INSPECTIONS DURING CONSTRUCTION Sample Clauses

INSPECTIONS DURING CONSTRUCTION. The Hydroelectric Facility shall be subject to periodic or continuous inspection by the Contracting Officer throughout its time of construction. The Contracting Officer shall inspect the Hydroelectric Facility to the extent necessary, as determined by the Contracting Officer, to ensure the continued safe operation and structural integrity of the Project facilities. Any construction and/or OM&R deficiencies or difficulties detected by the Contracting Officer will be immediately reported to the Lessee. In those cases when a construction and/or OM&R practice or deficiency may result in a situation that would or could endanger the structural integrity, environmental quality, safety, operational commitment of the Project facility, the Contracting Officer shall have the authority to stop construction and/or OM&R activities until the problem or situation is resolved to the satisfaction of the Contracting Officer.
Sample 1
AutoNDA by SimpleDocs
INSPECTIONS DURING CONSTRUCTION. Once construction is properly permitted to proceed, project compliance inspections will be performed and certified to by an independent third party mutually agreed upon by Applicant and the District, with the costs of such inspections to be paid for by Applicant. - Hunewill Construction will be the General Contractor - Xxxxx Xxxxx will monitor daily construction activity - CME will conduct compaction test daily - Humboldt County Building & Safety Manager will provide occasional inspections (i.e every two days or thereabouts)
Sample 1
INSPECTIONS DURING CONSTRUCTION. Upon final approval by District, and upon Applicant obtaining all other necessary permits, Applicant may proceed with construction of the improvements in accordance with the final approved engineering documentation. Applicant shall give District and District Engineer 2 weeks’ notice before beginning construction. The District shall appoint an Inspector who will represent the District during construction and who shall be on- site during all construction activities. The Inspector shall document construction activities and shall have the authority to request changes to defective construction work or work that is not in accordance with the approved engineering documentation. Upon completion of all improvements, Applicant shall provide District with one set of “As-Built” record drawings, along with an electronic copy in AutoCAD format.
Sample 1
INSPECTIONS DURING CONSTRUCTION. In order to expedite the construction of the Project in the time period desired by Power, the City's Building Inspection Department will not inspect the construction. Power agrees to contract with, or cause its Project developer to contract with, additional architects and engineers, with the approval of the City, to inspect the construction and to certify that all aspects of the Project are constructed in accordance with all applicable building, construction, plumbing and other development requirements.
Sample 1
INSPECTIONS DURING CONSTRUCTION. XXX may perform routine inspections of any construction over which FOCAS has responsibility while construction is in progress. A representative of the applicable Utility Company may be on-site during all construction work to perform functions such as safety watch, protection of its electric transmission system, and to obtain clearances.
Sample 1

Related to INSPECTIONS DURING CONSTRUCTION

  • Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.

  • Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.

  • During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

  • Inspection of Collateral Lender and Lender's designated representatives and agents shall have the right at all reasonable times to examine and inspect the Collateral wherever located.

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • Inspections The Servicer shall inspect the Mortgaged Property as often as deemed necessary by the Servicer in accordance with Accepted Servicing Practices to assure itself that the value of the Mortgaged Property is being preserved. In addition, if any Mortgage Loan is more than 45 days delinquent, the Servicer promptly shall inspect the Mortgaged Property and shall conduct subsequent inspections in accordance with Accepted Servicing Practices or as may be required by the primary mortgage guaranty insurer. Upon request, the Servicer shall produce an electronic report of each such inspection.

  • Installation, Inspection, and Maintenance The Contractor is responsible for installation and maintenance of the BMPs as a part of its Bid. The Design Professional shall obtain the services of a qualified testing laboratory to inspect the BMPs in accordance with the permits, the costs of such inspections to be borne by the Owner. In the event of Abnormal Weather Conditions or force majeure, the Contractor shall be compensated for re-installation of BMPs at established Unit Prices.

Time is Money Join Law Insider Premium to draft better contracts faster.