INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
INDEMNIFICATION RELATING TO INTELLECTUAL PROPERTY Contractor shall indemnify and hold the Department and the State of Utah harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities, and costs in any action or claim brought against the Department or the State of Utah for infringement of a third party’s copyright, trademark, trade secret, or other proprietary right. The parties agree that if there are any limitations of Contractor’s liability, such limitations of liability will not apply to this section.
Right to Indemnification Each Person who was or is made a party or is threatened to be made a party to or is otherwise involved in any action, suit or proceeding, whether civil, criminal, administrative or investigative (a “Proceeding”), by reason of the fact that he, she or it is or was the Sole Member, a Manager, an Officer, or an officer, director or stockholder of the Sole Member in its capacity as sole member of the Company, or is or was serving at the request of the Company as a director, manager or officer of another limited liability company, corporation, partnership, joint venture, trust or other enterprise, including service with respect to an employee benefit plan (an “Indemnitee”), whether the basis of such Proceeding is alleged action in an official capacity as an equity holder, manager, director or officer or in any other capacity while serving as an equity holder, manager, director or officer, shall be indemnified and held harmless by the Company, to the fullest extent permitted or required by the Delaware General Corporation Law as if the Company were a Delaware corporation, as the same exists or may hereafter be amended (but, in the case of any such amendment, only to the extent that such amendment permits broader indemnification rights than such law permitted prior to such amendment), against all expense, liability and loss (including attorneys’ fees, judgments, fines, excise taxes under the Employee Retirement Income Security Act of 1974, as amended and as may be further amended from time to time (“ERISA”), or penalties and amounts paid in settlement) reasonably incurred or suffered by such Indemnitee in connection therewith; provided, however, that, except as provided in Section 5.6 with respect to Proceedings to enforce rights to indemnification, the Company shall indemnify any such Indemnitee in connection with a Proceeding (or part thereof) initiated by such Indemnitee only if such Proceeding (or part thereof) was authorized by the Managers.
Procedures Related to Indemnification In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined).
Indemnification Clause The Union agrees to indemnify and hold the County of Los Angeles harmless from any liabilities of any nature which may arise as a result of the application of the provisions of this Article.
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
Limitation of Liability Indemnification (a)None of the Asset Manager, its affiliates, or any of their respective directors, members, stockholders, partners, officers, employees or controlling persons (collectively, “Managing Parties”) shall be liable to the Series or the Company for (i) any act or omission performed or failed to be performed by any Managing Party (other than any criminal wrongdoing) arising from the exercise of such Managing Party’s rights or obligations hereunder, or for any losses, claims, costs, damages, or liabilities arising therefrom, in the absence of criminal wrongdoing, willful misfeasance or gross negligence on the part of such Managing Party, (ii) any tax liability imposed on the Series or the Series #TICKER Asset, or (iii) any losses due to the actions or omissions of the Series or any brokers or other current or former agents or advisers of the Series.
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification (Breach of Warranty of Security) The Contractor agrees to defend, indemnify and hold harmless the Department, Customer, the State of Florida, its officers, directors and employees for any claims, suits or proceedings related to a breach of the Warranty of Security. The Contractor will include credit monitoring services at its own cost for those individuals affected or potentially affected by a breach of this warranty for a two year period of time following the breach.