Liquidated Damages Remedy Sample Clauses

Liquidated Damages Remedy. The parties hereto agree that this Development Agreement creates an obligation and duty upon OWNER to undertake and complete development of the Project within the time and manner specified herein. In the event OWNER breaches this Development Agreement by failing to undertake and complete development of the Project within the time and manner specified herein, the parties further agree that CITY will suffer actual damages as a result thereof, the amount of which is uncertain and would be impractical or extremely difficult to fix; therefore, OWNER agrees to pay CITY, in the event of any such breach by OWNER, the sum of One Hundred Thousand Dollars ($100,000.00) as liquidated and actual damages which sum shall be in addition to any other remedies available to CITY as a result of such breach pursuant to this Section 26.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Liquidated Damages Remedy. The parties hereto agree that this Development Agreement creates an obligation and duty upon OWNER to undertake and complete development of the Project within the time and manner specified herein. In the event OWNER breaches this Development Agreement by failing to undertake and complete development of the Project within the Term (as the same may be extended as set forth in the terms of the Development Agreement hereof) and in the manner specified herein, the parties further agree that CITY will suffer actual damages as a result thereof, the amount of which is uncertain and would be impractical or extremely difficult to fix; therefore, OWNER agrees to pay CITY, in the event of any such breach by OWNER, the sum of Two Hundred Forty Thousand Dollars ($240,000.00) as liquidated and actual damages which sum shall be in addition to any other remedies available to CITY as a result of such breach pursuant to this Section
Sample 1
Liquidated Damages Remedy. INTEL’s sole remedy, and MICRON’s complete liability to INTEL, for any failure by MICRON to comply with its commitments or obligations with respect Sections 1.1, 1.2, 2.1 (limited to the provision of [*] Samples, respectively, only), and 2.2 (limited to [*] DDR2 volume production milestones, respectively, and aggregate DDR2 volume production through [*], only) hereof, shall be as set forth immediately below:
Sample 1
Liquidated Damages Remedy. BUYER AND SELLER AGREE THAT: (A) IF BUYER BREACHES ITS OBLIGATIONS UNDER Section 34(a) ABOVE, THEN SELLER’S SOLE AND EXCLUSIVE REMEDY FOR SUCH BREACH SHALL BE TO RECOVER FROM BUYER LIQUIDATED DAMAGES IN THE AMOUNT OF $650,000 AND NOT AS A PENALTY; AND (B) BECAUSE OF THE NATURE OF THIS AGREEMENT, IT WOULD BE IMPRACTICAL AND EXTREMELY DIFFICULT TO FIX SELLER’S ACTUAL DAMAGES IF SUCH A BREACH OCCURS AND THAT THEREFORE THE AMOUNT OF LIQUIDATED DAMAGES SPECIFIED ABOVE SHALL BE PRESUMED TO BE THE AMOUNT OF DAMAGES SELLER WOULD SUSTAIN BY REASON OF SUCH A BREACH AND REPRESENTS A REASONABLE ESTIMATE OF THOSE DAMAGES PURSUANT TO CALIFORNIA CIVIL CODE SECTION 1671 THROUGH 1681. BUYER’S OBLIGATION TO PAY SUCH LIQUIDATED DAMAGES IS SECURED BY A DEED OF TRUST RECORDED AGAINST THE LAND IN THE FORM OF EXHIBIT “F” ATTACHED HERETO (“TRUST DEED”), AND SELLER WAIVES THE RIGHT TO OBTAIN A DEFIENCY JUDGEMENT AGAINST BUYER AFTER ANY FORECLOSURE OF THE TRUST DEED.
Sample 1

Related to Liquidated Damages Remedy

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Delay Liquidated Damages Delay Liquidated Damages has the meaning set out in GC 7.6.1.

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.

  • Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.

  • Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.

  • CONTRACT TIME AND LIQUIDATED DAMAGES (7-1-95) (Rev. 12-18-07) 108 SP1 G10 A The date of availability for this contract is August 1, 2018. The completion date for this contract is December 10, 2019. Except where otherwise provided by the contract, observation periods required by the contract will not be a part of the work to be completed by the completion date and/or intermediate contract times stated in the contract. The acceptable completion of the observation periods that extend beyond the final completion date shall be a part of the work covered by the performance and payment bonds. The liquidated damages for this contract are Five Hundred Dollars ($ 500.00) per calendar day.

  • Damages; Relief Termination of this Agreement shall not preclude either Party from claiming any other damages, compensation or relief that it may be entitled to upon such termination.

  • Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.

Time is Money Join Law Insider Premium to draft better contracts faster.