the names and addresses of the holders of such Indebtedness with respect to which there is a default existing or with respect to which the maturity has been or could be accelerated, and the amount of such Indebtedness; and (e) any other development in the business or affairs of any Borrower which could reasonably be expected to have a Material Adverse Effect; in each case describing the nature thereof and the action Borrowers propose to take with respect thereto.
Adverse Effect Any other action, event, or condition of any nature which could result in a material adverse effect on the business, property, or financial condition of Borrower.
Material Contract Defaults The Company is not, or has not received any notice or has any knowledge that any other party is, in default in any respect under any Material Contract; and there has not occurred any event that with the lapse of time or the giving of notice or both would constitute such a material default. For purposes of this Agreement, a “Material Contract” means any contract, agreement or commitment that is effective as of the Closing Date to which the Company is a party (i) with expected receipts or expenditures in excess of $50,000, (ii) requiring the Company to indemnify any person, (iii) granting exclusive rights to any party, (iv) evidencing indebtedness for borrowed or loaned money in excess of $50,000 or more, including guarantees of such indebtedness, or (v) which, if breached by the Company in such a manner would (A) permit any other party to cancel or terminate the same (with or without notice of passage of time) or (B) provide a basis for any other party to claim money damages (either individually or in the aggregate with all other such claims under that contract) from the Company or (C) give rise to a right of acceleration of any material obligation or loss of any material benefit under any such contract, agreement or commitment.
Material Term (1) The releases, covenants, dismissals, and granting of consent contemplated in this Section shall be considered a material term of the Settlement Agreement and the failure of any Court to approve the releases, covenants, dismissals, and granting of consent contemplated herein shall give rise to a right of termination pursuant to Section 5.1 of the Settlement Agreement.
Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:
Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:
No Material Default Neither the Seller nor any of its Affiliates is in material default under any agreement, contract, instrument or indenture of any nature whatsoever to which the Seller or any of its Affiliates is a party or by which it (or any of its assets) is bound, which default would have a material adverse effect on the ability of the Seller to perform under this Agreement, nor, to the best of the Seller's knowledge, has any event occurred which, with notice, lapse of time or both, would constitute a default under any such agreement, contract, instrument or indenture and have a material adverse effect on the ability of the Seller to perform its obligations under this Agreement;
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Material Contracts; Defaults Except for those agreements and other documents filed as exhibits to its SEC Documents, neither it nor any of its Subsidiaries is a party to, bound by or subject to any agreement, contract, arrangement, commitment or understanding (whether written or oral) (i) that is a "material contract" within the meaning of Item 601(b)(10) of the SEC's Regulation S-K or (ii) that materially restricts the conduct of business by it or any of its Subsidiaries. Neither it nor any of its Subsidiaries is in default under any contract, agreement, commitment, arrangement, lease, insurance policy or other instrument to which it is a party, by which its respective assets, business, or operations may be bound or affected, or under which it or its respective assets, business, or operations receives benefits, and there has not occurred any event that, with the lapse of time or the giving of notice or both, would constitute such a default.
