Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
Damage or Destruction If, during the Term of this Agreement, the entire Parking Facility or such portion thereof as shall render the Premises unsuitable for the continued conduct of the Tenant’s and its invitees activities thereon, shall be damaged or destroyed by fire or other casualty, then Landlord shall be entitled to retain all insurance proceeds payable by reason of and with respect to the damage or destruction to the Premises and Landlord shall rebuild or reconstruct the Parking Facility in a commercially reasonable and efficient manner subject to the following terms and conditions: (i) the casualty must be insured under Landlord's insurance policies, and Landlord’s obligation is limited to the extent of the insurance proceeds received by Landlord, (ii) Landlord’s duty to repair and restore the Premises shall not begin until receipt of the insurance proceeds, (iii) Landlord’s lender(s) must permit the insurance proceeds to be used for such repair and restoration, (iv) Landlord shall have no obligation to repair and restore any personal property on the Premises belonging to Tenant or any of Tenant’s employees, contractors, agents or invitees, (v) Landlord shall have no obligation to restore the damage or destruction (or to complete any restoration) during the last year of the Term or of any Option Period if Tenant has delivered notice that it is not renewing the Term of this Agreement pursuant to Section 2.2 or if Tenant has no more extension options pursuant to this Agreement, and (vi) Landlord shall rebuild or reconstruct the Parking Facility to a configuration substantially equivalent to that configuration which existed as of the Commencement Date. During the period in which the Parking is unavailable to a Tenant for any reason caused by Landlord during the Term of this Agreement for a period of more than thirty (30) consecutive days, including, without limitation, any such period during which Landlord is repairing and restoring the Parking Facility, the rental payable by Tenant shall xxxxx. The abatement of the rent shall be the exclusive remedy of Tenant against Landlord in the event of a casualty involving the Premises. Tenant hereby waives all claims against Landlord for any compensation or damage for loss of use of the whole or any part of the Premises and/or for any inconvenience or annoyance occasioned by any casualty and any resulting damage, destruction, repair, or restoration.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Data Destruction When no longer needed, all County PHI or PI must be cleared, purged, or destroyed consistent with NIST Special Publication 800-88, Guidelines for Media Sanitization such that the PHI or PI cannot be retrieved.
Act of God Days A. Scheduled days of student instruction which are not held because of conditions not within the control of school authorities, such as inclement weather, fires, epidemics, mechanical breakdowns, or health conditions (as defined by city, county, or state health authorities) will be rescheduled to ensure that there are a minimum number of days of student instruction as prescribed by Michigan law.
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.
Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:
