Manner of Construction. Landlord may impose, as an express condition of its consent (at the time said consent is given) to any and all Alterations (other than the Tenant Improvements) or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen selected by Tenant and approved by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed), the requirement that upon Landlord’s request at the time Landlord approves said Alterations (subject to the terms of Section 8.5, below), Tenant shall, at Tenant’s expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority). Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant shall deliver to the Project construction manager a reproducible copy of the “as built” drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations. Landlord shall make its construction rules and a pre-approved vendor list available to Tenant upon request.
Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that upon Landlord’s request, Tenant shall, at Tenant’s expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority). Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations, Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Mateo in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the “as built” drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.
Manner of Construction. Landlord may impose, as a condition of its consent to all Major Alterations of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, materials, mechanics and materialmen which regularly perform work in first-class office buildings in San Diego County, California and are approved by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed) provided such contractors and subcontractors agree to perform such work at competitive prices and pursuant to Tenant's reasonable scheduling requirements (the "Performance Requirement"); provided, however, that Tenant acknowledges and agrees that the Performance Requirement shall also apply to any Alterations installed by Tenant in the Premises except for those that are cosmetic and/or otherwise de minimis in nature. Tenant shall construct such Alterations and perform such repairs in conformance with any and all applicable rules and regulations of any federal, state, county or municipal code or ordinance and pursuant to a valid building permit, issued by the city in which the Real Property. is located, and in conformance with Landlord's commercially reasonable construction rules and regulations. Landlord's approval of the plans, specifications and working drawings for Tenant's Alterations shall create no responsibility or liability on the part of Landlord for their completeness, design sufficiency, or compliance with all applicable Laws. All work with respect to any Alterations must be done in a good and workmanlike manner and diligently prosecuted to completion to the end that the Premises shall at all times be a complete unit except during the period of work. In performing the work of any such Alterations, Tenant shall have the work performed in such manner as not to unreasonably obstruct access to the Building or Real Property or the common areas for any other tenant of the Real Property, and as not to unreasonably interfere with the business of Landlord or other tenants of the Real Property, or unreasonably interfere with the labor force working at the Real Property. If Tenant makes any Alterations, Tenant agrees to carry "Builder's All-Risk" insurance-in an amount approved by Landlord covering the construction of such Alterations, and such other insurance as Landlord may reasonably require, it being understood and agreed that all...
Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors reasonably approved by Landlord, and the requirement that upon Landlord’s request made at the time such consent is granted, Tenant shall, at Tenant’s expense, remove such Alterations upon the expiration or any early termination of the Lease Term and return the affected portion of the Premises to a building standard tenant improved condition as determined by Landlord. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the City of Mountain View, all in conformance with Landlord’s construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord’s design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the “Base Building,” as that term is defined below, then if Tenant shall not succeed in contesting such governmentally required change, Landlord shall, at Tenant’s expense, make such changes to the Base Building; provided that in the event that Tenant’s request for approval of any Alteration shall indicate Tenant’s desire for Landlord to notify Tenant of any such Base Building changes, Landlord shall notify Tenant (to the extent Landlord is then aware of any such required changes), in its approval of such Alterations (if applicable), and Tenant shall be permitted, at its option, to promptly elect to not have the Alterations performed. The “Base Building” shall include the structural portions of the Building, and the public restrooms, elevators, exit stairwells and the systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to obstruct the business of Landlord or other...
Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors reasonably approved by Landlord, and any removal and/or restoration obligations required to be performed pursuant to the TCCs of Section 8.5
Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such requirements as
Manner of Construction. Design, materials and workmanship will be in accordance with the Rules and Regulations of the Classification Society as per paragraph 2.10, laws, rules, regulations and enactment as per paragraph 2.11 and according to first class shipbuilding practice and the Technical Specification. All works and installations not precisely specified in the aforementioned documents shall be executed to internationally recognized shipbuilding practice. The Owner shall furnish to the Vessel such items as are set out in the list of Owner's Furnished Equipment attached hereto as Exhibit "E" and otherwise as may be mutually agreed in writing between the Parties.
Manner of Construction. Lessee shall be solely responsible for the design and construction of the Project in material compliance with Applicable Laws and any Permitted Exceptions. Lessee shall also comply with the provisions set forth in Schedule E attached hereto and incorporated herein by reference. Lessee shall record all notices of completion as may be required under Applicable Laws or good construction practices. Lessee shall commence construction of work on the foundations for the Venue (as opposed to pre-construction activities) no later than eighteen (18) months after the Lease Commencement Date, subject to extension on a day for day basis for each day of delay due to Force Majeure or Lessor Delay (the “Construction Commencement Date”) (provided, however, that any Force Majeure delays shall not extend the Construction Commencement Date by more than one hundred eighty (180) days after the date that is eighteen (18) months after the Lease Commencement Date), and shall diligently pursue construction of the Project thereafter. Lessee shall have achieved Development Completion and the Development Completion Date shall have occurred no later than three (3) years after the earlier to occur of (1) the actual date of commencement of work on the foundations for the Venue (as opposed to pre-construction activities) and (2) the Construction Commencement Date, subject to extension on a day for day basis for each day of delay due to Force Majeure or Lessor Delay (the “Outside Development Completion Date”) (provided, however, that Force Majeure extensions shall not be available during the period between (x) the date if any that an arbitrator determines pursuant to a binding ruling (in accordance with Section 39.15) that Lessee was not diligently pursuing construction of the Project after the Construction Commencement Date in accordance with this Section 5.3, and (y) the date that Lessee subsequently cures such default and resumes diligent pursuit of the construction). Throughout the construction process, Lessee will consult and coordinate with Lessor (with update meetings to occur no less frequently than quarterly).
Manner of Construction. Tenant shall construct any Alterations and perform any repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit issued by the City of Pasadena, and in conformance with Landlord’s construction rules and regulations; provided, however, that prior to constructing any Alterations requiring Landlord’s consent, Tenant shall obtain the approval of Landlord (which shall not be unreasonably withheld) with respect to all contractors selected by Tenant. Prior to commencing to construct any Alteration which requires Landlord’s consent, Tenant shall meet with Landlord to discuss Landlord’s design parameters and code compliance issues and any issues relating to maintain the Project’s Historical Designation. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the Building Structure, then Landlord shall, at Tenant’s expense, make such changes to the Building Structure. In performing the work of any such Alterations, Tenant shall have the work performed in a commercially reasonable manner and in such a manner so as not to obstruct access to the Project or any portion thereof. In addition to Tenant’s obligations under Article 9 of this Lease, upon completion of any Alterations, Xxxxxx agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of Los Angeles in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to Landlord a reproducible copy of the “as built” drawings of the Alterations, to the extent applicable, as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.
Manner of Construction. Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises, such reasonable and customary requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that upon Landlord's request, Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority). Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant agrees to cause a Notice of Completion to be recorded in the office of the Recorder of the County of San Mateo in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, and Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations as well as all permits, approvals and other documents issued by any governmental agency in connection with the Alterations.
