Initial Notice. Promptly after receipt by Indemnitee of notice of the commencement of or the threat of commencement of any Proceeding, Indemnitee shall, if indemnification with respect thereto may be sought from the Company under this Agreement, notify the Company of the commencement thereof. Indemnitee shall include therein or therewith such documentation and information as is reasonably available to Indemnitee and is reasonably necessary to determine whether and to what extent Indemnitee is entitled to indemnification. The Secretary of the Company shall promptly advise the Board in writing that Indemnitee has requested indemnification.
Initial Notice. If Owner has a Claim, Owner shall promptly notice Contractor of such Claim in writing, setting forth the known details and support for the Claim. If Contractor has a Claim, Contractor shall furnish Owner with a detailed, supported, written notice, setting forth the known or estimated length of any Delay and any known or estimated monetary impacts, due to such Claim. Contractor shall deliver to Owner such notice no later than seven (7) Days following actual knowledge of the event giving rise to the Claim. For purposes of Owner Parties’ denial of any of Contractor’s requests to modify any terms of the Contract Documents (whether Contract Sum, Contract Time, or otherwise) in accordance with Contractor’s rights to make such requests under the Contract Documents, the event giving rise to the Claim (and thus the start of the seven (7) Day period) shall be Contractor’s receipt of Owner Parties’ written denial. If it is impracticable to specify the actual length of a delay or monetary amount of a Claim at the time notice is required, the claimant shall provide estimates and periodic supplemental notices to keep the nonclaimant party informed of any change and other relevant information while the events giving rise to the Claim continue.
Initial Notice. Either Party may initiate dispute resolution procedures by sending written notice (the “Initial Notice”) to the other Party specifically stating the complaining Party’s claim and requesting dispute resolution in accordance with this Article 20. The Parties shall attempt in good faith to resolve any dispute arising out of or relating to this Agreement promptly by negotiation between executives who have authority to settle the controversy and who are at a higher level of management than the persons with direct responsibility for administration of this contract. Within 10 Business Days after delivery of the Initial Notice, the receiving Party shall submit to the other a written response. The Initial Notice and response shall include (a) a statement of that Party’s position and a summary of arguments supporting that position, and (b) the name and title of the executive who will represent that Party and of any other person who will accompany the executive. Within 25 Business Days after delivery of the Initial Notice, the executives of both Parties shall meet at a mutually acceptable time and place, and thereafter as often as they reasonably deem necessary, to attempt to resolve the dispute. All negotiations pursuant to this clause are confidential and shall be treated as compromise and settlement negotiations for purposes of applicable rules of evidence.
Initial Notice. See Section 10.2(a).
Initial Notice. Any Party asserting a Claim (“Claimant”) against another Party (“Respondent”) shall give written notice to each Respondent and to the Executive Board stating Claimant’s good faith description of: (i) the nature of the Claim, including the persons involved and the Respondent’s role in the Claim, and (ii) the Claimants’ desire to meet with the Respondent to discuss in good faith, ways to resolve the Claim. In that legal and professional fees are discouraged at this stage of these Procedures, no statement as to the legal basis of the Claim or of any proposed remedy is necessary.
Initial Notice. Either party promptly shall inform the other party whenever there is reason to believe that termination of the contract is indicated because of the existence of circumstances or conditions such as, but not limited to, failure to perform obligations described in this AGREEMENT, varying from the proposal without approval, lack of sufficient students, or the program not being fulfilled or reaching a stage where further efforts would produce little or no results as contemplated by the enabling legislation.
Initial Notice. Upon the Effective Date of this Agreement, the Association shall timely file with the Office of the Secretary of State the information required by Government Code Sections 6503.5 and 53051.
Initial Notice. For federal information, including without limitation, Federal Tax Information, Social Security Administration Data, and Medicaid Member Information, within the first, consecutive clock hour of discovery, and for all other types of Confidential Information not more than 24 hours after discovery, or in a timeframe otherwise approved by HHSC in writing, initially report to HHSC's Privacy and Security Officers via email at: xxxxxxx@xxxx.xxxxx.xx.xx and to the HHSC division responsible for this Contract;
Initial Notice. The Director must notify the Teacher and the Chapter Leader of the Association in writing of his/her request for "review of tenure." This notice shall describe the general areas of concern which shall be reflected in and supported by the standards and criteria developed by the standing committee created for this purpose in the 1998/99 contract year (interim standards and evaluation forms agreed upon by the Administration and the Association will be used until supplanted by further agreement following receipt of the standing committee's report).
Initial Notice. The first written notice YEP sends to you fifty-two to ninety (52 – 90) days prior to the expiration of your Initial Term, if you are enrolled in a fixed term plan, or if we propose to change the terms of service in any type of agreement.
